Landlord’s Contribution Landlord shall, in the manner hereinafter set forth, contribute the lesser of (i) the actual cost of Tenant’s Work or (ii) $1,698,800.00 (calculated on the basis of $40.00 per rentable square foot of the Relocation Premises) (“Landlord’s Contribution”) towards the costs of designing and constructing Tenant’s Work. Tenant shall be entitled to use up to $424,700.00 (i.e., $10.00 per rentable square foot of the Relocation Premises) of Landlord’s Contribution towards the cost of architectural and engineering drawings, furniture, fixtures and equipment, permitting costs, cabling, wiring and moving costs, signage, third-party legal fees and consulting costs incurred by Tenant in the performance of Tenant’s Work. Provided no Default of Tenant exists at the time that Tenant submits any Requisition (as hereinafter defined) on account of Landlord’s Contribution, Landlord shall pay the cost of the work shown on each Requisition submitted by Tenant to Landlord within twenty-five (25) days of Landlord’s receipt thereof. For the purposes hereof, a “Requisition” shall mean written documentation showing in reasonable detail the costs of the Tenant’s Work then installed by Tenant in the Premises. Each Requisition shall be accompanied by evidence reasonably satisfactory to Landlord that all work covered by previous Requisitions has been fully paid. Landlord shall have the right, upon reasonable advance notice to Tenant, to inspect Tenant’s books and records relating to each Requisition in order to verify the amount thereof. Tenant shall submit Requisition(s) no more often than monthly. Landlord’s Contribution, less a 10% retainage (which retainage shall be payable as part of the final draw), shall be paid to the general contractor that performs Tenant’s Work, in periodic disbursements within twenty-five (25) days after receipt of the following documentation: (i) an application for payment and sworn statement of contractor substantially in the form of AIA Document G-702 covering all work for which disbursement is to be made to a date specified therein; (ii) a certification from an AIA architect substantially in the form of the Architect’s Certificate for Payment found in AIA Document G702, Application and Certificate of Payment; (iii) Contractor’s, subcontractor’s and material supplier’s waivers of liens which shall cover all Tenant’s Work for which disbursement is being requested and all other statements and forms required for compliance with the mechanics’ lien laws of the state in which the Relocation Premises is located, together with all such invoices, contracts, or other supporting data as Landlord or Landlord’s Mortgagee may reasonably require; (iv) a cost breakdown for each trade or subcontractor performing Tenant’s Work; (v) plans and specifications for Tenant’s Work, together with a certificate from an AIA architect that such plans and specifications comply in all material respects with all laws affecting the Building, Property and Relocation Premises; (vi) copies of all construction contracts for Tenant’s Work, together with copies of all change orders, if any; and (vii) a request to disburse from Tenant containing an approval by Tenant of the work done and a good faith estimate of the cost to complete Tenant’s Work. Upon completion of Tenant’s Work, and prior to final disbursement of Landlord’s Contribution, Tenant shall furnish Landlord with: (I) general contractor and architect’s completion affidavits, (2) full and final waivers of lien, (3) receipted bills covering all labor and materials expended and used, (4) as-built plans of the Tenant’s Work, and (5) the certification of Tenant’s architect that Tenant’s Work has been installed in a good and workmanlike manner in accordance with the Tenant’s Plans, and in accordance with applicable laws, codes and ordinances. In no event shall Landlord be required to disburse Landlord’s Contribution more than one (1) time per month. Notwithstanding anything herein to the contrary, Landlord shall not be obligated to disburse any portion of Landlord’s Contribution during the continuance of an uncured Default by Tenant under the Lease, and Landlord’s obligation to disburse shall only resume when and if such Default is cured. If Tenant does not submit a request for payment of the entire Landlord’s Contribution to Landlord in accordance with the provisions contained in this Section II (D) on or before the date that is twelve (12) months after the Relocation Date, any unused amount shall accrue to the sole benefit of Landlord, it being understood that Tenant shall not be entitled to any credit, abatement or other concession in connection therewith. Tenant shall be responsible for all applicable state sales or use taxes, if any, payable in connection with Tenant’s Work and Landlord’s Contribution.
