Restoration The following provisions shall apply in connection with the Restoration of the Property:
Capital Account Restoration No Limited Partner shall have any obligation to restore any negative balance in its Capital Account upon liquidation of the Partnership. The General Partner shall be obligated to restore any negative balance in its Capital Account upon liquidation of its interest in the Partnership by the end of the taxable year of the Partnership during which such liquidation occurs, or, if later, within 90 days after the date of such liquidation.
Tenant Improvement Plans Tenant, at Tenant's sole cost and expense, shall retain an interior architect ("Architect") to prepare plans and outline specifications to be attached as Exhibit "C" ("Tenant Improvement Plans and Specifications") with respect to the construction of initial interior improvements to the Premises ("Tenant Improvements"). The Tenant Improvement Plans and Specifications shall be completed for all aspects of the work (either in one package or in phases as provided below) by June 30, 2001 with all detail necessary for submittal to the city, within three (3) days thereafter, for issuance of building permits and for construction, and shall include any information required by the relevant agencies regarding Tenant's use of Hazardous Materials if applicable. The Tenant Improvements shall: (i) be reasonably compatible with (and not damaging to) the structural, mechanical, electrical, plumbing and other systems of the Building, (ii) not materially adversely impact (in Landlord's reasonable judgment) the exterior appearance or operations of the Building, the currently existing interior improvements in the Building, or the appearance or operations of the public areas of the Building and (iii) comply with all any law, statute, ordinance, order, rule, regulation or requirement of any governmental or quasi-governmental authority. All Tenant Improvements shall be subject to Landlord's reasonable approval, which shall not be unreasonably withheld or delayed beyond five (5) business days following receipt of Tenant's Plans and Specifications, provided the above conditions are met. Landlord's failure to approve, or reasonably disapprove, the Tenant Improvement Plans and Specifications (or revised Plans and Specifications) within five (5) business days following Landlord's receipt thereof shall be deemed Landlord's approval. The Tenant Improvement Plans and Specifications shall include all detail required by the City of Santa Clara necessary to obtain a Certificate of Occupancy. Construction ox xxx Tenant Improvements shall be performed by a general contractor ("General Contractor") selected by Tenant, subject to Landlord's reasonable approval. Tenant shall not be required to use union labor as a condition of receiving Landlord's approval hereunder. The Tenant Improvement Plans and Specifications shall be prepared in sufficient detail to allow General Contractor to construct the Tenant Improvements. The Tenant shall contract directly with General Contractor for construction of the Tenant Improvements and shall cause the General Contractor to construct the Tenant Improvements in accordance with all Tenant Improvement Plans and Specifications. Tenant shall have no obligation to remove the Tenant Improvements at the expiration or earlier termination of the Lease. The Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall not be removed or altered by Tenant without the prior written consent of Landlord as provided in Section 7. Tenant shall have the right to depreciate and claim and collect any investment tax credits in the Tenant Improvements during the Lease Term. Upon expiration of the Lease Term or any earlier termination of the Lease, the Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall become the property of Landlord and shall remain upon and be surrendered with the Premises, and title thereto shall automatically vest in Landlord without any payment therefore.
Outage Restoration If an outage on the Attachment Facilities or System Upgrade Facilities or System Deliverability Upgrades of the Connecting Transmission Owner or Developer adversely affects the other Party’s operations or facilities, the Party that owns the facility that is out of service shall use Reasonable Efforts to promptly restore such facility(ies) to a normal operating condition consistent with the nature of the outage. The Party that owns the facility that is out of service shall provide the other Party and NYISO, to the extent such information is known, information on the nature of the Emergency State, an estimated time of restoration, and any corrective actions required. Initial verbal notice shall be followed up as soon as practicable with written notice explaining the nature of the outage.
Notice; Restoration If the Property is damaged or destroyed, in whole or in part, by fire or other casualty (a “Casualty”), Borrower shall give prompt notice thereof to Lender. Following the occurrence of a Casualty, Borrower, regardless of whether insurance proceeds are available, shall promptly proceed to restore, repair, replace or rebuild the Property in accordance with Legal Requirements to be of at least equal value and of substantially the same character as prior to such damage or destruction.
