City Delays definition

City Delays has the meaning expressed in Section 15.23.1
Sample 1Sample 2
City Delays means the number of days in which the City performs any obligation under Section 2.17 hereof in excess of the number of days set forth for such performance therein.
Sample 1
City Delays means any delays by the City in discharging its obligations under Section4.3 of this Agreement.
Sample 1

Examples of City Delays in a sentence

  • Furthermore, the time (including cure periods) for the performance of any of Developer’s obligations hereunder shall be extended by City Delays to the extent the same prevent Developer from meeting such obligation.

  • Without any additional resources from the DOE, Ms. Sicherman is essentially running three classes within her third-31 Gwynne Hogan, “ City Delays Christmas Week Family Shelter Evictions After Outcry,” THE CITY, December 6, 2023, available at https://www.thecity.nyc/2023/12/06/christmas-repreive-migrant-shelter-evictions/grade class to accommodate and teach the migrant children with severe educational needs alongside her other third-grade students.

  • Notwithstanding the foregoing, no more than two draws may be submitted until after the Arena Grand Opening, unless the Arena Grand Opening is delayed due to City Delays or Force Majeure.

  • Our promise to you safeguarded by the language of a very tough, expertly drawn contract is that we will always operate in the public interest.” Freddie Ferretti, City Delays Its Decision on CATV Policy, N.Y. TIMES, July 24, 1970, at 63.

  • Derived from the “Manson Rule” – a number of years ago Richard Manson was Commissioner of Accounts in Richmond and he promulgated the above rule, which has been widely followed.

  • The above-referenced deadlines for Commencement of Construction and for Completion of Construction will be extended one (1) day for each day of delay attributable to events of Force Majeure or to any City Delays.

  • There are three different payment rates, one for basic level of care, as defined in 130 CMR 404.407(A), one for complex level of care, as outlined in 130 CMR 404.414(A)(2), and one for health promotion and prevention, as outlined in 130 CMR 404.414(D).

  • Ashokan Cemeteries: City Delays in Making Payment for Work Done," Kingston Daily Freeman (KDF), October 31, 1910.difficulties, only 300 of the roughly 3,000 bodies buried in the Esopus Valley were left unclaimed.11 While some historians have argued that by the early twentieth century cemeteries were losing cultural value, replaced by more symbolic forms of memorialization, this number attests to the ongoing importance of the actual physical corpse.

  • Without limiting the specificity applicable to City Delays and Force Majeure (both as defined below), immediately following the commencement of any cause for delay, representatives of the Construction Manager and City shall confer for the purpose of determining the probable length of the delay and a course of action which would end or eliminate the occurrence or event which is causing delay.

  • As with the outside date to obtain the Loan Commitment, this date may be extended for up to two months and tolled for City Delays and catastrophic force majeure events.


More Definitions of City Delays

City Delays are defined in the Appendix as failure to timely respond to contractual approvals, or timely perform City’s contractual obligations, or failure to diligently defend litigation affecting the Arena project.
Sample 1

Related to City Delays

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Tenant Delays means delays caused by: (i) requirements of the Plans and Specifications requested by Tenant that do not conform to Landlord’s building standards for office and lab build-out, or which contain long lead-time or non-standard items requested by Tenant; provided that Landlord has notified Tenant of such deviations upon execution of this Lease (ii) any material change in the Plans and Specifications requested by Tenant and agreed to by Landlord; (iii) any request by Tenant for a delay in the commencement or completion of the Initial Tenant Improvements for any reason; (iv) Tenant delay in finalizing and approving the design of the vivarium and value engineering of same or (v) any other act or omission of Tenant or its employees, agents or contractors which reasonably inhibits the Landlord from timely completing the Initial Tenant Improvements including, without limitation any delays caused by Tenant’s presence in the Premises prior to the Term Commencement Date. The Premises shall not be deemed to be incomplete if only minor or insubstantial details of construction, decoration or mechanical adjustments remain to be done which do not unreasonably interfere with Tenant’s occupancy of the Premises. If as a result of Tenant Delays the Premises are deemed ready for Tenant’s occupancy, pursuant to the foregoing (and the term shall have commenced by reason thereof), but the Premises are not in fact actually ready for Tenant’s occupancy, Tenant shall not (except with Landlord’s consent not to be unreasonably withheld, conditioned or delayed) be entitled to take possession of the Premises for the permitted use until the Premises are in fact actually ready for such occupancy.

