Right to Stop Work If Contractor fails to correct any defective Work or repeatedly fails to perform the Work in accordance with the Contract Documents, Owner shall have the right to order Contractor to stop performing the Work, or any portion thereof, until the cause for such order is eliminated.
Right to Stop Payment and Procedure for Doing So If you have told us in advance to make regular payments out of your account, you can stop any of these payments by calling or writing us at the telephone number or address referenced below in this disclosure in time for us to receive your request three (3) business days or more before a payment is scheduled to be made. If you call, we may also require you to put your request in writing and get it to us within fourteen (14) days after you call. We will charge you according to the Schedule of Fees provided to you earlier in other documentation furnished when you opened your account(s) for each stop payment order you give.
City’s Right to Suspend for Convenience City may suspend all or any portion of Contractor’s performance under this Contract at its sole option and for its convenience for a reasonable period of time not to exceed six (6) months. City must first give ten (10) days’ written notice to Contractor of such suspension. City will pay to Contractor a sum equivalent to the reasonable value of the goods and/or services satisfactorily provided up to the date of suspension. City may rescind the suspension prior to or at six (6) months by providing Contractor with written notice of the rescission, at which time Contractor would be required to resume performance in compliance with the terms and provisions of this Contract. Contractor will be entitled to an extension of time to complete performance under the Contract equal to the length of the suspension unless otherwise agreed to in writing by the Parties.
Owner’s Right to Stop Work The Owner reserves the right, for itself and for any designated Construction Inspector retained by Owner, upon observation of apparent nonconforming Work, to immediately stop the affected Work. If the Work is later determined by the Design Professional to be in fact conforming Work, then Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the stop Work order and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's stop Work order. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
OWNER’S RIGHT TO STOP THE WORK If the Contractor fails to correct Work that is not in accordance with the requirements of the Contract Documents as required by Section 12.2 or repeatedly fails to carry out Work in accordance with the Contract Documents, the Owner may issue a written order to the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, the right of the Owner to stop the Work shall not give rise to a duty on the part of the Owner to exercise this right for the benefit of the Contractor or any other person or entity.
Right to Grieve Where an employee feels that she has been aggrieved by a decision of the Employer related to promotion, demotion or transfer, the employee may grieve the decision at Step 3 of the grievance procedure in Article 9 of this Agreement within seven (7) days of being notified of the results.
Right to suspend 2.1.1 Network Rail may serve a Suspension Notice where a Train Operator Event of Default has occurred and is continuing.
STATE'S RIGHT TO STOP THE WORK 3.3.1 If the Contractor fails to correct defective Work as required by Paragraph 13.2 or persistently fails to carry out the Work in accordance with the Contract Documents, the State, by a written order signed personally or by an agent specifically so empowered by the State in writing, may order the Contractor to stop the Work, or any portion thereof, until the cause for such order has been eliminated; however, this right of the State to the stop the Work shall not give rise to any duty on the part the State to exercise this right for the benefit of the Contractor or any other person or entity, except to the extent required by Subparagraph 6.1.3.
Owner’s Right to Suspend Work The Owner reserves the right, with or without the concurrence of the Design Professional, to suspend the Work at any time or from time to time at the Owner's sole discretion, upon giving Contractor five days advanced written notice thereof. If the Owner exercises this right and then resumes the Work covered hereby, Contractor shall be entitled upon timely claim to a Change Order for payment by Owner of any reasonable Actual Costs actually incurred by Contractor in connection with the suspension and resumption of the Work, as well as an extension in the time for performance of the Work to the extent Contractor is delayed by Owner's suspension, to include compensation based upon the rate for Time Dependent Overhead Costs. The Design Professional shall determine the time, which shall be binding upon both Owner and Contractor, as set forth in Section 3, Part 3.
Time Limits to Submit to Arbitration Failing satisfactory settlement at Step 2, and pursuant to Article 9, the President or his/her designate, may inform the Employer of his/her intention to submit the dispute to arbitration within:
