Commencement Delays Sample Clauses

Commencement Delays. Subject to Article 4, the Commencement Date, Rent and Tenant’s other obligations shall be postponed to the extent Tenant is not reasonably able to occupy the Premises because Landlord fails, by the Commencement Date set forth in Article I, to: (i) deliver possession of the Premises, and (ii) substantially complete any improvements to the Premises required to be performed by Landlord under this Lease, except to the extent that Tenant, its space planners, architects, contractors, agents or employees cause such failure. If such failure occurs with respect to a portion of the Premises, the Commencement Date, Rent and Tenant’s other obligations shall be so postponed with respect to such portion (and fairly prorated based on the rentable square footage involved). If the Commencement Date is postponed pursuant to the foregoing provisions for a ninety (90) day initial grace period, Tenant shall have the right to terminate this Lease by notice to Landlord given within ten (10) days thereafter, subject to Landlord’s right to cure as provided in Article 21. Any such delay in the Commencement Date shall not subject Landlord to liability for loss or damage resulting therefrom, and Tenant’s sole recourse with respect thereto shall be the postponement of Rent and other obligations and right to terminate this Lease described herein,
Sample 1Sample 2See All (6)
AutoNDA by SimpleDocs
Commencement Delays. The Commencement Date, Rent and Xxxxxx’s other obligations shall be postponed to the extent Tenant is unable to occupy the Premises because Landlord fails: (i) to Substantially Complete the Landlord’s Work required to be performed by Landlord under this Lease, or (ii) to deliver possession of the Premises for any other reason, including holding over by prior occupants, except to the extent that Tenant, its contractors, agents or employees cause either such failures. If Landlord so fails for a ninety (90) day initial grace period (provided that such period shall be equitably extended for any delays caused by Tenant, its agents, contractors, or employees), Tenant shall, as its sole remedy, have the right to terminate this Lease by written notice within ten (10) days (—provided that upon any such termination, Landlord shall promptly refund to Tenant the Security Deposit). Any such delay in the Commencement Date shall not subject Landlord to liability for loss or damage resulting therefrom, and Xxxxxx’s sole recourse with respect thereto shall be the postponement of Rent or termination of the Lease as aforesaid.
Sample 1Sample 2
Commencement Delays. The Commencement Date, Rent and Tenant's other obligations shall be postponed to the extent Tenant is unable to occupy the Premises because Landlord fails to deliver possession of the Premises for any reason, including holding over by prior occupants, except to the extent that Tenant, its contractors, agents or employees in any way contribute to such failure. If such event occurs with respect to a portion of the Premises, the Commencement Date, Rent and Tenant's other obligations shall be so postponed with respect to such portion (and fairly prorated based on the rentable square footage involved). If Landlord so fails for a one hundred and eighty (180) day initial grace period, Tenant shall have the right to terminate this Lease by notice within ten (10) days thereafter, subject to Landlord's right to cure as provided in Article 21. Any such delay in the Commencement Date shall not subject Landlord to liability for loss or damage resulting therefrom, and Tenant's sole recourse with respect thereto shall be the postponement of Rent and other obligations and right to terminate this Lease described herein.
Sample 1
Commencement Delays. The Commencement Date, Rent and Tenant’s other obligations shall be postponed to the extent Tenant is unable to occupy the Premises because Landlord fails to substantially complete any improvements to the Premises and deliver possession of the Premises to Tenant to the extent due to a delay solely caused by Landlord or a force majeure event, including holding over by prior occupants. To the extent Landlord fails to substantially complete any improvements to the Premises and deliver possession of the Premises to Tenant due to a Tenant Delay (as defined in Exhibit D), the Commencement Date, Rent and Tenant’s other obligations shall not be postponed. Any delay in the Commencement Date shall not subject Landlord to liability for loss or damage resulting therefrom, and, except as otherwise expressly provided in this Section 3.0 below, Tenant’s sole recourse with respect thereto shall be the postponement of Rent and other obligations. If Landlord fails to deliver possession of the Premises with the Improvements substantially complete on or before the Required Completion Date (defined below), Landlord will grant to Tenant a credit
Sample 1Sample 2
Commencement Delays. The Commencement Date, Rent and Tenant’s other obligations shall be postponed to the extent Tenant is unable to occupy the Premises because Landlord fails to deliver possession of the Premises for any other reason, including holding over by prior occupants. If Landlord so fails for a ninety (90) day initial grace period, Tenant shall have the right to terminate this Lease by notice within ten (10) days. Any such delay in the Commencement Date shall not subject Landlord to liability for loss or damage resulting therefrom, and Tenant’s sole recourse with respect thereto shall be the postponement of Rent or termination of this Lease in accordance with the preceding sentence.
Sample 1
Commencement Delays. The Commencement Date, Rent and Subtenant's other obligations shall be postponed to the extent Subtenant is unable to occupy the Premises because Landlord fails: (i) to substantially complete any improvements to the Premises required to be performed by Landlord under this Sublease or (ii) to deliver possession of the Premises for any other reason, except to the extent that Subtenant, its contractors, agents or employees in any way contribute to either such failures.
Sample 1

