Infringement Indemnification If notified promptly in writing of any judicial action brought against City based on an allegation that City’s use of the Licensed Software infringes a patent, copyright, or any right of a third party or constitutes misuse or misappropriation of a trade secret or any other right in intellectual property (Infringement), Contractor will hold City harmless and defend such action at its own expense. Contractor will pay the costs and damages awarded in any such action or the cost of settling such action, provided that Contractor shall have sole control of the defense of any such action and all negotiations or its settlement or compromise. If notified promptly in writing of any informal claim (other than a judicial action) brought against City based on an allegation that City’s use of the Licensed Software constitutes Infringement, Contractor will pay the costs associated with resolving such claim and will pay the settlement amount (if any), provided that Contractor shall have sole control of the resolution of any such claim and all negotiations for its settlement. In the event a final injunction is obtained against City’s use of the Licensed Software by reason of Infringement, or in Contractor’s opinion City’s use of the Licensed Software is likely to become the subject of Infringement, Contractor may at its option and expense: (a) procure for City the right to continue to use the Licensed Software as contemplated hereunder, (b) replace the Licensed Software with a non-infringing, functionally equivalent substitute Licensed Software, or (c) suitably modify the Licensed Software to make its use hereunder non-infringing while retaining functional equivalency to the unmodified version of the Licensed Software. If none of these options is reasonably available to Contractor, then the Agreement may be terminated at the option of either Party hereto and Contractor shall refund to City all amounts paid under this Agreement for the license of such infringing Licensed Software. Any unauthorized modification or attempted modification of the Licensed Software by City or any failure by City to implement any improvements or updates to the Licensed Software, as supplied by Contractor, shall void this indemnity unless City has obtained prior written authorization from Contractor permitting such modification, attempted modification or failure to implement. Contractor shall have no liability for any claim of Infringement based on City’s use or combination of the Licensed Software with products or data of the type for which the Licensed Software was neither designed nor intended to be used.
Indemnification by Supplier Supplier indemnifies and agrees to hold Distributor harmless from and against any and all claims, demands or actions and costs, liabilities, or losses arising out of (a) any actual or alleged death or injury to any person or damage to any tangible property resulting or claimed to result wholly from (i) any actual or alleged defect in the Product, or (ii) any statement or misstatement contained in the documentation and marketing materials provided by Supplier; or (b) arising out of any breach of this Agreement by Supplier.
Infringement Indemnity Except as specifically provided below, Ricoh will indemnify, defend and hold Subscriber harmless from and against any and all liabilities, damages, costs and expenses (including reasonable attorneys fees) incurred by Subscriber arising from a third party claim that the Services or Application, as delivered by Ricoh and used within the scope of this Agreement, infringe any existing domestic patent, copyright or trademark, but only if, (i) Subscriber notifies Ricoh in writing within thirty (30) days of any such claim, (ii) Ricoh shall have full control of the defense and all related settlement negotiations, and (iii) Subscriber shall provide Ricoh with assistance, information and authority necessary to perform the above. Notwithstanding the foregoing, Ricoh shall have no indemnity obligation for any claim relating to (i) any software of third parties, including without limitation, any embedded open source or similar software, (ii) any modifications to the Services or Application made by any entity other than Ricoh, (iii) combination or use of the Services or Application with other products, (iv) use of an outdated version of the Ancillary Software when Ricoh has made available an updated version that does not infringe, or (v) any addition, change or modification of the functionality of the Services or Application made at Subscriber’s request, if such claim would not have arisen but for such functionality. In the event of an infringement claim, if it is commercially reasonable to do so, and at its option, Ricoh will either obtain the right for Subscriber to use the Services or will modify the Services to make them non-infringing, and failing these options, Ricoh may terminate the license and Subscriber will return any Ancillary Software. THE REMEDIES ABOVE ARE THE SOLE AND EXCLUSIVE REMEDIES FOR RICOH’S BREACH OF ANY INTELLECTUAL PROPERTY WARRANTY CONTAINED IN THIS AGREEMENT OR IMPOSED OR IMPLIED BY LAW.
