Time to Submit the Baseline Performance Schedule Clause Samples
The 'Time to Submit the Baseline Performance Schedule' clause establishes the deadline by which a contractor or service provider must deliver an initial, comprehensive schedule outlining key project milestones and deliverables. Typically, this clause specifies a set number of days after contract commencement or notice to proceed within which the baseline schedule must be submitted for approval. By clearly defining this timeframe, the clause ensures that all parties have a shared understanding of the project's timeline from the outset, facilitating effective planning and coordination while minimizing the risk of delays due to late schedule submissions.
POPULAR SAMPLE Copied 1 times
Time to Submit the Baseline Performance Schedule. The Buyer shall prepare and submit to the Contracting Officer a finalized baseline performance schedule within seven (7) days after the Contract start date. The baseline performance schedule shall incorporate the latest revisions to all tasks and shall take into account all other work in the Buyer's facility or scheduled to arrive at the facility that directly impacts the Obsolete Vessel performance schedule. The Buyer shall include a narrative report addressing all constraints to the Obsolete Vessel performance schedule incurred as a direct result of all other work in the Buyer's facility. Upon acceptance of the finalized baseline schedule by the Contracting Officer the Buyer shall manage the project under this schedule. The baseline schedule shall be used for the development of the required reports, progressing methodology and determining progress payments if necessary. The baseline schedule shall not be altered or changed during the performance period.