Damages and Fines Sample Clauses

Damages and Fines. Any damages resulting from surcharging, overflow or back-up caused by the Contractor’s operations shall be the Contractor’s responsibility. Any fines levied against the Owner resulting from a surcharge, overflow or backup caused by the Contractor shall be paid by the Contractor.
Sample 1Sample 2Sample 3See All (12)
AutoNDA by SimpleDocs
Damages and Fines. (Modifies Article 20.b of General Conditions) -Any damages resulting from surcharging, overflow, backup or permit violation caused by the Contractor’s operations shall be the Contractor’s responsibility. Any fines levied against the Owner resulting from a surcharge, overflow, backup or permit violation caused by the Contractor shall be paid by the Contractor.
Sample 1
Damages and Fines. ● If at any point during the year there is damage or loss, the student must contact his/her teacher immediately. The teacher will record the damage and allow the student to check out a temporary device if necessary. ● Any technical issue with the device must be reported immediately. Teacher will record the issue and submit a tech ticket. Again, a temporary device may be loaned to the student if necessary. ● Original power adapters will be checked out with devices to students in grades 5-8. Students are responsible for the replacement cost of adapters if they are not turned in at the end of the year. NOTE: Third-party adapters turned in will not be accepted. ● Accidental damage will be covered as follows: o 1st incident will be covered for students utilizing SRA’s Chromebook insurance program. For students not utilizing the insurance, repair/replacement costs will be the responsibility of the student. o 2nd + incident(s) will be the responsibility of the student, regardless of participation in the insurance program. ● Intentional damage will be the sole responsibility of the student. Students and parents will be charged for damage to devices that is a result of misuse or abusive handling. The charges will include parts and labor. ● All repairs will be performed by SRA’s IT services. Under no circumstances should students seek repairs through a third party. ● Snowy Range Academy will be responsible for repairing (at no charge to the student): o Computers that malfunction due to manufacturing or software defects. o Devices that suffer damage from appropriate typical wear and tear. o Any issue covered under manufacturer warranty.
Sample 1

Related to Damages and Fines

  • Damages and Costs You agree to pay for damages, lost property or extraordinary service or administrative costs you, your designated roommate or your guests cause to University residence facilities whether through accident, neglect or intent. See Appendix II for more information about assessments. All residents of a floor or unit may be assessed for cleaning, damages, lost property or extraordinary service costs where the person(s) responsible cannot be ascertained by the University but where the damages, lost property, or excessive mess were reasonably believed by Student Housing and Hospitality Services to be caused by one or more residents of a floor or unit. Where charges and costs have not been paid by the specified date, a late fee will be added. Failure to pay assessments may result in the relocation of you or other resident(s) to another floor or unit, denial of future residence assignment or eviction from residence. To appeal an assessment you must follow the written appeal procedure outlined on the assessment form. Appeals will only be considered if you are not in arrears for any other fees, charges or amounts owed to Student Housing and Hospitality Services.

  • NO LIMITATION OF LIABILITY FOR DAMAGES FOR PERSONAL INJURY OR PROPERTY DAMAGE ARE PERMITTED OR AGREED BY TIPS/ESC REGION 8. Per Texas Education Code §44.032(f), reasonable Attorney’s fees are recoverable by the prevailing party in any dispute resulting in litigation. State of Texas Franchise Tax By signature hereon, the bidder hereby certifies that he/she is not currently delinquent in the payment of any franchise taxes owed the State of Texas under Chapter 171, Tax Code.

  • Indemnity Consequential Damages and Insurance 18.1 Indemnity 18.1.1 Indemnified Party 18.1.2 Indemnifying Party 18.1.3 Indemnity Procedures 18.2 Consequential Damages 18.3 Insurance 18.3.1 18.3.2 18.3.3 18.3.4 18.3.5 18.3.6 18.3.7 18.3.8 18.3.9 18.3.10 18.3.11

  • Damages for breach of maintenance obligations 17.8.1 In the event that the Concessionaire fails to repair or rectify any defect or deficiency set forth in the Maintenance Requirements within the period specified therein, it shall be deemed to be in breach of this Agreement and the Authority shall be entitled to recover Damages, to be calculated and paid for each day of delay until the breach is cured, at the higher of (a) 0.5% (zero point five per cent) of Performance Guarantee, and (b) 0.1% (zero point one per cent) of the cost of such repair or rectification as estimated by the Independent Engineer. Recovery of such Damages shall be without prejudice to the rights of the Authority under this Agreement, including the right of Termination thereof.