  • Landlord Delay shall occur if either: (i) Landlord fails to complete the Base Building and/or other improvements on the Project that are required by the DDA, the Parking REA and/or the CC&Rs, and as a direct result of such failure Tenant is unable to obtain a temporary or permanent certificate of occupancy for the Premises upon substantial completion of the Tenant Improvements; or (ii) substantial completion of the Warm Shell Improvements or Tenant Improvements is delayed directly and solely as a result of any of the following and such delay could not have been mitigated by Tenant using commercially reasonable measures, which delay occurs after the Delivery Date and before the Commencement Date and does not result from Tenant's interference or delay in connection with completion of the Tenant Improvements or after a Tenant Default or Work Letter Draw Event: (a) subject to Paragraph 8 above, unreasonable interference by Landlord or Landlord's Contractor with the construction of the Warm Shell Improvements or the Tenant Improvements; (b) Landlord's failure to comply with any deadlines for response to, or submissions from, Tenant as required by this Work Letter; (c) any material Discretionary Changes to Landlord's Plans or the Warm Shell Plans after their final approval by applicable governmental entities (other than Tenant Modifications) that directly affect Tenant's Plans or the Tenant Improvements; and/or (d) Landlord failure to complete portions of the Base Building and/or other improvements on the Project that are Landlord's obligation to complete hereunder, and as a direct result of such failure Tenant and Tenant's contractors do not have access to the Premises to the extent required to complete the Warm Shell Improvements and/or Tenant Improvements. Tenant shall give Landlord at least five (5) days prior notice if Tenant becomes aware that Landlord is in danger of causing a Landlord Delay, and if Landlord takes appropriate measures to prevent such delay within such five (5) day period, no adjustment to the Commencement Date shall be made on account of such Landlord; provided, however, that if such delay was not reasonably foreseeable by Tenant, the five (5) day period for prior notice and opportunity to mitigate provided above shall be changed to forty-eight (48) hours after Tenant becomes aware of such delay or potential delay.

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.

  • Base Building Work means the base building work for the Building as described in this Manual.

  • Tenant Delay as used in the Lease or this Agreement shall mean any delay that Landlord may encounter in the performance of Landlord’s obligations under the Lease or this Agreement because of any act or omission of any nature by Tenant or its agents or contractors, including any: (1) delay attributable to changes in or additions to the Approved Plans or to the Landlord’s Work requested by Tenant; (2) delay attributable to the postponement of any Landlord’s Work at the request of Tenant; (3) delay caused by a Change Order requested by Tenant; (4) delay attributable to the failure of Tenant to pay, when due, any amounts required to be paid by Tenant pursuant to the Lease; or (5) delay attributable to a failure of Tenant to employ union labor for Tenant’s work at the Premises during the time the Landlord’s Work is being constructed. Tenant shall pay all actual costs and expenses incurred by Landlord which result from any Tenant Delay and the Commencement Date of the Lease shall be accelerated one (1) day for each day the Premises is not Ready for Occupancy as a result of a Tenant Delay. No Tenant Delay shall be deemed to have occurred unless Landlord gives Tenant prior written notice or written notice within five (5) days of the occurrence, as reasonable under the circumstances, specifying the claimed reasons for such Tenant Delay, and Tenant shall fail to promptly correct or cure such Tenant Delay. There shall be excluded from the number of days of any Tenant Delay, or any of the following events of force majeure: labor disputes, fire, unusual delay in transportation, adverse weather conditions not reasonably anticipatable, unavoidable casualties, delays in obtaining permits or governmental approvals or any other causes beyond Landlord’s or its contractor’s reasonable control (and other than for financial reasons) (collectively, “Force Majeure Delays”).

  • Building Work has the meaning given to it in section 6 of the Building and Construction Industry (Improving Productivity) Act 2016 (Cth);

  • Unavoidable Delays means delays due to any of the following, and only the following, (provided that such delay is beyond Construction Manager’s reasonable control): war, insurrection, civil commotion, strikes, slowdowns, lock outs, riots, flood, earthquakes, fires, casualties, acts of God, acts of a public enemy, acts of terrorism, epidemics, quarantine restrictions, freight embargoes, lack of transportation, governmental moratoriums, unusually severe or abnormal weather conditions, failure of utilities, or a court order which causes a delay (unless resulting from a wrongful act of Construction Manager). In no event shall the application to Construction Manager of any applicable law, regulation, rule or other governmental requirement constitute an Unavoidable Delay. Contractor shall use reasonable good faith efforts to notify Owner not later than five (5) days after Construction Manager knows of the occurrence of an Unavoidable Delay. An extension of time for an Unavoidable Delay shall only be for the period of the Unavoidable Delay, which period shall commence to run from the time of the commencement of the cause of the Unavoidable Delay.

