Project Goals The schedule, budget, physical, technical and other objectives for the Project shall be defined.
Milestones Subject to the provisions of the SGIP, the Parties shall agree on milestones for which each Party is responsible and list them in Attachment 4 of this Agreement. A Party’s obligations under this provision may be extended by agreement. If a Party anticipates that it will be unable to meet a milestone for any reason other than a Force Majeure event, it shall immediately notify the other Parties of the reason(s) for not meeting the milestone and (1) propose the earliest reasonable alternate date by which it can attain this and future milestones, and (2) requesting appropriate amendments to Attachment 4. The Party affected by the failure to meet a milestone shall not unreasonably withhold agreement to such an amendment unless it will suffer significant uncompensated economic or operational harm from the delay, (1) attainment of the same milestone has previously been delayed, or (2) it has reason to believe that the delay in meeting the milestone is intentional or unwarranted notwithstanding the circumstances explained by the Party proposing the amendment.
STATEWIDE ACHIEVEMENT TESTING When CONTRACTOR is an NPS, per implementation of Senate Bill 484, CONTRACTOR shall administer all Statewide assessments within the California Assessment of Student Performance and Progress (“CAASP”), Desired Results Developmental Profile (“DRDP”), California Alternative Assessment (“CAA”), achievement and abilities tests (using LEA-authorized assessment instruments), the Fitness Gram with the exception of the English Language Proficiency Assessments for California (“ELPAC”) to be completed by the LEA, and as appropriate to the student, and mandated by XXX xxxxxxxx to LEA and state and federal guidelines. CONTRACTOR is subject to the alternative accountability system developed pursuant to Education Code section 52052, in the same manner as public schools. Each LEA student placed with CONTRACTOR by the LEA shall be tested by qualified staff of CONTRACTOR in accordance with that accountability program. XXX shall provide test administration training to CONTRACTOR’S qualified staff. CONTRACTOR shall attend LEA test training and comply with completion of all coding requirements as required by XXX.
Development Milestones In addition to its obligations under Paragraph 7.1, LICENSEE specifically commits to achieving the following development milestones in its diligence activities under this AGREEMENT: (a) (b).
Performance Measures and Metrics This section outlines the performance measures and metrics upon which service under this SLA will be assessed. Shared Service Centers and Customers will negotiate the performance metric, frequency, customer and provider service responsibilities associated with each performance measure. Measurements of the Port of Seattle activities are critical to improving services and are the basis for cost recovery for services provided. The Port of Seattle and The Northwest Seaport Alliance have identified activities critical to meeting The NWSA’s business requirements and have agreed upon how these activities will be assessed.
Contract Goals A. For purposes of this procurement, OGS conducted a comprehensive search and determined that the Contract does not offer sufficient opportunities to set goals for participation by MWBEs as subcontractors, service providers, or suppliers to Contractor. Contractor is, however, encouraged to make every good faith effort to promote and assist the participation of MWBEs on this Contract for the provision of services and materials. The directory of New York State Certified MWBEs can be viewed at: xxxxx://xx.xxxxxxxxxxxxxx.xxx/FrontEnd/VendorSearchPublic.asp?TN=ny&XID=2528. Additionally, following Contract execution, Contractor is encouraged to contact the Division of Minority and Women’s Business Development ((000) 000-0000; (000) 000-0000; or (000) 000-0000) to discuss additional methods of maximizing participation by MWBEs on the Contract.
Goals Goals define availability, performance and other objectives of Service provisioning and delivery. Goals do not include remedies and failure to meet any Service Goal does not entitle Customer to a Service credit.
Program Goals CalHFA MAC envisions that these monies would be used to complement other federal or lender programs designed specifically to stabilize communities by providing assistance to homeowners who have suffered a financial hardship and as a result are no longer financially able to afford their first-lien mortgage loan payments or their Property Expenses when associated with a Federal Housing Administration (“FHA”) Home Equity Conversion Mortgages (“HECM”) loan, only.
Metrics The DISTRICT and PARTNER will partake in monthly coordination meetings at mutually agreed upon times and dates to discuss the progress of the program Scope of Work. DISTRICT and PARTNER will also mutually establish criteria and process for ongoing program assessment/evaluation such as, but not limited to the DISTRICT’s assessment metrics and other state metrics [(Measures of Academic Progress – English, SBAC – 11th grade, Redesignation Rates, mutually developed rubric score/s, student attendance, and Social Emotional Learning (SEL) data)]. The DISTRICT and PARTNER will also engage in annual review of program content to ensure standards alignment that comply with DISTRICT approved coursework. The PARTNER will provide their impact data based upon these metrics.
Targets a) Seller’s supplier diversity spending target for Work supporting the construction of the Project prior to the Commercial Operation Date is ____ percent (___%) as measured relative to Seller’s total expenditures on construction of the Project prior to the Commercial Operation Date, and;
