Capital Improvement Coordination with Airline Sample Clauses

Capital Improvement Coordination with Airline. On or about July 1, or approximately ninety (90) days prior to the end of the then-current Fiscal Year, City shall notify Airline in writing of its proposed Capital Improvement program for the subsequent Fiscal Year, as contained in City’s proposed Capital Improvement budget for the Fiscal Year. City further reserves the right to notify Airline in writing at any other time of proposed Capital Improvements. The City agrees to provide Airline a written description of such Capital Improvements, such description to include the purpose, method of financing, and any reasonably anticipated effect on airline rents, fees, and charges hereunder and, to meet with Airline and other airlines within thirty (30) days after notification to Airline of said Capital Improvement to further discuss the proposed Capital Improvement. Such meeting may occur concurrently with the airline consultation described in Article 6. The City will give due consideration to the comments and recommendation of Airline with respect to the proposed Capital Improvements. Certain Capital Improvements are subject to deferral if Airline, together with other airlines, requests a deferral of a proposed Capital Improvement. If seventy-five percent (75%) in number of the airlines currently leasing premises from the City and operating at the Airport (excluding any Affiliates), and representing at least seventy-five percent (75%) of airline rents, fees, and charges associated with this Agreement paid during the previous Fiscal Year request deferral of a particular Capital Improvement not excluded below, it will be deferred for a period of twelve (12) months. Any such request for deferral must be in writing and submitted to City by Airline within thirty (30) days following the meeting as described above in accordance with Section 19.5. In the event of a Capital Improvement deferral, the Capital Improvement will be deferred for twelve (12) months following the deferral request. Following the twelve (12) months deferral period, the Capital Improvement may be constructed and the capital, operating, and maintenance costs and expenses will be included in airline’s rents, fees and charges upon the Capital Improvement’s completion.
Sample 1
AutoNDA by SimpleDocs

Related to Capital Improvement Coordination with Airline

  • Capital Improvements The Department has identified the following possible opportunities for Capital Improvements:

  • Project Coordination The Engineer shall coordinate all subconsultant activity to include quality and consistency of deliverables and administration of the invoices and monthly progress reports. The Engineer shall coordinate with necessary local entities.

  • Utility Coordination Identify all potential utility conflicts and provide preliminary office check plans showing the problem locations, posted to the City’s FTP site. Plans will clearly identify specific utility company facilities by color and by name (i.e. not just “gas” or “fiber optic”). ENGINEER shall include a conflict list for each utility, also posted to the FTP site. ENGINEER shall meet with utility company representatives to review plans and utility verification forms (Attachment No. 3 to Exhibit “A”) at each milestone date and as directed by the CITY and as determined necessary by the ENGINEER. This in- formation will be compiled into a summary report (Attachment No. 4 to Exhibit “A” also available on the City’s FTP site) maintained and updated by ENGINEER as necessary to present a cohesive and reflective status of utilities, and provided to the City as necessary. ENGINEER shall maintain involvement with utility companies until all conflicts have been resolved (not just identified). When appropriate, the City Engineer will approve the identification on plans of conflicts to be resolved during construction. ENGINEER shall meet with involved utility company/ies and project contractor to resolve any conflicts with utilities that occur during construction.

  • Construction Activities Please list all major construction activities, both planned and completed, to be performed by Seller or the EPC Contractor. Activity EPC Contractor / Subcontractor Completion Date __/__/____ (expected / actual) __/__/____ (expected / actual)

  • Construction Phase Services 3.1.1 – Basic Construction Services

  • PROFESSIONAL IMPROVEMENT A. The parties’ support the principle of continuing training of teachers, participation by teachers in professional organizations in the areas of their specialization, leaves for work on advanced degrees or special studies, foreign travel and participation in community educational projects.

  • Improvement Plan A written plan developed by the evaluator, utilized when a teacher received a Rating of Ineffective on his/her Evaluation or on any individual deficiency in the evaluation system.

  • Tenant Improvement Plans Tenant, at Tenant's sole cost and expense, shall retain an interior architect ("Architect") to prepare plans and outline specifications to be attached as Exhibit "C" ("Tenant Improvement Plans and Specifications") with respect to the construction of initial interior improvements to the Premises ("Tenant Improvements"). The Tenant Improvement Plans and Specifications shall be completed for all aspects of the work (either in one package or in phases as provided below) by June 30, 2001 with all detail necessary for submittal to the city, within three (3) days thereafter, for issuance of building permits and for construction, and shall include any information required by the relevant agencies regarding Tenant's use of Hazardous Materials if applicable. The Tenant Improvements shall: (i) be reasonably compatible with (and not damaging to) the structural, mechanical, electrical, plumbing and other systems of the Building, (ii) not materially adversely impact (in Landlord's reasonable judgment) the exterior appearance or operations of the Building, the currently existing interior improvements in the Building, or the appearance or operations of the public areas of the Building and (iii) comply with all any law, statute, ordinance, order, rule, regulation or requirement of any governmental or quasi-governmental authority. All Tenant Improvements shall be subject to Landlord's reasonable approval, which shall not be unreasonably withheld or delayed beyond five (5) business days following receipt of Tenant's Plans and Specifications, provided the above conditions are met. Landlord's failure to approve, or reasonably disapprove, the Tenant Improvement Plans and Specifications (or revised Plans and Specifications) within five (5) business days following Landlord's receipt thereof shall be deemed Landlord's approval. The Tenant Improvement Plans and Specifications shall include all detail required by the City of Santa Clara necessary to obtain a Certificate of Occupancy. Construction ox xxx Tenant Improvements shall be performed by a general contractor ("General Contractor") selected by Tenant, subject to Landlord's reasonable approval. Tenant shall not be required to use union labor as a condition of receiving Landlord's approval hereunder. The Tenant Improvement Plans and Specifications shall be prepared in sufficient detail to allow General Contractor to construct the Tenant Improvements. The Tenant shall contract directly with General Contractor for construction of the Tenant Improvements and shall cause the General Contractor to construct the Tenant Improvements in accordance with all Tenant Improvement Plans and Specifications. Tenant shall have no obligation to remove the Tenant Improvements at the expiration or earlier termination of the Lease. The Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall not be removed or altered by Tenant without the prior written consent of Landlord as provided in Section 7. Tenant shall have the right to depreciate and claim and collect any investment tax credits in the Tenant Improvements during the Lease Term. Upon expiration of the Lease Term or any earlier termination of the Lease, the Tenant Improvements (other than Tenant's trade fixtures, equipment and furnishings and other personal property of Tenant that can be removed without permanent damage to the Premises) shall become the property of Landlord and shall remain upon and be surrendered with the Premises, and title thereto shall automatically vest in Landlord without any payment therefore.

