Site Plan It is Licensee’s responsibility before signing this Agreement to ensure that the Site Plan correctly shows the work that Licensee intends to perform, that the Site Plan correctly shows all improvements and equipment that Licensee intends be located on the Use Areas, that the Site Plan shows no work, improvements or equipment outside the Exclusive Areas and Shared Areas properly depicted and labeled on the Boundary Plan, and that all work, improvements and equipment is encompassed within the purposes enumerated in the Standard Terms for that particular Exclusive Area or Shared Area. Any work, improvements or equipment not conforming to all the foregoing is prohibited, even if it is clearly shown on the Site Plan or discussed in the Standard Terms. Any refinement or other change to the Site Plan after Licensor executes this Agreement is void unless Licensee obtains Licensee’s approval of the change pursuant to the plans approval processes set out in the Standard Terms and pursuant to all applicable regulatory requirements.
Tenant Improvement Plans Tenant, at Tenant's sole cost and expense, shall retain an interior architect ("Architect") to prepare plans and outline specifications to be attached as Exhibit "C" ("Tenant Improvement Plans and Specifications") with respect to the construction of initial interior improvements to the Premises ("Tenant Improvements"). The Tenant Improvement Plans and Specifications shall be completed for all aspects of the work (either in one package or in phases as provided below) by June 30, 2001 with all detail necessary for submittal to the city, within three (3) days thereafter, for issuance of building permits and for construction, and shall include any information required by the relevant agencies regarding Tenant's use of Hazardous Materials if applicable. The Tenant Improvements shall: (i) be reasonably compatible with (and not damaging to) the structural, mechanical, electrical, plumbing and other systems of the Building, (ii) not materially adversely impact (in Landlord's reasonable judgment) the exterior appearance or operations of the Building, the currently existing interior improvements in the Building, or the appearance or operations of the public areas of the Building and (iii) comply with all any law, statute, ordinance, order, rule, regulation or requirement of any governmental or quasi-governmental authority. All Tenant Improvements shall be subject to Landlord's reasonable approval, which shall not be unreasonably withheld or delayed beyond five (5) business days following receipt of Tenant's Plans and Specifications, provided the above conditions are met. Landlord's failure to approve, or reasonably disapprove, the Tenant Improvement Plans and Specifications (or revised Plans and Specifications) within five (5) business days following Landlord's receipt thereof shall be deemed Landlord's approval. The Tenant Improvement Plans and Specifications shall include all detail required by the City of Santa Clara necessary to obtain a Certificate of Occupancy. Construction ox xxx Tenant Improvements shall be performed by a general contractor ("General Contractor") selected by Tenant, subject to Landlord's reasonable approval. Tenant shall not be required to use union labor as a condition of receiving Landlord's approval hereunder. The Tenant Improvement Plans and Specifications shall be prepared in sufficient detail to allow General Contractor to construct the Tenant Improvements. The Tenant shall contract directly with General Contractor for construction of the Tenant Improvements and shall cause the General Contractor to construct the Tenant Improvements in accordance with all Tenant Improvement Plans and Specifications. Tenant shall have no obligation to remove the Tenant Improvements at the expiration or earlier termination of the Lease. The Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall not be removed or altered by Tenant without the prior written consent of Landlord as provided in Section 7. Tenant shall have the right to depreciate and claim and collect any investment tax credits in the Tenant Improvements during the Lease Term. Upon expiration of the Lease Term or any earlier termination of the Lease, the Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall become the property of Landlord and shall remain upon and be surrendered with the Premises, and title thereto shall automatically vest in Landlord without any payment therefore.
Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.
Punchlist Upon completion of the Performance Tests and prior to Substantial Completion, Owner and Contractor shall inspect Subproject 3, and Contractor shall prepare a proposed Punchlist of items identified as needing to be completed or corrected as a result of such inspection. Contractor shall promptly provide the proposed Punchlist to Owner for its review, together with an estimate of the time and cost necessary to complete or correct each Punchlist item. Contractor shall add to the proposed Punchlist any Punchlist items that are identified by Owner within ten (10) Days after Owner’s receipt of the proposed Punchlist from Contractor, and Contractor shall immediately initiate measures to complete or correct, as appropriate, any item on Contractor’s proposed Punchlist (including those items identified by Owner during Owner’s review) that are not of a Punchlist nature. Notwithstanding anything to the contrary in this Agreement, Contractor and Owner are not required as a condition of Substantial Completion to agree upon and identify every Punchlist item and include it on the Punchlist, but Contractor is required to complete as a condition of Substantial Completion all Work that does not meet the definition of Punchlist as provided in Section 1.1. In the event of a dispute regarding whether a specific item of Work meets the definition of Punchlist under Section 1.1, the Parties shall resolve such dispute in accordance with Section 18.1A. Owner shall provide Contractor with access to the Work after Substantial Completion sufficient to enable Contractor to complete all Punchlist items, so long as such access does not unreasonably interfere with operation of Subproject 3 after Substantial Completion or Subproject 1 or Subproject 2 after substantial completion of Subproject 1 or Subproject 2 (as applicable) under the Stage 1 EPC Agreement and subject to any reasonable security or safety requirements of Owner. Upon Contractor’s completion or correction of any items necessary to achieve Substantial Completion, as modified by any Owner additions, such Punchlist shall govern Contractor’s performance of the Punchlist items up to Final Completion. All Work on the Punchlist shall be completed by the date required for Final Completion, as specified in Section 5.3C, or Owner may, in addition to any other rights that it may have under this Agreement, complete such Punchlist Work at the expense of Contractor. In the event Owner elects to complete such Punchlist Work, Contractor shall pay Owner, within ten (10) Days after receipt of written notice from Owner, all reasonable costs and expenses incurred by Owner in performing such Punchlist Work, or, at Owner’s sole discretion, Owner may withhold or offset amounts owed to Contractor or collect on the Letter of Credit in accordance with Section 7.8 in the amount of such costs and expenses. Any Defective Work identified after agreement between the Parties of the Punchlist shall be corrected by Contractor as a Warranty item under Article 12.