Tenant’s Work During the Term Tenant may not perform any work, alterations, installations, additions, improvements, structural repairs or restorations to the Property (“Tenant’s Work”) without the prior written consent of Landlord which (i) in the case of alterations, additions, installations or improvements of a structural nature or involving the Building systems, may be granted or withheld by Landlord in its sole and absolute discretion and (ii) in the case of alterations or improvements of a non-structural nature or not involving Building systems, shall not be unreasonably withheld or delayed. In connection with such consent, Tenant shall submit to Landlord such detailed plans, specifications, drawings and other materials reasonably requested by Landlord. Tenant may make such non-structural alterations and perform work of a decorative nature without Xxxxxxxx’s prior written consent. At Tenant’s sole cost, Xxxxxxxx agrees to cooperate with Xxxxxx (including signing applications) in obtaining any necessary permits for any Tenant’s Work that Xxxxxx is permitted to make hereunder. In all cases the Tenant’s Work shall be performed at Tenant’s sole cost and expense and by contractors selected by Xxxxxx. Tenant agrees that the Tenant’s plans and specifications shall be in compliance with applicable laws, rules and regulations, that Tenant shall not commence construction until it obtains (if required) a building permit for Tenant’s Work, and that such Tenant’s Work shall be performed in accordance with the building permit, in compliance with applicable law and in accordance with the Tenant’s plans and specifications. As a condition of approving such Tenant's Work the Landlord may require the Tenant to maintain such additional insurance coverages (in addition to those required in Article 8 hereof) as the Landlord may reasonably require.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Landlord’s Fees Whenever Tenant requests Landlord to take any action not required of it hereunder or give any consent required or permitted under this Lease, Tenant will reimburse Landlord for Landlord’s reasonable, out-of-pocket costs payable to third parties and incurred by Landlord in reviewing the proposed action or consent, including reasonable attorneys’, engineers’ or architects’ fees, within thirty (30) days after Landlord’s delivery to Tenant of a statement of such costs. Tenant will be obligated to make such reimbursement without regard to whether Landlord consents to any such proposed action.
Landlord's Costs Tenant shall, within thirty (30) days after receipt of an invoice from Landlord, pay the reasonable costs, expenses, and fees of any architect or engineer employed by Landlord to review any plans and specifications and to supervise and approve any construction, or for any services rendered by such architect or engineer to Landlord as contemplated by any of the provisions of this Agreement, or for any services performed by Landlord's attorneys in connection therewith; provided, however, that Landlord will consult with Tenant and notify Tenant of the estimated amount of such expenses.
Tenant’s Contractors If Tenant should desire to enter the Premises or authorize its agent to do so prior to the Commencement Date of the Lease, to perform approved work not requested of the Landlord, Landlord shall permit such entry if:
Landlord’s Expenses In the event Tenant shall assign this Lease or sublet the Premises or request the consent of Landlord to any Transfer, then Tenant shall pay Landlord's reasonable costs and expenses incurred in connection therewith, including, but not limited to, attorneys', architects', accountants', engineers' or other consultants' fees.
Landlord's Improvements All fixtures, improvements or equipment which are installed, constructed on or attached to the Premises or Common Area by Landlord shall be a part of the realty and belong to Landlord.
Landlord’s Repairs Landlord, as an Operating Expense, shall maintain all of the structural, exterior, parking and other Common Areas of the Project, including HVAC, plumbing, fire sprinklers, elevators and all other building systems serving the Premises and other portions of the Project (“Building Systems”), in good repair, reasonable wear and tear and uninsured losses and damages caused by Tenant, or by any of Tenant’s agents, servants, employees, invitees and contractors (collectively, “Tenant Parties”) excluded. Losses and damages caused by Tenant or any Tenant Party shall be repaired by Landlord, to the extent not covered by insurance, at Tenant’s sole cost and expense. Landlord reserves the right to stop Building Systems services when necessary (i) by reason of accident or emergency, or (ii) for planned repairs, alterations or improvements, which are, in the judgment of Landlord, desirable or necessary to be made, until said repairs, alterations or improvements shall have been completed. Landlord shall have no responsibility or liability for failure to supply Building Systems services during any such period of interruption; provided, however, that Landlord shall, except in case of emergency, make a commercially reasonable effort to give Tenant 24 hours advance notice of any planned stoppage of Building Systems services for routine maintenance, repairs, alterations or improvements. Tenant shall promptly give Landlord written notice of any repair required by Landlord pursuant to this Section, after which Landlord shall make a commercially reasonable effort to effect such repair. Landlord shall not be liable for any failure to make any repairs or to perform any maintenance unless such failure shall persist for an unreasonable time after Tenant’s written notice of the need for such repairs or maintenance. Tenant waives its rights under any state or local law to terminate this Lease or to make such repairs at Landlord’s expense and agrees that the parties’ respective rights with respect to such matters shall be solely as set forth herein. Repairs required as the result of fire, earthquake, flood, vandalism, war, or similar cause of damage or destruction shall be controlled by Section 18.
LESSEE'S IMPROVEMENTS Since Lessor is the Insuring Party, Lessor shall not be required to insure Lessee-Owned Alterations and Utility Installations unless the item in question has become the property of Lessor under the terms of this Lease.