Related to Commencement Delays

  • Payment Delay Notwithstanding any other terms of this Agreement, no payments will be made to CONTRACTOR until COUNTY is satisfied that work of such value has been rendered pursuant to this Agreement. However, COUNTY will not unreasonably withhold payment and, if a dispute exists, the withheld payment shall be proportional only to the item in dispute.

  • Tenant Delays A "Tenant Delay” shall be defined as any delay in the design, permitting or performance of the Base Building Work to the extent that such delay is actually caused by any act or, where there is a duty to act under this Lease, any failure to act by Tenant or Tenant's contractors, architects, engineers, or anyone else engaged by or on behalf of Tenant in connection with the construction of the Tenant Improvement Work as set forth in this Article III (including, without limitation, any delays resulting from the Approved Tenant Finishes under Section 3.l(C) above) and disclosed to Tenant as hereinafter provided. Notwithstanding the foregoing, in no event shall any delays in the completion of the Base Building Work caused by Tenant’s use of non-union labor constitute a Tenant Delay hereunder. Notwithstanding the foregoing, no event shall be deemed a Tenant Delay unless and until Landlord has given Tenant written notice (the "Tenant Delay Notice") advising Tenant: (x) that a Tenant Delay is occurring and setting forth Landlord's good faith estimate as to the likely length of such Tenant Delay; (y) of the basis on which Landlord has determined that a Tenant Delay is occurring; and (z) the actions which Landlord believes that Tenant must take to eliminate such Tenant Delay. No event shall be deemed to be a Tenant Delay unless and until Tenant has failed to rectify the situation causing the Tenant Delay within forty-eight (48) hours after Tenant's receipt of the Tenant Delay Notice (which for the purposes of determining receipt may be delivered by hand to Tenant's Construction Representative, with copies to follow to Tenant at the notice address set forth in Section 1.2 of this Lease within five (5) days thereafter); provided, however, that if Tenant shall fail to eliminate the delay within the aforesaid 48-hour period, then the 48-hour cure period shall be included in the period of time charged to Tenant pursuant to such Tenant Delay Notice (it being understood and agreed that if Tenant shall in fact eliminate the Tenant Delay within the 48-hour cure period, no Tenant Delay shall be deemed to have occurred for the purposes of this Article III). In addition, any delay to the extent caused by (i) Landlord Delay or (ii) subject to the limitations of subsection (D) below, Tenant's Force Majeure (as defined in said subsection (D)) shall not constitute Tenant Delay. Tenant covenants that no Tenant Delay shall delay commencement of the Term or the obligation to pay Annual Fixed Rent or Additional Rent. The Delivery Dates and/or the date of substantial completion of the Base Building Work, as applicable, shall be deemed to have occurred as of the date when such Delivery Dates and/or date of substantial completion of the Base Building Work, as applicable, would have occurred but for any Tenant Delays, as determined by Landlord in the exercise of its good faith business judgment (it being understood and agreed that the foregoing shall not be construed so as to relieve Landlord of its obligation to actually complete the Base Building Work, notwithstanding the fact that substantial completion may have been deemed to have occurred prior to actual completion as the result of Tenant Delays).

  • Tenant Delay If substantial completion of the Tenant Improvements, Warm Shell Improvements or Base Building is delayed due to any of the following (collectively, "Tenant Delays"), then the Delivery Date and/or Commencement Date, as applicable, shall be adjusted to reflect what the substantial completion date would have been if there had been no delay: (i) Tenant's failure to timely submit any items required by this Work Letter, including, without limitation, Tenant's Plans; (ii) Tenant Modifications; (iii) Tenant's failure to comply with Landlord's contractor's schedule; (iv) Tenant's or Tenant's Contractor's failure to comply with Paragraph 8, (v) Tenant's requested changes to the Tenant's Plans after they are approved by Landlord; (vi) Tenant's request for materials, finishes or installations which require longer than thirty (30) days to complete; (vii) delays caused by Tenant in construction of the Warm Shell Improvements or the Tenant Improvements; or (viii) any other event expressly constituting "Tenant Delay" pursuant to any provision of this Work Letter. Landlord shall give Tenant at least five (5) days prior notice if Landlord becomes aware that Tenant is in danger of causing a Tenant Delay, and if Tenant takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Delivery Date or Commencement Date shall be made on account of such Tenant Delay; provided, however, that if such delay was not reasonably foreseeable by Landlord, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Landlord becomes aware of such delay or potential delay; and provided further, that no such notice shall be required if Tenant Delay results from Tenant's failure to perform any obligation within a specific date or time period (including, without limitation, any delay in delivery of Tenant's space plan or Working Drawings or non-compliance with Landlord's contractor's schedule), or from schedule changes resulting from Tenant Modifications of which Tenant is advised by Landlord's architect or contractor as provided in Paragraph 4, or from causes that, due to the parties' relative positions with respect to the construction process, are more likely to be foreseeable by Tenant than by Landlord.