Approved Working Drawings The Final Working Drawings shall be approved by Landlord (the “Approved Working Drawings”) prior to the commencement of construction of the Premises by Tenant. After approval by Landlord of the Final Working Drawings, Tenant may submit the same to the appropriate municipal authorities for all applicable building permits. Tenant hereby agrees that neither Landlord nor Landlord’s consultants shall be responsible for obtaining any building permit or certificate of occupancy for the Premises and that obtaining the same shall be Tenant’s responsibility; provided, however, that Landlord shall cooperate with Tenant in executing permit applications and performing other ministerial acts reasonably necessary to enable Tenant to obtain any such permit or certificate of occupancy. No changes, modifications or alterations in the Approved Working Drawings may be made without the prior written consent of Landlord, which consent may not be unreasonably withheld.
Tenant Improvements a. Tenant shall cause to be constructed certain tenant improvements (including those listed in Sections 7(e), 7(f) and 7(g) below) in the Additional Premises (“Tenant’s Work”) pursuant to the Work Letter attached as Exhibit E hereto (the “Work Letter”). Landlord shall provide Tenant with an improvement allowance in an amount not to exceed Nine Hundred Five Thousand Five Hundred Thirty-Five Dollars ($905,535) (based upon Forty-Five Dollars ($45) per rentable square foot) (the “TI Allowance”). The TI Allowance may be used to pay for the following costs related to Tenant’s Work: (i) construction, (ii) project oversight by Landlord (which fee shall equal three percent (3%) of the TI Allowance), (iii) space planning, architect, engineering and other related services performed by third parties unaffiliated with Tenant and (iv) building permits and other taxes, fees, charges and levies by Governmental Authorities for permits or for inspections of Tenant’s Work. In no event shall the TI Allowance be used for: (v) payments to Tenant or any affiliates of Tenant, (w) the purchase of any furniture, personal property or other non-building system equipment, (x) the cost of work that is not authorized by the Approved Plans or otherwise approved in writing by Landlord, (y) costs resulting from any default by Tenant of its obligations under the Amended Lease or (z) costs that are recoverable or reasonably recoverable by Tenant from a third party (e.g., insurers, warrantors, or tortfeasors). If the total cost of Tenant’s Work exceeds Forty-Five Dollars ($45) per rentable square foot of the Additional Premises, then Tenant shall pay the overage as and when due. Tenant shall have until December 31, 2008, to expend any unused portion of the TI Allowance, after which date Landlord’s obligation to fund such costs shall expire. Tenant shall deliver to Landlord (Y) a certificate of occupancy for the Additional Premises suitable for the permitted use and (Z) a Certificate of Substantial Completion in the form of the American Institute of Architects document G704, executed by the project architect with respect to Tenant’s Work in the Additional Premises.
Schematic Design Documents In accordance with the approved Preliminary Design and Construction Schedule and based upon approval of and comments made by the Owner regarding the Concept Design Studies, the Design Professional shall prepare and submit to the Owner Schematic Design Documents, including drawings and outline specifications. These documents shall represent a further development of the approved design concept, providing additional detail and specificity regarding the intended design solution. Typically, all such documents shall be drawn to scale, indicating materials and assemblies, as appropriate, to convey the design intent and to illustrate the Project’s basic elements, scale and relationship to the Site. All major pieces of furniture and equipment to be fixed or supplied by the CM/GC shall be illustrated to scale. (See ASTM Standard Practice E 1804-02, August 2007, Sections 6.3, 8.2 and 8.3 for guidance on information which is generally developed in Schematic Design.)
