Permitted Remedies means, with respect to any securities, one or more of the following remedies:
Landlord Default shall have the meaning given such term in Article 14.
Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.
Landlord Waiver means a letter in form and substance reasonably acceptable to the Administrative Agent and executed by a landlord in respect of Inventory of a Loan Party located at any leased premises of a Loan Party pursuant to which such landlord, among other things, waives or subordinates on terms and conditions reasonably acceptable to the Administrative Agent any Lien such landlord may have in respect of such Inventory.
Landlord Personal Property Collateral Access Agreement means a Landlord Waiver and Consent Agreement substantially in the form of Exhibit K with such amendments or modifications as may be approved by Collateral Agent.
Landlord Parties means Landlord and Property Manager and their respective officers, directors, partners, shareholders, members and employees.
Major Damage means damage that in the estimation of the surveyor exceeds USD
Landlord Party or “Landlord Parties” shall mean Landlord, any affiliate of Landlord, Landlord’s managing agents for the Building, each mortgagee (if any), each ground lessor (if any), and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents or representatives. For the purposes of this Lease, the term “Tenant Party” or “Tenant Parties” shall mean Tenant, any affiliate of Tenant, any permitted subtenant or any other permitted occupant of the Premises, and each of their respective direct or indirect partners, officers, shareholders, directors, members, trustees, beneficiaries, servants, employees, principals, contractors, licensees, agents, invitees or representatives.
Landlord Liens means liens on or against the Leased Property or any payment of Rent (a) which result from any act of, or any claim against, Landlord or any owner (other than Tenant) of a direct or indirect interest in the Leased Property, or which result from any violation by Landlord of any terms of this Agreement or the Purchase Agreement, or (b) which result from liens in favor of any taxing authority by reason of any tax owed by Landlord or any fee owner of a direct or indirect interest in the Leased Property; provided, however, that "Landlord Lien" shall not include any lien resulting from any tax for which Tenant is obligated to pay or indemnify Landlord against until such time as Tenant shall have already paid to or on behalf of Landlord the tax or the required indemnity with respect to the same.
Major Tenants has the meaning ascribed to such term in Section 7.2.
Premises Building Partial Damage means if the Building of which the Premises are a part is damaged or destroyed to the extent that the cost to repair is less than fifty percent of the then replacement cost of the Building.
Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.
Remedies means actions designed to restore or preserve the complainant’s equal access to education after a respondent is found responsible. Remedies may include the same individualized services that constitute supportive measures, but need not be non-punitive or non-disciplinary, nor must they avoid burdening the respondent.
Required Percentage-Remedies shall be 66-2/3% of the aggregate Voting Rights.
Master Lease means any master lease now or hereafter entered into, in which the Healthcare Facility is aggregated with other HUD-insured healthcare facilities and leased to a Master Tenant and any amendments or joinders thereto.
Landlord means the owner, lessor or sublessor of the dwelling unit or the building of which such
Landlord Reserve means, as to each location at which a Borrower has Inventory or books and records located and as to which a Collateral Access Agreement has not been received by Agent, a reserve in an amount equal to the greater of (a) the number of months' rent for which the landlord will have, under applicable law, a Lien in the Inventory of such Borrower to secure the payment of rent or other amounts under the lease relative to such location, or (b) 3 months' rent under the lease relative to such location.
Premises Partial Damage means damage or destruction to the Premises, other than Lessee-Owned Alterations and Utility Installations, the repair cost of which damage or destruction is less than fifty percent (50%) of the then Replacement Cost (as defined in Paragraph 9.1(d)) of the Premises (excluding Lessee-Owned Alterations and Utility Installations and Trade Fixtures) immediately prior to such damage or destruction.
Leasehold Mortgagee means the holder of a Leasehold Mortgage.
Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:
Structural damage means a covered building, regardless of the date of its construction, has experienced the following.
Landlord Agreement means an agreement substantially in the form provided by Lender to Borrower or such other form as Lender may agree to accept.
Parking space leasing data means the following government data on an application for, or lease of, a parking space: residence address, home telephone number, beginning and ending work hours, place of employment, location of parking space, and work telephone number.
Tenant’s Property means Tenant's movable fixtures and movable partitions, telephone and other equipment, furniture, furnishings, decorations and other items of personal property.
Tenant means any Person leasing, subleasing or otherwise occupying any portion of the Property under a Lease or other occupancy agreement.
this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.