Work Duration Schedules Sample Clauses

Work Duration Schedules. With each quote, the Contractor agrees to furnish a work duration schedule showing the order in which the Contractor proposes to perform the work, the durations in which the Contractor is to perform the work, and the relative dates on which the Contractor contemplates starting and completing project tasks, including the acquisition of materials, fabrication, and equipment. The County may determine the level of detail and the number of tasks required to be included on the schedule. Unless otherwise specified, the schedule shall be in the form of a Xxxxx chart work duration schedule of suitable scale to indicate appropriately the percentage of work scheduled for completion. At the discretion of the County, the Contractor may be required to furnish a Critical Path Method (CPM) schedule. The purpose of the Work Duration Schedule is to ensure adequate planning, coordination, and execution of the work, and to evaluate the progress of the work. The schedule indicates the dates for starting and completing various aspects of the work including, but not limited to, on- site construction activities as well as the submittal, approval, procurement, fabrication, and delivery of major items, materials and equipment. The schedule indicates phasing of work activities as required. The schedule provides the Contractor s initial plan for the work based on its understanding of the Detailed Scope of Work, with the critical path highlighted.
Sample 1
AutoNDA by SimpleDocs

Related to Work Duration Schedules

  • Vacation Schedules (a) Employees shall submit their vacation requests to the supervisor on or before:

  • COMPLETION SCHEDULE 6.1 The proposed schedule for the completion of the Project is presented in “Attachment D” and is made a part hereof.

  • Work Schedules Workweeks and work shifts of different numbers of hours may be established by the Employer in order to meet business and customer service needs, as long as the work schedules meet federal and state laws.

  • Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.

  • Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.

  • Project Schedule Construction must begin within 30 days of the date set forth in Appendix A, Page 2, for the start of construction, or this Agreement may become null and void, at the sole discretion of the Director. However, the Recipient may apply to the Director in writing for an extension of the date to initiate construction. The Recipient shall specify the reasons for the delay in the start of construction and provide the Director with a new start of construction date. The Director will review such requests for extensions and may extend the start date, providing that the Project can be completed within a reasonable time frame.

  • Vacation Schedule 1. Vacation periods shall be fixed by the Employer to suit the requirements of his business, but as far as possible and practicable, vacations will be given during the summer months, and for employees with school-age children, during the school vacations. Vacation periods shall be unbroken unless by mutual consent between Employer and employee, or where it is impractical. Grievances relating to this Section shall be subject to the Adjustment and Arbitration Procedure in this Agreement.

  • Contract Schedule The information set forth in the Contract Schedule is true and correct.

  • Alternative Work Schedules Employees may request alternative work schedules such as a nine (9) day - 80 hour two week schedule or a four (4) day - 40 hour week schedule. Management will respond to an employee's request within 15 calendar days. Any changes from existing work schedules will be based on the needs of the service as determined by Management. Employees covered by the Fair Labor Standards Act will not be placed on alternate work schedules that mandate the payment of overtime under the Act.

  • Shift Schedules 1501 Shift schedules for a minimum of a four (4) week period shall be posted at least two (2) weeks in advance of the beginning of the scheduled period. Shifts within the minimum four (4) week period shall not be altered after posting except by mutual agreement between the nurse(s) concerned and the Employer. Requests for specific days off duty shall be submitted in writing at least two (2) weeks prior to posting and granted, if possible in the judgment of the Employer. 1502 Requests for interchanges in posted shifts or a portion thereof shall also be submitted in writing, co-signed by the nurse willing to exchange shifts with the applicant. Where reasonably possible, interchanges in posted shifts are to be completed within the posted shift schedule. It is understood that any change in shifts or days off initiated by the nurses and approved by the Employer shall not result in overtime costs to the Employer. 1503 Night shift shall be considered as the first shift of each calendar day. 1504 Master rotations for each nursing unit shall be planned by the Employer in meaningful consultation with the nurse(s) concerned. The process for meaningful consultation shall include:  Employer proposes a master rotation including the Employer established criteria and provides to Nurses concerned  Nurses are provided reasonable time to submit feedback and/or an alternate master rotation for consideration.  The amended or new master rotation is provided to Nurses for review. Nurses are provided with a reasonable time to submit feedback.  At each step of the consultation process the Union will be provided with the new or revised master rotation to ensure contract compliance.  Employer has the sole discretion to select the new master rotation and provides rationale for the selection. Master Rotations shall, unless otherwise mutually agreed between the nurse(s) concerned and the Employer, observe the conditions listed hereinafter:

Time is Money Join Law Insider Premium to draft better contracts faster.