Punch List If, at any time after the Project has been Physically Completed, there shall exist any item or items requiring completion or correction, then the Developer agrees to use all reasonable diligence to complete or correct such item or items so that each conforms to the Final Plans. The parties shall make a Punch-List of the items requiring completion or correction (the "Punch List"). Each item on the Punch-List shall be assigned a reasonable value based upon the reasonable cost of completion or correction of the same or such other value as may be required by the Owner's lender ("Punch-List Amount"). The Developer shall give its written undertaking to complete each such item within forty-five (45) days (or such other period of time as is mutually agreed upon by the parties).
Plans and Specifications Tenant shall be solely responsible for the preparation of the final architectural, electrical and mechanical construction drawings, plans and specifications (called “plans”) necessary for Tenant to construct the Premises for Tenant’s occupancy, which plans shall be subject to approval by Landlord’s architect and engineers and shall comply with their reasonable requirements to avoid aesthetic or other conflicts with the design and function of the balance of the Building. Landlord’s approval is solely given for the benefit of Landlord, and neither Tenant nor any third party shall have the right to rely upon Landlord’s approval of Tenant’s plans for any purpose whatsoever other than that Landlord does not object thereto under this Lease. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan submission by Tenant within 8 business days after Landlord’s receipt thereof. If Landlord fails to respond to any such submission within such 8 business day period, which failure continues for more than 2 business days after Tenant gives Landlord a written notice (the “Deemed Approved Notice”) advising Landlord that such plan submission shall be deemed approved within 2 business days of Landlord’s receipt of the Deemed Approved Notice, then such plan submission shall be deemed approved hereunder. The Deemed Approved Notice shall, in order to be effective, contain on the first page thereof, in a font at least twice as large as the font of any other text contained in such notice, a legend substantially as follows: “FAILURE TO RESPOND TO THIS NOTICE WITHIN TWO (2) BUSINESS DAYS AFTER RECEIPT HEREOF SHALL CONSTITUTE LANDLORD’S APPROVAL OF SUBMITTED PLANS.” In the event Landlord’s architect’s or engineers’ approval of Tenant’s plans is withheld or conditioned, Landlord shall send prompt written notification thereof to Tenant and include a reasonably detailed statement identifying the reasons for such refusal or condition, and Tenant shall promptly have the plans revised by its architect to incorporate all reasonable objections and conditions presented by Landlord and shall resubmit such plans to Landlord. Landlord’s architects and engineers shall respond (with approval or disapproval) to any plan re-submission by Tenant within 8 business days after Landlord’s receipt thereof. Such process shall be followed until the plans shall have been approved by Landlord’s architect and engineers without unreasonable objection or condition. Without limiting the foregoing, Tenant shall be responsible for all elements of the design of Tenant’s plans (including, without limitation, compliance with law, functionality of design, the structural integrity of the design, the configuration of the Premises and the placement of Tenant’s furniture, appliances and equipment), and Landlord’s approval of Tenant’s plans shall in no event relieve Tenant of the responsibility for such design. Tenant agrees it shall be solely responsible for the timely preparation and submission of all such plans and for all elements of the design of such plans and for all costs related thereto. (The word “architect” as used in this Section 3.2 shall include an interior designer or space planner.) Tenant shall reimburse Landlord Landlord’s reasonable out-of-pocket expense incurred in connection with the review of Tenant’s plans.
Space Plan Tenant or Tenant’s Architect shall prepare a proposed space plan for the Tenant Improvements in the Premises which shall include a layout and designation of all partitioning, intended use for such space and equipment to be contained therein (the “Space Plan”) and shall deliver the proposed Space Plan to Landlord with a request for Landlord’s approval. Landlord shall approve or disapprove the Space Plan by written notice given to Tenant within ten (10) Business Days after receipt of the Space Plan. Landlord shall not unreasonably withhold its approval of the Space Plan, provided that, without limiting the generality of the foregoing, Landlord shall be entitled to withhold its consent to the Space Plan if, in Landlord’s good faith judgment, any one or more of the following conditions exist: (a) the proposed Tenant Improvements will adversely affect the exterior appearance of the Building; (b) the proposed Tenant Improvements may impair the structural strength of the Building, affect any of the Base Building Systems or adversely affect the value of the Building; or (c) the proposed Tenant Improvement Work would trigger the necessity under Applicable Laws or otherwise for work to be performed outside the Premises. If Tenant’s proposed interior partitioning or other aspects of the Tenant Improvement Work will, in Landlord’s good faith judgment, require changes or alterations in the Base Building Systems located outside of the Premises, and Landlord approves such changes or alterations, such changes or alterations shall be made at Tenant’s expense. If Landlord disapproves the Space Plan, Landlord shall return the Space Plan to Tenant with a statement of Landlord’s reasons for disapproval, or specifying any required corrections and/or revisions. Landlord shall approve or disapprove of any revisions to the Space Plan by written notice given to Tenant within five (5) Business Days after receipt of such revisions. This procedure shall be repeated until Landlord approves the Space Plan (as so approved, the “Approved Space Plan”).