Initial Improvements Landlord shall cause to be constructed, in a good workmanlike manner, the improvements (the “Initial Improvements”) in the Premises in accordance with plans and specifications approved by Tenant and Landlord (the “Plans”), which approvals shall not be unreasonably withheld. The Initial Improvements shall be performed at the Landlord’s cost. Landlord shall cause the Plans to be prepared by a professional architect, and mechanical and electrical engineer(s) and based upon the space plans as shown on Appendix C-1 attached hereto using building standard finishes. Within ten (10) business days after the later to occur of (i) the mutual execution of the Lease or (ii) Tenant’s providing to Landlord the preliminary space plans for the Premises and such other information reasonably required by Landlord to commence preparation of the Plans, Landlord shall furnish the initial draft of the Plans to Tenant for Tenant’s review and approval. Tenant shall, within ten (10) days after receipt, either provide comments to such Plans or approve the same. Tenant shall be deemed to have approved such Plans if it does not timely provide comments on such Plans. If Tenant provides Landlord with comments to the initial draft of the Plans, Landlord shall provide revised Plans to Tenant incorporating Tenant’s comments within one (1) week after receipt of Tenant’s comments. Tenant shall, within five (5) business days after receipt, then either provide comments to such revised Plans or approve such Plans. Tenant shall be deemed to have approved such revised Plans if Tenant does not timely provide comments on such Plans. The process described above shall be repeated, if necessary, until the Plans have been finally approved by Tenant and Landlord; provided, however, if Landlord and Tenant cannot, despite using good faith efforts, reach agreement with respect to the Plans by June 15, 2005, then either Landlord or Tenant may terminate this Lease upon delivery of written notice to the other, whereupon (i) Landlord shall return to Tenant any prepaid Rent and (ii) the parties shall have no further rights or obligations under this Lease. Landlord hereby agrees that the Plans for the Initial Improvements shall comply with all applicable Governmental Requirements. Once the Plans have been finally approved, Landlord will promptly prepare all necessary construction drawings for the construction of the Initial Improvements. Upon the completion of such construction drawings, Landlord shall submit the same to Tenant for its approval. Tenant shall, within five (5) days after receipt, then either provide comments to such drawings or approve the same. Tenant shall be deemed to have approved such drawings if Tenant does not timely provide comments thereto. If Tenant timely provides any comments to such drawings, Landlord shall revise such drawings and resubmit the same to Tenant for its review and approval. Until such time as Landlord and Tenant mutually approve such construction drawings, the process described above shall be repeated as reasonably necessary, and both Landlord and Tenant agree to act in good faith in order to derive mutually acceptable construction drawings for the construction of the Initial Improvements. Once the Plans and all construction drawings relative thereto have been finalized and approved by Tenant and Landlord, Landlord shall promptly (i) submit the same to the appropriate governmental authorities for the issuance of all necessary building permits, and (ii) select a contractor to perform the construction of the Initial Improvements. Landlord shall use commercially reasonable efforts to cause the Initial Improvements to be substantially completed, except for mechanical adjustments or minor details of construction (“Punch List Items”), on or before July 1, 2005 (the “Intended Completion Date”), subject to Tenant Delay (as defined in Section 4 hereof) and Force Majeure.
Improvement Plans A. A professional improvement plan is a clearly articulated assistance program for a teacher whose student growth measure dimension of the evaluation is below the expected level of student growth. For the purposes of this agreement, improvement plans shall be based on the individual student growth measure level, and not for overall subjects or classes taught.
Additional Improvements Common Area Operating Expenses shall not include Real Property Taxes specified in the tax assessor's records and work sheets as being caused by additional improvements placed upon the Industrial Center by other lessees or by Lessor for the exclusive enjoyment of such other lessees. Notwithstanding Paragraph 10.1 hereof, Lessee shall, however, pay to Lessor at the time Common Area Operating Expenses are payable under Paragraph 4.2, the entirety of any increase in Real Property Taxes if assessed solely by reason of Alterations, Trade Fixtures or Utility Installations placed upon the Premises by Lessee or at Lessee's request.
Improvement Plan A written plan developed by the evaluator, utilized when a teacher received a Rating of Ineffective on his/her Evaluation or on any individual deficiency in the evaluation system.
Decommissioning The expenditure for Decommissioning will be estimated on the basis of technical studies undertaken by the Contractor, to be agreed by the National Petroleum Agency, as part of each Field Development Program and revised as necessary.
