Credit for Project Work In order to compensate PURCHASER for project work that PURCHASER agrees to complete under the section titled, “Project Work,” of this contract, STATE agrees to credit PURCHASER’s timber account in the sum of $46,657 upon completion of and STATE’s acceptance of all work, unless otherwise approved in writing by STATE. PURCHASER may request partial credit for project work when PURCHASER has completed and STATE has accepted project work, in accordance with the following credit schedule: Partial credit amount of $24,999 (Project No. 1 completion) Partial credit amount of $ 545 (Project No. 2 completion) Partial credit amount of $ 2,721 (Project No. 3 completion) Partial credit amount of $ 1,753 (Project No. 4 completion) Partial credit amount of $16,639 (Project No. 5 completion)
Development Area 10.4. The Development Area shall encompass all Deposits to be produced.
CONSTRUCTION INDUSTRY DEVELOPMENT & PROMOTION FUND 19.01 The Employer shall contribute to the Union’s Construction Industry Development and Promotion Fund (the “Industry Fund”) the amount identified at Schedule “A” for each hour worked by each employee covered by this Agreement, and it shall remit such contributions to the Union together with union dues, and in the manner described in the Remittances to the Union article and in the Union’s remittance directives.
Partnership Working 7.1 Partnerships will be supported by local authorities on four levels between:
Participating TO’s Interconnection Facilities The Participating TO shall design, procure, construct, install, own and/or control the Participating TO’s Interconnection Facilities described in Appendix A at the sole expense of the Interconnection Customer. Unless the Participating TO elects to fund the capital for the Participating TO’s Interconnection Facilities, they shall be solely funded by the Interconnection Customer.
Loop Provisioning Involving IDLC 2.16.1 Where TWTC has requested an Unbundled Loop and AT&T uses IDLC systems to provide the local service to the customer and AT&T has a suitable alternate facility available, AT&T will make such alternative facilities available to TWTC. If a suitable alternative facility is not available, then to the extent it is technically feasible, AT&T will implement one of the following alternative arrangements for TWTC (e.g., hairpinning):
Generating Facility The Interconnection Customer’s device for the production of electricity identified in the Interconnection Request, but shall not include the Interconnection Customer’s Interconnection Facilities.
Project Area The Project Area is the incorporated area of the City of San Xxxx.
Asset Improvement 5. (a) The Bank shall not, directly or indirectly, extend or renew any credit to or for the benefit of any borrower, including any related interest of the borrower, who is obligated to the Bank in any manner on any extension of credit or portion thereof that has been charged off by the Bank or classified, in whole or in part, “loss” in the Report of Examination or in any subsequent report of examination, as long as such credit remains uncollected.
Temporary Credit for Unamortized Specified Road Construction Cost When, under B8.33, Contracting Officer orders a delay or interruption of Purchaser’s Operations for more than 30 days when scheduled operations would be occurring but for the order, the Contracting Officer shall credit the unamortized cost of Specified Roads to Purchaser’s Timber Sale Account, upon the written request of Purchaser or at the discretion of Contracting Officer. The amount credited to Purchaser shall be limited to stumpage paid above Base Rates. Any Specified Road construction cost credited to Purchaser pursuant to this Subsection may be refunded or transferred at the request of Purchaser. However, if Purchaser has outstanding debt owing the United States, Contracting Officer must apply the amount of credit that could be refunded to the debt owed in accordance with the Debt Collection Improvement Act of 1996, as amended. Upon written notice from Contracting Officer that the basis for the delay or interruption no longer exists, Purchaser shall pay for timber a per unit amount, in addition to Current Contract Rates, that is equal to the amount credited to Purchaser’s Timber Sale Account divided by 80 percent of the estimated remaining volume of the contract, until the full amount credited to Purchaser has been returned.
