Development Schedule The Project shall substantially comply with the specific timetables and triggers for action set forth in Article 5 of this Agreement. The parties acknowledge that, as provided in G.S. 160A-400.25(b), the failure to meet a commencement or completion date shall not, in and of itself, constitute a material breach of this Agreement pursuant to G.S. 160A-400.27 but must be judged based upon the totality of the circumstances.
Change Order (5) The Change Order is then submitted to the Project Manager who immediately processes the CO with OPC as required by Bulletin 3.5 and BGS’ Contracting Plan.
Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).
Product Changes Vocera shall have the right, in its absolute discretion, without liability to End User, to update to provide new functionality or otherwise change the design of any Product or to discontinue the manufacture or sale of any Product. Vocera shall notify End User at least 90 days prior to the delivery of any Product which incorporates a change that adversely affects form, fit or function (“Material Change”). Vocera shall also notify End User at least 90 days prior to the discontinuance of manufacture of any Product. Notification will be made as soon as reasonably practical for changes associated with regulatory or health and safety issues.
Development Plan document specifying the work program, schedule, and relevant investments required for the Development and the Production of a Discovery or set of Discoveries of Oil and Gas in the Contract Area, including its abandonment.
Statement of Work The Contractor shall provide the services and staff, and otherwise do all things necessary for or incidental to the performance of work, as set forth below:
Development and Regulatory Milestones With respect to each of the following milestones, Ikaria shall pay BioLineRx the corresponding payment set forth below within [**] days after the achievement by Ikaria, its Affiliates or Licensees of such milestone: MILESTONE PAYMENT
Additional Products Upon satisfying the minimum order requirements above, Enrolled Affiliate may order Additional Products.
Software Modifications Company may request that BNYM, at Company’s expense, develop modifications to the software constituting a part of the Licensed System that BNYM generally makes available to customers for modification (“Software”) that are required to adapt the Software for Company’s unique business requirements. Such requests, containing the material features and functionalities of all such modifications in reasonable detail, will be submitted by Company in writing to BNYM in accordance with the applicable, commercially reasonable procedures maintained by BNYM at the time of the request. Company shall be solely responsible for preparing, reviewing and verifying the accuracy and completeness of the business specifications and requirements relied upon by BNYM to estimate, design and develop such modifications to the Software. BNYM shall have no obligation to develop modifications to the Licensed System requested by Company, but may in its discretion agree to develop requested modifications which it, in its sole discretion, reasonably determines it can accomplish with existing resources or with readily obtainable resources without disruption of normal business operations provided Company agrees at such time in writing to pay all costs and expenses, including out-of-pocket expenses, associated with the customized modification. BNYM shall be obligated to develop modifications under this Section 2.16 only upon the execution of and in accordance with a writing containing, to BNYM’s reasonable satisfaction, all necessary business and technical terms, specifications and requirements for the modification as determined by BNYM in its sole judgment (“Customization Order”) and Company’s agreement to pay all costs and expenses, including out-of-pocket expenses, associated with the customized modification (“Customization Fee Agreement”). All modifications developed and incorporated into the Licensed System pursuant to a Customization Order are referred to herein as “Company Modifications”. BNYM may make Company Modifications available to all users of the Licensed System, including BNYM, at any time after implementation of the particular Company Modification and any entitlement of Company to reimbursement on account of such action must be contained in the Customization Fee Agreement.
Manufacturing Services Jabil will manufacture the Product in accordance with the Specifications and any applicable Build Schedules. Jabil will reply to each proposed Build Schedule that is submitted in accordance with the terms of this Agreement by notifying Company of its acceptance or rejection within three (3) business days of receipt of any proposed Build Schedule. In the event of Jabil’s rejection of a proposed Build Schedule, Jabil’s notice of rejection will specify the basis for such rejection. When requested by Company, and subject to appropriate fee and cost adjustments, Jabil will provide Additional Services for existing or future Product manufactured by Jabil. Company shall be solely responsible for the sufficiency and adequacy of the Specifications [***].