  • Information Systems Acquisition Development and Maintenance Security of System Files. To protect City Information Processing Systems and system files containing information, Service Provider will ensure that access to source code is restricted to authorized users whose specific job function necessitates such access.

  • Construction of the Tenant Improvements Construction or installation of the Tenant Improvements shall be performed by a licensed general contractor or contractors selected by Tenant and approved by Landlord, such approval not to be unreasonably withheld or delayed (the “Tenant’s Contractor,” whether one or more), pursuant to a written construction contract negotiated and entered into by and between the Tenant’s Contractor and Tenant and approved by Landlord. Each such contract shall (i) obligate Tenant’s Contractor to comply with all reasonable rules and regulations of Landlord relating to construction activities in the Building, (ii) name Landlord as an additional indemnitee under the provisions of the contract whereby the Tenant’s Contractor holds Tenant harmless from and against any and all claims, damages, losses, liabilities and expenses arising out of or resulting from the performance of such work, (iii) name Landlord as a beneficiary of (and a party entitled to enforce) all of the warranties of the Tenant’s Contractor with respect to the work performed thereunder and the obligation of the Tenant’s Contractor to replace defective materials and correct defective workmanship for a period of not less than one (1) year following final completion of the work under such contract, (iv) evidence the agreement of the Tenant’s Contractor that the provisions of the Lease shall control over the provisions of the contract with respect to distribution or use of insurance proceeds, in the event of a casualty during construction, and (v) evidence the waiver and release by the Tenant’s Contractor of any lien or right to assert a lien on all or any portion of the fee estate of Landlord in and to the Building as a result of the work performed or to be performed thereunder (and obligating the Tenant’s Contractor to include a substantially similar release and waiver provision in all subcontracts and purchase orders entered under or pursuant to the contract). Notwithstanding anything to the contrary, union labor shall not be required to be used for construction of the Tenant Improvements; provided, however, Landlord shall be permitted to withhold its consent to a contractor proposed to be utilized by Tenant to the extent such contractor would create a labor dispute at the Building or Project that could impair or affect the Landlord’s ability to operate the Building or otherwise provide the services it is required to provide to its tenants. In the event there is any labor dispute as a result of Tenant’s contractor and such labor dispute is impairing or affecting Landlord’s ability to operate the Building or otherwise provide the services it is required to provide to its tenants, then Tenant shall immediately take such actions as may be required in order to cause such labor dispute to cease. Tenant and its contractors shall be required to comply with the constructions rules and regulations set forth Exhibit B-1 attached hereto (and the Tenant Improvement shall be required to incorporate all design elements set forth in such Exhibit B-1). Tenant acknowledges and understands that all roof penetrations involved in the construction of the Tenant Improvements must be performed by the Landlord’s Building roofing contractor. All costs, fees and expenses incurred with such contractor in performing such work shall be a cost of the Tenant Improvements (which such cost may be payable out of the Landlord’s Construction Allowance), in accordance with the provisions of this Exhibit B. Tenant or Tenant’s Contractor shall be responsible for all water, gas, electricity, sewer or other utilities used or consumed at the Premises during the construction of the Tenant Improvements. Tenant specifically agrees to carry, or cause the Tenant’s Contractor to carry, during all such times as the Tenant’s work is being performed, (a) builder’s risk completed value insurance on the Tenant Improvements, in an amount not less than the full replacement cost of the Tenant Improvements, (b) a policy of insurance covering commercial general liability, in an amount not less than One Million Dollars ($1,000,000.00), combined single limit for bodily injury and property damage per occurrence (and combined single limit coverage of $2,000,000.00 in the aggregate), and automobile liability coverage (including owned, non-owned and hired vehicles) in an amount not less than One Million Dollars ($1,000,000.00) combined single limit (each person, each accident), and endorsed to show Landlord as an additional insured, and (c) workers’ compensation insurance as required by law, endorsed to show a waiver of subrogation by the insurer to any claim the Tenant’s Contractor may have against Landlord. Tenant shall not commence construction of the Tenant Improvements until Landlord has issued to Tenant a written authorization to proceed with construction after Tenant has delivered to Landlord’s construction representative (i) certificates of the insurance policies described above, (ii) copies of all permits required for construction of the Tenant Improvements and a copy of the permitted Final Plans as approved by the appropriate governmental agency, and (iii) a copy of each signed construction contract for the Tenant Improvements (a copy of each subsequently signed contract shall be forwarded to Landlord’s construction representative without request or demand, promptly after execution thereof and prior to the performance of any work thereunder). All of the construction work shall be the responsibility of and supervised by Tenant.

Time is Money Join Law Insider Premium to draft better contracts faster.