Notice of Acceptance definition

Notice of Acceptance means the written notification and any accompanying documentation sent to the Consultant by the Principal advising acceptance of its Tender to provide the Services under the Contract.

Notice of Acceptance means the written notification and any accompanying documentation sent to the Contractor by the Principal advising acceptance of its Quotation to execute the Works.

Notice of Acceptance has the meaning set forth in Section 4.15(b).

Examples of Notice of Acceptance in a sentence

Contract - This RFP, any addendum to this RFP, the bidder's bid proposal submitted in response to this RFP and the Division's Notice of Acceptance.
In the event that any Buyer so elects to reduce the number or amount of Offered Securities specified in its Notice of Acceptance, the Company may not issue, sell or exchange more than the reduced number or amount of the Offered Securities unless and until such securities have again been offered to the Buyers in accordance with Section 4(o)(i) above.
Discrete physical portions of the Project may be separately and partially deemed finally complete at the discretion of the Principal Representative when that portion of the Project reaches such stage of completion and a partial Notice of Acceptance can be issued.
The Notice of Acceptance shall establish the completion date of the Project.
Such property insurance shall be maintained, unless otherwise provided in the Contract Documents or otherwise agreed in writing by all persons and entities who are beneficiaries of such insurance, until final payment has been made or until no person or entity other than the Owner has an insurable interest in the property, or the Date of Notice specified on the Notice of Acceptance, State Form SBP-6.27 or whichever is later.

Notice of Acceptance means a written notice from a Purchaser to the Company containing the information specified in Section 3.1(b).

Notice of Acceptance has the meaning set forth in Section 2.3(b)(i).

Notice of Acceptance means the written notification and any accompanying documentation sent to the Contractor by the Principal advising acceptance of the its to supply the Goods under the Contract.

Notice of Acceptance means formal notice by KDOT to a Contractor that the Contractor has completed all physical work on the Project and that the Contractor is relieved of responsibility to perform physical construction on the Project (except construction arising out of any breach of warranty, breach of guaranty, latent defects, fraud or misrepresentation discovered after acceptance), repair damages to the Project caused by Acts of God or third parties, and maintain the Project.

Notice of Acceptance means the written notice or official order and any accompanying documentation sent to the Contractor by the Principal advising acceptance of the Tenderer’s Tender to execute the Works.

Notice of Acceptance shall have the meaning set forth in Section 3.4(b).

Notice of Acceptance means the written notification and any accompanying documentation sent to the Contractor by the Principal advising acceptance of the Respondent’s Quotation to provide the Services.