  • Assignment Liability Indemnity Force Majeure Consequential Damages and Default Notwithstanding any other provision of this Agreement, the liability, indemnification and insurance provisions of the Transmission Operating Agreement (“TOA”) or other applicable operating agreements shall apply to the relationship between the System Operator and the Interconnection Transmission Owner and the liability, indemnification and insurance provisions of the Tariff apply to the relationship between the System Operator and the Interconnection Customer and between the Interconnecting Transmission Owner and the Interconnection Customer.

  • No Damages for Delay The Contractor has no claim for monetary damages for delay or hindrances to the Work from any cause, including without limitation any act or omission of the Owner.

  • Withholding for unpaid wages and liquidated damages The FHWA or the contacting agency shall upon its own action or upon written request of an authorized representative of the Department of Labor withhold or cause to be withheld, from any moneys payable on account of work performed by the contractor or subcontractor under any such contract or any other Federal contract with the same prime contractor, or any other federally-assisted contract subject to the Contract Work Hours and Safety Standards Act, which is held by the same prime contractor, such sums as may be determined to be necessary to satisfy any liabilities of such contractor or subcontractor for unpaid wages and liquidated damages as provided in the clause set forth in paragraph (2.) of this section.

  • No Damages for Delays Notwithstanding any other provision of this contract, Engineer shall not be entitled to claim or receive any compensation as a result of or arising out of any delay, hindrance, disruption, force majeure, impact or interference, foreseen or unforeseen.

  • Responsibility For Damages Or Injury The County its elected and appointed officials, officers, employees, agents and those special districts and agencies which County’s Board of Supervisors acts as the governing Board (“County Indemnitees”) shall not be answerable or accountable in any manner: for any loss or damage that may happen to the Project or any part thereof; for any loss or damage to any of the materials or other things used or employed in performing the Project; for injury to or death of any person either workers or the public; or for damage to property from any cause which might have been prevented by the Contractor, or his workers, or anyone employed by him. The Contractor shall be responsible for any liability imposed by law and for injuries to or death of any person or damage to property resulting from defects or obstructions or from any cause whatsoever during the progress of the Project or at any time before its completion and final acceptance. The Contractor shall indemnify, defend with counsel approved in writing by County and save harmless the County Indemnitees from all claims, suits or actions of every name, kind and description, brought for, or on account of, injuries to or death of any person or damage to property resulting from the construction of the Project or by or in consequence of any negligence in guarding the Project; use of improper materials in construction of the Project; or by or on account of any act or omission by the Contractor or his agents during the progress of the Work or at any time before the completion and final acceptance of the Project. In addition to any remedy authorized by law, so much of the money due the Contractor under and by virtue of the Contract as shall be considered necessary by the County may be retained by it until disposition has been made of such suits or claims for damages as aforesaid. If judgment is entered against Contractor and County by a court of competent jurisdiction because of the concurrent active negligence of County and County Indemnitees, Contractor and County agree that liability will be apportioned as determined by the court. Neither Party shall request a jury apportionment. Notwithstanding anything stated above, nothing contained herein shall relieve Contractor of any insurance requirements of obligations created elsewhere in this Contract.

  • Damages and Withholding Notwithstanding any other remedial action by the State, Contractor shall remain liable to the State or appropriate Purchasing Entity for any damages sustained by the State or Purchasing Entity in connection with any breach by Contractor, and the Purchasing Entity may withhold payment to Contractor for the purpose of mitigating the Purchasing Entity’s damages. A Purchasing Entity may withhold any amount that may be due Contractor as the Purchasing Entity deems necessary to protect itself against loss including, without limitation, loss as a result of outstanding liens and costs incurred by the Purchasing Entity in procuring from third parties replacement Work as cover.

Time is Money Join Law Insider Premium to draft better contracts faster.