Claims for Overtime Sample Clauses

Claims for Overtime. Any worker employed by the Contractor shall be foreclosed from the right to collect for any overtime provided in ORS 279C.540 unless a claim for payment is filed with the Contractor within 90 days from the completion of the Contract, provided the Contractor has: (1) caused a circular clearly printed in boldfaced 12-point type and containing a copy of this Section 5.4 to be posted in a prominent place alongside the door of the timekeeper’s office or in a similar place that is readily available and freely visible to any or all workers employed on the Work; and (2) maintained such circular continuously posted from the inception to the completion of the contract on which workers are or have been employed.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Claims for Overtime. Any worker employed by Contractor shall be foreclosed from the right to collect for any overtime provided for in ORS 279C.540, unless a claim for payment is filed with Contractor within 90 days from the completion of the Contract, provided Contractor has (1) caused a circular, clearly printed in boldfaced 12-point type and containing a copy of this section, to be posted in a prominent place alongside the door of the timekeeper’s office or in a similar place that is readily available and freely visible to any or all workers employed on the Work;
Sample 1Sample 2Sample 3
Claims for Overtime. All claims for payment of overtime hours worked shall be made to the Chief Constable on the prescribed forms and all such claims must bear the approval of the Chief Constable prior to processing.
Sample 1Sample 2Sample 3
Claims for Overtime. All claims for payment of overtime hours worked shall be made to the appropriate NCO on the prescribed forms and all such claims must bear the approval of the NCO prior to processing.
Sample 1
Claims for Overtime. All claims for overtime payment are made by completion of a time sheet. The supervisor and the employee must sign and forward the form to the payroll clerk semi-monthly.
Sample 1

Related to Claims for Overtime

  • Claims for Additional Time § 14.1.6.1 If the Design-Builder intends to make a Claim for an increase in the Contract Time, written notice as provided herein shall be given. The Design-Builder’s Claim shall include an estimate of cost and of probable effect of delay on progress of the Work. In the case of a continuing delay, only one Claim is necessary.

  • Claims for Benefits All Claims for benefits will be deemed to have been filed on the date received by AvMed. If a Claim is a Pre-Service or Urgent Care Claim, a Health Professional with knowledge of the Member’s Condition will be permitted to act as the Member’s authorized representative, and will be notified of all approvals on the Member’s behalf.

  • CLAIMS FOR ADDITIONAL COST 12.3.1 If the Contractor wishes to make a claim for an increase in the Contract Sum, he shall give the Architect written notice thereof within twenty days after the occurrence of the event giving rise to such claim. This notice shall be given by the Contractor before proceeding to execute the Work, except in an emergency endangering life or property in which case the Contractor shall proceed in accordance with Paragraph 10.3 of these General Conditions. No such claim shall be valid unless so made. If the State and the Contractor cannot agree on the amount of the adjustment in the Contract Sum, it shall be determined by the Architect. Any change in the Contract Sum resulting from such claim shall be authorized by Change Order.

  • CLAIMS FOR DAMAGES 7.4.1 Should either party to the Contract suffer injury or damage to person or property because of any act or omission of the other party or of any of his / her employees, agents or others for whose acts he / she is legally liable, claim shall be made in writing to such other party within a reasonable time after the first observance of such injury or damage.

  • No Entitlement or Claims for Compensation By accepting this Agreement, you hereby acknowledge and agree as follows:

  • Matters Applicable to All Requests for Compensation (a) Any Agent or any Lender claiming compensation under this Article III shall deliver a certificate to the Borrower setting forth the additional amount or amounts to be paid to it hereunder which shall be conclusive in the absence of manifest error. In determining such amount, such Agent or such Lender may use any reasonable averaging and attribution methods.

  • Technical Objections to Grievances It is the intent of both parties to this agreement that no grievance shall be defeated merely because of a technical error other than time limitations in processing the grievance through the grievance procedure. To this end an arbitration board shall have the power to allow all necessary amendments to the grievance and the power to waive formal procedural irregularities in the processing of a grievance in order to determine the real matter in dispute and to render a decision according to equitable principles and the justice of the case.

  • Statement of Grievance The grievance shall contain a statement of:

  • Grievance Commissioner System This is to confirm the discussion of the parties during collective bargaining that they are committed to encouraging early discussion and resolution of labour relations issues at the local level and seek to resolve grievances in a timely and cost efficient manner. To that end, this is to confirm that pursuant to Article 8, the parties agree that the Employer and Union at individual nursing homes may agree to utilize the following process in order to resolve a particular grievance through the utilization of a joint mediation-arbitration procedure:

  • Grievance Committee The Hospital will recognize a Grievance Committee composed of the Chief Xxxxxxx and not more than (as set out in Local Provisions Appendix) employees selected by the Union who have completed their probationary period. A general representative of the Union may be present at any meeting of the Committee. The purpose of the Committee is to deal with complaints or grievances as set out in this Collective Agreement. The Union shall keep the Hospital notified in writing of the names of the members of the Grievance Committee appointed or selected under this Article as well as the effective date of their respective appointments. A Committee member shall suffer no loss of earnings for time spent during their regular scheduled working hours in attending grievance meetings with the Hospital up to, but not including arbitration. The number of employees on the Grievance Committee shall be determined locally.

Time is Money Join Law Insider Premium to draft better contracts faster.