  • Landlord’s Work means the work of constructing the Tenant Improvements.

  • Occupancy Date means the date on which occupancy of all Units in a Project is permitted;

  • Work Letter means the work letter between Landlord and Tenant regarding the construction of the Tenant Improvements, if any, in the form of Exhibit C.

  • Building Drain means that part of the lowest horizontal piping of a drainage system which receives the discharge from soil, waste, and other drainage pipes inside the walls of the building and conveys it to the building sewer, beginning five (5) feet (1.5 meters) outside the inner face of the building wall.

  • Landlord Work means the work, if any, that Landlord is obligated to perform in the Premises pursuant to a separate agreement (the “Work Letter”), if any, attached to this Lease as Exhibit C.

  • Force Majeure Period has the meaning specified in Section 13.1.

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Force Majeure Failure has the meaning set forth in Section 8.1(d).

  • Expansion Space means any space in the Building which, at any time during the Lease Term, is occupied by a Person other than Landlord under a written lease with Landlord, and the term “Tenant’s Expansion Space” means Expansion Space which Tenant has elected to lease as provided in this paragraph. Landlord agrees to notify Tenant promptly after Landlord learns that any Expansion Space is or will become available. Subject to the prior rights of other tenants to whom Landlord has granted substantially similar rights, Tenant has the option to lease any Expansion Space which Landlord notifies Tenant is or will become available. If Tenant gives Landlord notice of its exercise of this option within thirty (30) days after notification from Landlord of the availability of the Expansion Space and if no Event of Default exists when Tenant’s notice is given, this Lease will be deemed to be amended to include Tenant’s Expansion Space as part of the Premises for the remainder of the Lease Term upon all of the same terms contained in this Lease except that (i) the Rentable Area of the Premises will be amended to include Tenant’s Expansion Space; (ii) Tenant’s Share will be increased to include the rentable area of Tenant’s Expansion Space; (iii) the Term Commencement Date with respect to Tenant’s Expansion Space will be the earlier of sixty (60) days after the date on which Tenant’s Expansion Space becomes vacant and ready for occupancy (provided that date is at least sixty (60) days after Tenant exercises its option to lease the Expansion Space), or the date on which the Expansion Space is first occupied by Tenant; (iv) if Tenant’s Expansion Space contains a rentable area of 10,000 square feet or more, and if there are less than three (3) Lease Years remaining in the Lease Term, the Lease Term will be extended to include three (3) full years from the Term Commencement Date with respect to Tenant’s Expansion Space; and (v) subject to adjustment during each Fixed Rental Period as provided in Exhibit E, Basic Rent for each year of the remaining Lease Term (as it may be extended) will be the greater of (a) the Basic Rent last paid by the Person most recently occupying Tenant’s Expansion Space or (b) Market Rent determined as provided in the Rent Rider attached as Exhibit E. If Tenant exercises this option, Tenant’s Expansion Space will be leased to Tenant in its “as is” condition and Tenant will, at its expense and in compliance with the provisions of Section 7.06, design and construct all Improvements desired by Tenant for its use and occupancy. Landlord and Tenant agree to execute such amendments to this Lease and other instruments as either of them considers necessary or desirable to reflect Tenant’s exercise of this option.

  • Tenant’s Work means all improvements, alterations, fixture, equipment, and signage installation, and furniture placement necessary or appropriate for the conduct of the Permitted Use, including all work described as Tenant’s Work on Exhibit D, attached (the “Work Letter”).

  • Ready for Occupancy means the date upon which (i) the Leased Premises are available for Tenant's occupancy in a broom clean condition and (ii) the improvements, if any, to be made to the Leased Premises by Landlord as a condition to Tenant's obligation to accept possession of the Leased Premises have been substantially completed and the appropriate governmental building department (i.e., the City building department, if the Property is located within a City, or otherwise the County building department) shall have approved the construction of such improvements as substantially complete or is willing to so approve the construction of the improvements as substantially complete subject only to compliance with specified conditions which are the responsibility of Tenant to satisfy or is willing to allow Tenant to occupy subject to its receiving assurances that specified work will be completed.

  • this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

  • Modular building retailer means any person who purchases or acquires a modular building from a

  • Tenant Improvements Defined in Exhibit B, if any.

  • Rentable Area of the Premises The amount of square footage set forth in Section 1.01(10).

  • Base Rental means the sum of Seven Hundred Nineteen Thousand Two Hundred Sixty-Eight and NO/100 Dollars ($719,268.00), payable by Tenant to Landlord in sixty (60) monthly installments as follows:

  • Base Rent As defined in Section 3.1.