CONSTRUCTION MANAGER’S RESPONSIBILITIES Clause Samples

CONSTRUCTION MANAGER’S RESPONSIBILITIES. Construction Manager shall perform the services described in this Article. The services to be provided under Section 2.1 constitute the Preconstruction Phase services. If Owner and Construction Manager agree, after consultation with the Architect, the Construction Phase may commence before Preconstruction Phase is completed, in which case both phases shall proceed concurrently.

CONSTRUCTION MANAGER’S RESPONSIBILITIES. § 2.1 The Construction Manager shall provide the services as set forth in this Agreement. § 2.2 The Construction Manager shall perform its services consistent with the skill and care ordinarily provided by construction managers practicing in the same or similar locality under the same or similar circumstances. The Construction Manager shall perform its services as expeditiously as is consistent with such skill and care and the orderly progress of the Project. § 2.3 The Construction Manager shall provide its services in conjunction with the services of an Architect as described in AIA Document B132™–2019, Standard Form of Agreement Between Owner and Architect, Construction Manager as Adviser Edition. The Construction Manager shall not be responsible for actions taken by the Architect. § 2.4 The Construction Manager shall coordinate its services with those services provided by the Owner, the Architect, the Contractors, and the Owner’s other consultants and Separate Contractors. The Construction Manager shall be entitled to rely on, and shall not be responsible for, the accuracy and completeness of services and information furnished by the Owner, the Architect, and the Owner’s other consultants and Separate Contractors. The Construction Manager shall provide prompt written notice to the Owner if the Construction Manager becomes aware of any error, omission, or inconsistency in such services or information. § 2.5 The Construction Manager shall identify a representative authorized to act on behalf of the Construction Manager with respect to the Project. § 2.6 The Construction Manager, as soon as practicable after execution of the Agreement, shall notify the Owner in writing of the names and qualifications of its proposed key staff members. Within 14 days of receipt of the names and qualifications of the Construction Manager’s proposed key staff members, the Owner may reply to the Construction Manager in writing, stating (1) whether the Owner has reasonable objection to a proposed key staff member or (2) that the Owner requires additional time to review. Failure of the Owner to reply within the 14-day period shall constitute notice of no reasonable objection. The Construction Manager shall not staff any employees on the Project to whom the Owner has made reasonable and timely objection. The Construction Manager shall not change its key staff members without the Owner’s consent, which shall not be unreasonably withheld or delayed. § 2.7 Except with the Owner’s kn...

CONSTRUCTION MANAGER’S RESPONSIBILITIES. The Construction Manager shall perform the services described in this Article.

CONSTRUCTION MANAGER’S RESPONSIBILITIES. Other Preconstruction Phase Services (if any): None.

CONSTRUCTION MANAGER’S RESPONSIBILITIES. The Construction Manager’s Preconstruction Phase responsibilities are set forth in Sections 2.1 and 2.2. The Construction Manager’s Construction Phase responsibilities are set forth in Section 2.3. The Owner and Construction Manager may agree, in consultation with the Architect, for the Construction Phase to commence prior to completion of the Preconstruction Phase, in which case, both phases will proceed concurrently. The Construction Manager shall identify a representative authorized to act on behalf of the Construction Manager with respect to the Project which designation shall be subject to the Owner’s approval and which designation shall not be changed without the Owner’s prior written approval.

CONSTRUCTION MANAGER’S RESPONSIBILITIES. The Construction Manager shall perform the Work described in this Article or reasonably inferable therefrom as reasonably necessary to produce the intended results. The Construction Manager’s Preconstruction Phase responsibilities are set forth in Sections 3.1 and 3.2, and in the applicable provisions of A201-2017 referenced in Section 2.3.1. The Construction Manager’s Construction Phase responsibilities are set forth in Section 3.3. The Owner and Construction Manager may agree, in consultation with the Architect, for the Construction Phase to commence prior to completion of the Preconstruction Phase, in which case, both phases will proceed concurrently. The Construction Manager shall identify a representative authorized to act on behalf of the Construction Manager with respect to the Project.

CONSTRUCTION MANAGER’S RESPONSIBILITIES. The Construction Manager’s Preconstruction Phase responsibilities are set forth in Sections 3.1 and 3.2, and in the applicable provisions of A201-2017 referenced in Section 2.3.1. The Construction Manager’s Construction Phase responsibilities are set forth in Section 3.3. The Owner and Construction Manager may agree, in consultation with the Architect, for the Construction Phase to commence prior to completion of the Preconstruction Phase, in which case, both phases will proceed concurrently. The Construction Manager shall identify a representative authorized to act on behalf of the Construction Manager with respect to the Project. Construction Manager shall execute its responsibilities by following and applying at all times the highest professional, industry, construction, and technical guidelines and standards. If Owner becomes dissatisfied with the work product of or the working relationship with those individuals assigned to work on this Contract, Owner may request in writing the replacement of any or all such individuals, and Construction Manager shall grant such request.

CONSTRUCTION MANAGER’S RESPONSIBILITIES. § 2.1 The Construction Manager shall provide the services as set forth in this Agreement. § 2.2 The Construction Manager shall perform its services consistent with the skill and care ordinarily provided by construction managers practicing in the same or similar locality under the same or similar circumstances. The Construction Manager shall perform its services as expeditiously as is consistent with such skill and care and the orderly progress of the Project. § 2.3 The Construction Manager shall provide its services in conjunction with the services of the Architect. The Construction Manager shall not be responsible for actions taken by the Architect. § 2.4 The Construction Manager shall identify a representative authorized to act on behalf of the Construction Manager with respect to the Project. § 2.5 Except with the Owner’s knowledge and consent, the Construction Manager shall not engage in any activity, or accept any employment, interest or contribution that would reasonably appear to compromise the Construction Manager’s judgment with respect to this Project. § 2.6 The Construction Manager shall maintain the following insurance for the duration of this Agreement. § 2.6.1 Comprehensive General Liability with policy limits of not less than «One Million Dollars » ($ «1,000,000.00 » ) for each occurrence and in the aggregate for bodily injury and property damage. § 2.6.2 Automobile Liability covering owned and rented vehicles operated by the Construction Manager with policy limits of not less than «Five Hundred Thousand Dollars » ($ «500,000.00 » ) combined single limit and aggregate for bodily injury and property damage. § 2.6.3 The Construction Manager may use umbrella or excess liability insurance to achieve the required coverage for Comprehensive General Liability and Automobile Liability, provided that such umbrella or excess insurance results in the same type of coverage as required for the individual policies.

CONSTRUCTION MANAGER’S RESPONSIBILITIES. GENERAL RESPONSIBILITIES The Construction Manager’s responsibilities are more fully identified in Exhibit A, Construction Manager’s Designated Services and Method of Payment. The Construction Manager shall provide all labor, materials, equipment, and services necessary to complete the Work, all of which shall be provided in full accord with and reasonably inferable from the Contract Documents. Any additional facilities or areas required for construction operations or storage of materials that are outside of the areas designated in the Contract Documents shall be provided by the Construction Manager at no additional cost to the Owner. The Construction Manager shall be responsible for the supervision and coordination of the Work, including the construction means, methods, techniques, sequences, and procedures utilized, unless the Contract Documents give other specific instructions. In such case, the Construction Manager shall not be liable to the Owner for damages resulting from compliance with such instructions unless the Construction Manager recognized and failed to timely report to the Owner any error, inconsistency, omission, or unsafe practice that it discovered in the specified construction means, methods, techniques, sequences, or procedures. The Construction Manager shall perform Work only within locations allowed by the Contract Documents, Laws, and applicable permits.