Indemnification by Licensor Licensor shall defend, indemnify and hold harmless Licensee and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensee Parties”) from and against any claim, suit, demand or action (“Action”), and any and all direct losses suffered or incurred by Licensee in connection with any third party claims (a) arising out of or resulting from any breach by Licensor of any provision of this Agreement, or (b) that Licensee’s use of the Licensed Software infringes on any intellectual property rights of such third party, provided, however, that Licensee’s use is consistent with the terms of this Agreement and that the Action is not caused by the use of the Licensed Software or any component thereof in combination with any other system, equipment or Software where but for such use, the Action for infringement would not lie. Licensor’s obligation to indemnify Licensee shall be conditioned on (a) Licensee’s provision to Licensor of prompt notice of such an Action (except where any delay does not materially prejudice Licensor); (b) Licensee’s reasonable cooperation with Licensor in the defense and settlement of such an Action at Licensor’s cost; and (c) Licensor having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensor may not settle any Action in a manner that adversely affects Licensee without Licensee’s prior written consent, not to be unreasonably withheld or delayed).
Indemnification by Licensee Licensee shall defend, indemnify and hold harmless Licensor and its Affiliates, and their respective officers, directors, employees, agents, shareholders, successors and assigns, (collectively, the “Licensor Parties”) from and against any Action, and any and all direct losses suffered or incurred by Licensor in connection with any third party claims (a) arising out of or resulting from any breach by Licensee of any provision of this Agreement, (b) regarding the Content (other than Licensed Content) of the websites associated with Licensed Domain Names, or (c) regarding any Content that was subject to a request for removal by a Governmental Authority, even if Licensee removes such Content within the time period proscribed by the Governmental Authority, provided that, in all cases, Licensee shall not be liable for any direct losses suffered or incurred by Licensor as a result of Licensor’s failure to provide Licensee with a reasonable period of time to remove Content in cases where (i) the basis or nature of the offense has not previously been identified by any Governmental Authority as offensive or inappropriate and (ii) Licensee has not also received notice from the Governmental Authority. Licensee’s obligation to indemnify Licensor shall be conditioned on (x) Licensor’s provision to Licensee of prompt notice of such an Action (except where any delay does not materially prejudice Licensee); (y) Licensor’s reasonable cooperation with Licensee in the defense and settlement of such an Action at Licensee’s cost; and (z) Licensee having exclusive control of the defense, settlement and/or compromise of such an Action (provided that Licensee may not settle any Action in a manner that adversely affects Licensor without Licensor’s prior written consent, not to be unreasonably withheld or delayed).
Indemnification; Third Party Claims (a) The Special Servicer and any Affiliate, director, officer, employee, member, manager or agent of the Special Servicer (the “Special Servicer Indemnified Parties”) shall be indemnified and held harmless out of the proceeds of the Mortgage Loans, any Serviced Companion Loans and any B Notes (including REO Loans), against any and all claims, losses, penalties, fines, forfeitures, legal fees and related costs, judgments and any other costs, liabilities, fees and expenses (“Special Servicer Losses”) incurred in connection with any legal action relating to (i) this Agreement, any Mortgage Loans, any Serviced Companion Loans, any B Notes, any REO Property or the Certificates or any exercise of any right under this Agreement reasonably requiring the use of counsel or the incurring of expenses and (ii) any action properly taken by the Special Servicer in accordance with this Agreement based on an instruction delivered in writing to the Special Servicer by the Trustee, the Controlling Class Representative or the Master Servicer pursuant to any provision of this Agreement, and the Special Servicer and each of its Affiliates, directors, officers, employees, members, managers and agents shall be entitled to indemnification from the Trust for any loss, liability or expense (including attorneys’ fees) incurred in connection with the provision by the Special Servicer of any information included by the Special Servicer in the report required to be provided by the Special Servicer pursuant to this Agreement, in each case other than any loss, liability or expense: (A) specifically required to be borne by the party seeking indemnification, without right of reimbursement pursuant to the terms of this Agreement; (B) which constitutes a Servicing Advance that is otherwise reimbursable under this Agreement; (C) incurred in connection with any legal action or claim against the party seeking indemnification, resulting from any breach on the part of that party of a representation or warranty made in this Agreement; or (D) incurred in connection with any legal action or claim against the party seeking indemnification, resulting from any willful misfeasance, bad faith or negligence on the part of that party in the performance of its obligations or duties under this Agreement or negligent