Target Completion Date has the meaning given such term in Section 3.3(b).
Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.
The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.
Final Completion Date means the date on which Final Completion occurs.
Project Completion Date means the date on which the Completion Certificate is issued;
Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity
project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;
COMPLETION TIME means the period by ‘date/month’ specified in the ‘Letter of Intent/Award’ or date mutually agreed upon for handing over of the intended scope of work, the erected equipment/plant which are found acceptable by the Engineer, being of required standard and conforming to the specifications of the Contract.
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
Substantial Completion Date means the date on which Substantial Completion occurs.
Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.
Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.
Scheduled Completion Date shall be the date set forth in Clause 10.3;
Construction Completion means physical construction of a cleanup action component is complete.
Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date
Virtual Completion means the premise is in the opinion of the Employer fit for occupation.
Project Completion Schedule means the progressive Project Milestones set forth in Schedule-J for completion of the Project Highway on or before the Scheduled Completion Date;
Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;
Commissioning Period means, with respect to each Subproject, the period commencing upon the first delivery of Feed Gas to the Subproject in accordance with Sections 4.8 and 11.1 of the Agreement continuing through achievement of RFSU, commissioning, Start Up, Performance Testing and achievement of Substantial Completion for such Subproject.
Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;
Project Milestone means the project milestone set forth in Schedule-J;
Completion Schedule means the fulfilment of the Related Services by the Supplier in accordance with the terms and conditions set forth in the Contract;
Milestone Date means the date set against the relevant Milestone in the Implementation Plan;
Framework Commencement Date means [insert date dd/mm/yyyy];
Testson Completion means the tests which are specified in the Contractor agreed by both Parties or instructed as a Variation, and which are carried out under Clause 9 [Tests on Completion] before the Works or a Section (as the case may be) are taken over by the Procuring Entity.
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which: