COOPERATION WITH WORK OF OWNER AND OTHERS Sample Clauses

COOPERATION WITH WORK OF OWNER AND OTHERS. 3.5.1 The Owner may perform work at the Worksite directly or by Others. Any agreements with Others to perform construction or operations related to the Project shall include provisions pertaining to insurance, indemnification, waiver of subrogation, consequential damages, coordination, interference, clean up, and safety that are substantively the same as the corresponding provisions of this Agreement.
Sample 1Sample 2Sample 3See All (9)
AutoNDA by SimpleDocs
COOPERATION WITH WORK OF OWNER AND OTHERS. The Owner may perform work at the Worksite directly or by Others. Any agreements with Others to perform construction or operations related to the Project shall include provisions pertaining to insurance, indemnification, waiver of subrogation, consequential damages, coordination, interference, clean up, and safety that are substantively the same as the corresponding provisions of this Agreement. If the Owner elects to perform work at the Worksite directly or by Others, the Construction Manager and Owner shall coordinate the activities of all forces at the Worksite and agree upon fair and reasonable schedules and operational procedures for Worksite activities. The Owner shall require each separate contractor to cooperate with the Construction Manager and assist with the coordination of activities and the review of construction schedules and operations. The GMP or the Contract Time shall be equitably adjusted, as mutually agreed by the Parties, for changes made necessary by the coordination of construction activities, and the Schedule of the Work shall be revised accordingly. The Construction Manager, the Owner, and Others shall adhere to the revised Schedule of the Work. With regard to the work of the Owner and Others, the Construction Manager shall (a) proceed with the Work in a manner that does not hinder, delay, or interfere with the work of the Owner or Others or cause the work of the Owner or Others to become defective, (b) afford the Owner or Others reasonable access for introduction and storage of their materials and equipment and performance of their activities, and (c) coordinate the Construction Manager's Work with theirs. Before proceeding with any portion of the Work affected by the construction or operations of the Owner or Others, the Construction Manager shall give the Owner prompt, written notification of any defects or delays the Construction Manager discovers in or resulting from the work of the Owner or Others which will prevent the proper execution of the Work. The Construction Manager's obligations in this subsection do not create a responsibility for the work of Owner or Others but are for the purpose of facilitating the Work. If the Construction Manager does not notify the Owner of defects or delays interfering with the performance of the Work, the Construction Manager acknowledges that the work of the Owner or Others has not contributed to delays and is not defective and is acceptable for the proper execution of the Work. Following r...
Sample 1Sample 2
COOPERATION WITH WORK OF OWNER AND OTHERS. The Construction Manager shall perform the Work so as not to interrupt any operations of the Owner on the Site.
Sample 1

Related to COOPERATION WITH WORK OF OWNER AND OTHERS

  • Permits and Other Operating Rights The Company and each Subsidiary has all such valid and sufficient certificates of convenience and necessity, franchises, licenses, permits, operating rights and other authorizations from federal, state, foreign, regional, municipal and other local regulatory bodies or administrative agencies or other governmental bodies having jurisdiction over the Company or any Subsidiary or any of its properties, as are necessary for the ownership, operation and maintenance of its businesses and properties, as presently conducted and as proposed to be conducted while the Notes are outstanding, subject to exceptions and deficiencies which, individually or in the aggregate, could not reasonably be expected to have a Material Adverse Effect, and such certificates of convenience and necessity, franchises, licenses, permits, operating rights and other authorizations from federal, state, foreign, regional, municipal and other local regulatory bodies or administrative agencies or other governmental bodies having jurisdiction over the Company, any Subsidiary or any of its properties are free from restrictions or conditions which, individually or in the aggregate, could reasonably be expected to have a Material Adverse Effect, and neither the Company nor any Subsidiary is in violation of any thereof in any material respect.

  • Waiver and Other Action This Agreement may be amended, modified or supplemented only by a written instrument executed by the parties against which enforcement of the amendment, modification or supplement is sought.

  • Taxes and Other Impositions All ad valorem real property taxes, special taxes, possessory interest taxes, bonds and special lien assessments or other impositions of any kind with respect to the Project, the Project Site and the improvements thereon, charged to or imposed upon either Developer or the District or their respective interests or estates in the Project, shall at all times be paid by District. In the event any possessory interest tax is levied on Developer, its successors and assigns, by virtue of this Facilities Lease or the Site Lease, District shall pay such possessory interest tax directly, if possible, or shall reimburse Developer, its successors and assigns for the full amount thereof within forty-five (45) days after presentation of proof of payment by Developer.

  • Taxes and Other Liens Each Related Person shall pay and discharge promptly all taxes, assessments and governmental charges or levies imposed upon it or upon its income or upon any of its Property as well as all claims of any kind (including claims for labor, materials, supplies and rent) which, if unpaid, might become a Lien upon any or all of its Property; provided, however, each Related Person shall not be required to pay any such tax, assessment, charge, levy or claim if the amount, applicability or validity thereof shall currently be contested in good faith by appropriate proceedings diligently conducted by or on behalf of such Related Person and if such Related Person shall have set up reserves therefor adequate under GAAP.

  • Mechanics' and Other Liens Except for Permitted Encumbrances, the Company shall not suffer or permit any mechanics' or other Liens to be filed or to exist against the Collateral or any payments paid or payable under the Loan Documents, by reason of work, labor, services or materials supplied or claimed to have been supplied to, for or in connection with the Collateral or to the Company, the Director or anyone holding the Collateral or any part thereof through or under the Company. If any such Lien shall at any time be filed, the Company shall, within thirty (30) days after notice of the filing thereof but subject to the right to contest as herein set forth, cause the same to be discharged of record by payment, deposit, bond, order of a court of competent jurisdiction or otherwise. Notwithstanding the foregoing, the Company shall have the right, at the Company's expense and after written notice to the Director, by appropriate proceeding timely instituted and diligently prosecuted, to contest in good faith the validity or the amount of any such Lien. If, however, the Director shall notify the Company that, in the opinion of Independent Counsel, by nonpayment of any such items the lien, pledge or security interest created by this Security Agreement as to any part of the Collateral will be materially affected or the Collateral or any part thereof will be subject to imminent loss or forfeiture, the Company shall promptly cause such Lien to be discharged of record, as herein provided. Should the Company fail to cause such Lien to be discharged or to contest the validity or amount thereof, within the period aforesaid, then, the Director may, but shall be under no obligation to, discharge the same either by paying the claim or by procuring the discharge of such Lien by making a deposit or obtaining a bond, which advances if any shall be paid by the Company to the Director on demand, together with interest thereon at the Interest Rate for Advances from the date thereof, in addition to all other payments to be made by the Company pursuant to the Loan Documents and shall be subject to and secured by this Security Agreement as additional indebtedness in accordance with the provisions of Section 2.8 hereof.

  • Taxes and Other Payments 7.1. Unless otherwise specifically provided for in this Agreement, the Company shall not be liable for the payment of taxes or other payments for which the Employee is responsible as result of this Agreement or any other legal provision, and the Employee shall be personally liable for such taxes and other payments.

  • Improper and Other Payments (a) Neither the Company, any director, officer, employee thereof, nor any agent or representative of the Company nor any person acting on behalf of any of them, has made, paid or received any unlawful bribes, kickbacks or other similar payments to or from any person or authority, (b) no contributions have been made, directly or indirectly, by the Company to a domestic or foreign political party or candidate; and (c) the internal accounting controls of the Company are believed by the Company’s management to be adequate to detect any of the foregoing under current circumstances.

Time is Money Join Law Insider Premium to draft better contracts faster.