Twenty First Floor Work Completion Date definition

Twenty First Floor Work Completion Date means the date that is eighteen (18) months from the date hereof.
Sample 1

Examples of Twenty First Floor Work Completion Date in a sentence

  • Tenant will use commercially reasonable efforts, consistent with Tenant’s express obligations under Section 11.11 of this Lease, to complete the Twenty First Floor Work no later than the Twenty First Floor Work Completion Date.

Related to Twenty First Floor Work Completion Date

  • The Completion Date means the date of completion of the Works as certified by the Employer’s Representative.

  • Construction Completion Date means the date by which the overall development of the Project is completed in accordance with the provisions of this Agreement and when the Construction Completion Certificate is issued by the Independent Engineer as per Article 14.1.

  • Final Completion Date means the date on which Final Completion occurs.

  • Substantial Completion Date means the date on which Substantial Completion occurs.

  • Project Completion Date means the date on which the Completion Certificate is issued;

  • Completion Date means the date of completion of the Services by the Service Provider as certified by the Procuring Entity

  • project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;

  • Target Completion Date has the meaning given such term in Section 3.3(b).

  • Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.

  • Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:

  • Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.

  • Outside Completion Date shall have the meaning assigned to such term in Section 6.3(d).

  • Construction Completion means physical construction of a cleanup action component is complete.

  • Construction Commencement Date means the date set out in the Addendum, if applicable, by which you must commence construction of the Hotel. For the Hotel to be considered under construction, youmust have begun to pour concrete foundations for the Hotel or otherwise satisfied any site-specific criteria for “under construction” set out in the Addendum.

  • Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;

  • Commencement Date means the date fourteen (14) days after the date the Contract comes into effect or any other date named in the Contract Data.

  • Scheduled Completion Date shall be the date set forth in Clause 10.3;

  • Framework Commencement Date means [insert date dd/mm/yyyy];

  • Time of Completion means the time for completing the execution of and passing the Tests on Completion of the Works of any section or part thereof as stated in the Contract (or as extended under Clause...) calculated from the Commencement Date

  • Mechanical Completion means that (a) all components and systems of the Project have been properly constructed, installed and functionally tested according to EPC Contract requirements in a safe and prudent manner that does not void any equipment or system warranties or violate any permits, approvals or Laws; (b) the Project is ready for testing and commissioning, as applicable; (c) Seller has provided written acceptance to the EPC Contractor of mechanical completion as that term is specifically defined in the EPC Contract.

  • Term Start Date means [Insert date];

  • Project Start Date means the first Milestone Start Date specified in Schedule B;

  • Virtual Completion means the premise is in the opinion of the Employer fit for occupation.

  • Phase 1 means the first implementation phase of this section, beginning June 1, 2018 and ending May 31, 2022.

  • Start Date for Term Calculation Purposes Only: Regardless of actual award/effective date of Contract, for Agreement “term” calculation purposes only, the Agreement “start date” is the last day of the month that Award Notifications are anticipated as published in the Solicitation. Example: If the anticipated award date published in the Solicitation is August 27, 2020 but extended negotiations delay award until September 24, 2020 the end date of the resulting initial “two-year” term Agreement, (which is subject to an extension(s)) will still be August 31, 2022 in this example

  • Date of Completion with respect to a Project shall mean: (i) the date upon which such Project and all components thereof have been acquired or constructed and are capable of performing the functions for which they were intended, as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; or (ii) the date on which the Issuer determines, upon the recommendation of or in consultation with the Consulting Engineer, that it cannot complete such Project in a sound and economical manner within a reasonable period of time as evidenced by an Engineers’ Certificate filed with the Trustee and the Issuer; provided that in each case such certificate of the Consulting Engineer shall set forth the amount of all Costs of such Project which have theretofore been incurred, but which on the Date of Completion is or will be unpaid or unreimbursed.