disregard of such obligations or duties. Except as provided in the following sentence, indemnification for Special Servicer Losses described in the preceding paragraph (including in the case of such Special Servicer Losses that relate primarily to the administration of the Trust, to any REMIC Pool or to any determination respecting the amount, payment or avoidance of any tax under the REMIC Provisions or the actual payment of any REMIC tax or expense) shall be paid out of collections on, and other proceeds of, the Mortgage Loans as a whole but not out of collections on, or other proceeds of, any Serviced Companion Loan or any B Note. In the case of any such Special Servicer Losses that do not relate primarily to the administration of the Trust, to any REMIC Pool or to any determination respecting the amount, payment or avoidance of any tax under the REMIC Provisions or the actual payment of any REMIC tax or expense:
Additional Indemnification by the Seller; Third Party Claims (a) The Seller shall indemnify any Purchaser and its present and former directors, officers, employees and agents and the Successor Servicer and its present and former directors, officers, employees and agents, and hold such parties harmless against any and all claims, losses, damages, penalties, fines, forfeitures, legal fees and expenses (including legal fees and expenses incurred in connection with the enforcement of the Seller's indemnification obligation under this Subsection 14.01) and related costs, judgments, and any other costs, fees and expenses that such parties may sustain in any way related to the failure of the Seller to perform its duties and the Interim Servicer to service the Mortgage Loans in strict compliance with the terms of this Agreement or any Reconstitution Agreement entered into pursuant to Section 13 or any breach of any of Seller's representations, warranties and covenants set forth in this Agreement. For purposes of this clause "
Indemnification of Third Party Claims The obligations and liabilities of any party to indemnify any other under this Article 6 with respect to Claims relating to third parties shall be subject to the following terms and conditions:
Indemnification by Customer Customer shall indemnify, defend and hold harmless MSIL and its affiliates from and against any loss, liability, damage, cost or expense (including attorneys' and accountants' fees and expenses incurred in the defense of any demands, claims or lawsuits) actually and reasonably incurred arising from any act, omission, conduct, or activity undertaken by MSIL on behalf of Customer, including, without limitation, any demands, claims or lawsuits initiated by a limited partner (or assignee thereof); provided that (i) MSIL has determined, in good faith, that the act, omission, conduct, or activity giving rise to the claim for indemnification was in the best interests of the Customer, and (ii) the act, omission, conduct or activity that was the basis for such loss, liability, damage, cost or expense was not the result of misconduct or negligence. Notwithstanding the foregoing, no indemnification of MSIL or its affiliates by Customer shall be permitted for any losses, liabilities or expenses arising from or out of any alleged violation of federal or state securities laws unless (i) there has been a successful adjudication on the merits of each count involving alleged securities law violations as to the particular indemnitee, or (ii) such claims have been dismissed with prejudice on the merits by a court of competent jurisdiction as to the particular indemnitee, or (iii) a court of competent jurisdiction approves a settlement of the claims against the particular indemnitee and finds that indemnification of the settlement and related costs should be made, provided with regard to such court approval, the indemnitee must apprise the court of the position of the SEC and the positions of the respective securities administrators of Massachusetts, Missouri, Tennessee and/or those other states and jurisdictions in which the plaintiffs claim that they were offered or sold Units, with respect to indemnification for securities laws violations before seeking court approval for indemnification. Furthermore, in any action or proceeding brought by a limited partner in the right of Customer to which MSIL or any affiliate thereof is a party defendant, any such person shall be indemnified only to the extent and subject to the conditions specified in the Delaware Revised Uniform Limited Partnership Act, as amended, and this Section 2. The Customer shall make advances to MSIL or its affiliates hereunder only if: (i) the demand, claim lawsuit or legal action relates to the performance of duties or services by such persons to Customer; (ii) such demand, claim lawsuit or legal action is not initiated by a limited partner; and (iii) such advances are repaid, with interest at the legal rate under Delaware law, if the person receiving such advance is ultimately found not to be entitled to indemnification hereunder.
Indemnification by Client Client shall indemnify and hold Dalmore, its affiliates and their representatives and agents harmless from, any and all actual or direct losses, liabilities, judgments, arbitration awards, settlements, damages and costs (collectively, “Losses”), resulting from or arising out of any third party suits, actions, claims, demands or similar proceedings (collectively, “Proceedings”) to the extent they are based upon (i) a breach of this Agreement by Client, (ii) the wrongful acts or omissions of Client, or (iii) the Offering.
