Utilization Reports Both the Contractor and Subcontractor shall complete Quarterly Utilization Reports (or similar type documents containing the same information) and submit them to the Contracting Officer and to the Bureau within ten (10) business days at the end of each quarter. This information will be used to determine the actual dollar amount paid to Subcontractor and will also serve as a record of fulfillment of Contractor’s Small Diverse Business and Small Business Commitments. If there was no activity during the quarter, then the form must be completed by stating “No activity in this quarter.” A late fee of $100.00 per day may be assessed against the Contractor if its Utilization Report is not submitted in accordance with the schedule above.
Service Availability You understand that Service availability is at all times conditioned upon the corresponding operation and availability of the communication systems used in communicating your instructions and requests to the Credit Union. We will not be liable or have any responsibility of any kind for any loss or damage thereby incurred by you in the event of any failure or interruption of such communication systems or services resulting from the act or omission of any third party, or from any other cause not reasonably within the control of the Credit Union.
Waiver of Compliance Any failure of any of the parties to comply with any obligation, covenant, agreement or condition herein may be waived by the party entitled to the benefits thereof only by a written instrument signed by the party granting such waiver, but any such written waiver, or the failure to insist upon strict compliance with any obligation, covenant, agreement or condition herein, shall not operate as a waiver of, or estoppel with respect to, any subsequent or other failure.
Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.