Major renovation means the renovation of a building where:
Expansion Space means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.
Tenant Work All work installed or furnished to the Premises by Tenant in connection with Tenant’s initial occupancy pursuant to Rider 2 and the Workletter.
Landlord’s Work means the work of constructing the Tenant Improvements.
Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.
Tenant Improvements Defined in Exhibit B, if any.
Tenant Improvement Work means the construction of the Tenant Improvements, together with any related work (including demolition) that is necessary to construct the Tenant Improvements.
Work space means that portion of the court’s facilities dedicated to each court reporter, including but not limited to actual space in the courtroom and any designated office space.
Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).
Base Building Work means the base building work for the Building as described in this Manual.
Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);
Renovation means altering a facility or one or more facility components in any way, including the stripping or removal of RACM from a facility component. Operations in which load-supporting structural members are wrecked or taken out are demolitions.
Tenant Improvement Allowance in the maximum amount of $200.00 per rentable square foot in the Premises, which is included in the Base Rent set forth in the Lease; and
Construction Work means any work in connection with
Base Building shall include the structural portions of the Building, the public restrooms and the Building mechanical, electrical and plumbing systems and equipment located in the internal core of the Building on the floor or floors on which the Premises are located. Tenant shall promptly provide Landlord with copies of any notices it receives regarding an alleged violation of Law. Tenant shall comply with the rules and regulations of the Building attached as Exhibit E and such other reasonable rules and regulations adopted by Landlord from time to time, including rules and regulations for the performance of Alterations (defined in Section 9).
Commercial Premises Means a place of trade or premises operated for financial gain, including but not limited to, a retirement village or a block of flats that has a common facility; a place of trade where the manufacture and production of products or produce takes place; a site where renovation, restoration and refurbishment work as described in Appendix B takes place.
this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.
Open space means undeveloped land, a naturally landscaped area, or a formal or man-made landscaped area that provides a connective link or a buffer between other resources.
Tenant Delays A "Tenant Delay" shall mean any delay in Substantial Completion of the Building as a result of any of the following: (i) Tenant's failure to complete or approve the Tenant Improvement Plans by the dates set forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction by the dates set forth in Section 5.C, (iii) changes to either the Shell Plans and Specifications or the Tenant Improvement Plans requested by Tenant which delay the progress of the work, (iv) Tenant's request for materials, components or finishes which are not available in a commercially reasonable time given the target Commencement Date, (v) Tenant's failure to make a progress payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's request for more than one (1) rebidding of the cost of all or a portion of the work, and (vii) any errors or omissions in the Tenant Improvement Plans provided by Tenant's architect. In the event Landlord believes Tenant is causing a Tenant Delay, Landlord shall notify Tenant in writing, state the action or inaction that it believes is causing the Tenant Delay, and state the date from which a Tenant Delay is being calculated. Claim of Tenant Delay shall be made within five (5) days after Landlord's discovery of the occurrence of the event giving rise to such claim. Tenant shall have the right to expedite work, at its sole cost, to minimize the effect of any Tenant Delays, to the extent it is practicable to do so. However, no Tenant Delay shall advance the Commencement Date to a date before the estimated Commencement Date of October 1, 2001. Notwithstanding anything to the contrary set forth in this Lease and regardless of the actual date the Premises are Substantially Complete (but subject to the limitation in the preceding sentence), the Commencement Date shall be deemed to be the date the Commencement Date would have occurred if no Tenant Delay had occurred as reasonably determined by Landlord. In addition, if a Tenant Delay results in an increase in the cost of the labor or materials, Tenant shall pay the cost of such increases.
residential premises means a house, building, structure, shelter, or mobile home, or portion thereof, used as a dwelling, home, residence, or living place by 1 or more human beings. “Residential premises” includes an apartment unit, a boardinghouse, a rooming house, a mobile home, a mobile home space, and a single or multiple family dwelling, but does not include a hotel, a motel, motor home, or other tourist accommodation, when used as a temporary accommodation for guests or tourists, or premises used as the principal place of residence of the owner and rented occasionally during temporary absences including vacation or sabbatical leave.
demolition work means a method to dismantle, wreck, break, pull down or knock down of a structure or part thereof by way of manual labour, machinery, or the use of explosives;
Rentable Area of the Premises The amount of square footage set forth in Section 1.01(10).
On-premises sign means a sign advertising activities conducted or maintained on the property on which it is located. The boundary of the property shall be as determined by tax rolls, deed registrations, and apparent land use delineations. If a sign consists principally of brand name or trade name advertising and the product or service advertised is only incidental to the principal activity conducted or maintained on the property, or if the sign brings rental income to the property owner or sign owner, it shall be considered the business of outdoor advertising and not an on-premises sign. On-premises sign does not include a sign on a narrow strip of land contiguous to the advertised activity, or a sign on an easement on adjacent property, when the purpose is clearly to circumvent the intent of this act.
New Building ’ means a new construction to house a complete motor vehicle as- sembly process, where that construction includes the pouring or construction of a new foundation and floor, the erection of a new frame and roof, and the instal- lation of new plumbing and electrical and other utilities;
Subleased Premises means approximately -18;961 rentable square feet on the 141h floor of the Building, as more specifically depicted on Exhibit A attached hereto and made a part hereof. The Subleased Premises include all of the Leased Premises identified in the Prime Lease.
Expansion Project has the meaning set forth in Section IV.3.a of this Agreement.