  • Rent Commencement Date The "Rent Commencement Date" shall be the date that Tenant first uses the Premises or any portion thereof for any purpose permitted under this lease. In the event this lease pertains to a building or building interior finish to be constructed, the "Rent Commencement Date" shall be the date upon which the buildings and other improvements erected and to be erected upon the premises shall have been substantially completed in accordance with the plans and specifications described on Exhibit "C" attached hereto and incorporated herein by reference, provided however, that if Landlord shall be delayed in such substantial completion as a result of: (i) Tenant's failure to agree to plans, specifications, and cost estimates, within a reasonable period of time; (ii) Tenant's request for materials, finishes or installations other than Landlord's standard; (iii) Tenant's changes in plans: the commencement date and the payment of rent hereunder shall be accelerated by the number of days of such delay, and provided further that if Landlord cannot substantially complete the premises as a result of any events (i) through (iii) above, Landlord may as its election complete so much of Landlord's work as may be practical under the circumstances and, by written notice to Tenant, establish the commencement date as the date of such partial completion, subject to any applicable accelerations due to delays resulting from events (i) through (iii) above. Taking possession by Tenant shall be deemed conclusively to establish that said buildings and other improvements have been completed in accordance with the plans and specifications and that the premises are in good and satisfactory condition, as of when possession was so taken. Tenant acknowledges that no representations as to the repair of the premises have been made by Landlord, unless such are expressly set forth in the lease. After such "Rent Commencement Date" Tenant shall, upon demand, execute and deliver to Landlord a letter of acceptance of delivery of the premises. In the event of any dispute as to substantial completion of work performed, execute or required to be performed by Landlord, the certificate of Landlord's architect or general contractor shall be conclusive.

  • Force Majeure Delays In any case where either party hereto is required to do any act (other than the payment of money), delays caused by or resulting from Acts of God or Nature, war, civil commotion, fire, flood or other casualty, labor difficulties, shortages of labor or materials or equipment, government regulations, delay by government or regulatory agencies with respect to approval or permit process, unusually severe weather, or other causes beyond such party’s reasonable control the time during which act shall be completed, shall be deemed to be extended by the period of such delay, whether such time be designated by a fixed date, a fixed time or “a reasonable time.”

  • Commencement Date The Subcontractor shall be permitted to begin the Services on ______________________, 20____ (“Commencement Date”).

  • Commencement of Work Engineer shall not commence any field work under this Contract until he/she/it has obtained all required insurance and such insurance has been approved by County. As further set out below, Engineer shall not allow any subcontractor/subconsultant(s) to commence work to be performed in connection with this Contract until all required insurance has been obtained and approved and such approval shall not be unreasonably withheld. Approval of the insurance by County shall not relieve or decrease the liability of Engineer hereunder.

  • Lease Commencement Date The earlier to occur of (i) the date upon which Tenant first commences to conduct business in the Premises, and (ii) sixty (60) days following the date of delivery of the Premises from Landlord to Tenant, which delivery date is anticipated to be May 1, 2002, as such date may be adjusted pursuant to the Tenant Work Letter attached hereto as Exhibit B.

  • PRE-COMMENCEMENT PHASE Part 1 - Pre-commencement Phase Services Part 2 - Construction Documents and Site Plan SECTION 3 – CONSTRUCTION PHASE Part 1 - Construction Phase Services Part 2 - Changes to the Work Part 3 - Time. Part 4 - Correcting the Work, Inspections, Covering and Uncovering Work Part 5 - Subcontractors, Trade Contractors, and Suppliers

  • Construction Commencement The Connecting Transmission Owner shall commence construction of the Connecting Transmission Owner’s Attachment Facilities and System Upgrade Facilities and System Deliverability Upgrades for which it is responsible as soon as practicable after the following additional conditions are satisfied:

Time is Money Join Law Insider Premium to draft better contracts faster.