Preliminary Plans, Cost Review and Approval Sample Clauses

Preliminary Plans, Cost Review and Approval. The County will review the preliminary plans submittal and provide comments and conditional approval. I&L will incorporate the review comments into the final design plan.
Sample 1
AutoNDA by SimpleDocs
Preliminary Plans, Cost Review and Approval. The CITY will review the preliminary plans submittal and provide comments and conditional approval. I&L will incorporate the review comments into the final design plan. WILDWOOD ‐ XXXXX ROAD FLOOD CONTROL DESIGN Personnel Type/Title Principal Project Manager H&H Engineer CAD / GISDesigner Environmental Scientist Structural Engineer Subtotal Hours Subtotal Personnel Cost Direct Expenses Sub Consultant Expenses Subtotal Personnel Billing Rate 225.00 135.00 105.00 95.00 75.00 150.00 1.0 Surveying 0 $ ‐ $ ‐ Coordination 4 4 $ 540.00 $ 540.00 1 $ 30,000 Meridian 0 $ ‐ $ 30,000.00 $ 30,000.00 1 $ 9,500 0 $ ‐ $ 9,500.00 $ 9,500.00 0 $ ‐ $ ‐ Subtotal = 0 4 0 0 0 0 4 $ 540.00 $ ‐ $ 39,500.00 $ 40,040.00 2.0 Hydraulic Analysis 0 $ ‐ $ ‐ HEC RAS Modeling 0 $ ‐ $ ‐ Developed Existing Conditions RAS 8 32 40 $ 4,440.00 $ 4,440.00 0 $ ‐ $ ‐ Final Hydraulic Design 0 $ ‐ $ ‐ Develop 2015 Analysis Configurations 4 20 24 $ 2,640.00 $ 2,640.00 Evaluate modifications to configuration 4 12 16 $ 1,800.00 $ 1,800.00 Evaluate 100 year design solutions 4 4 $ 540.00 $ 540.00 0 $ ‐ $ ‐ Design Meeting 0 $ ‐ $ ‐ Prepare for meeting 1 2 3 $ 345.00 $ 345.00 meet with City 4 4 8 $ 960.00 $ 960.00 0 $ ‐ $ ‐ 0 $ ‐ $ ‐ Subtotal = 0 25 70 0 0 0 95 $ 10,725.00 $ ‐ $ ‐ $ 10,725.00 3.0 Open House 0 $ ‐ $ ‐ Open House Coordination 1 1 2 $ 240.00 $ 240.00 0 $ ‐ $ ‐ Open House Presentation 2 8 10 $ 1,110.00 $ 1,110.00 0 $ ‐ $ ‐ Open House Exhibits and Forms 2 8 10 $ 1,110.00 $ 1,110.00 Attend Open House 4 4 4 12 $ 1,860.00 $ 1,860.00 Open House Summary 1 2 3 $ 345.00 $ 345.00 0 $ ‐ $ ‐ Follow Up Resident Coordination 16 16 $ 2,160.00 $ 2,160.00 0 $ ‐ $ ‐ Subtotal = 4 26 23 0 0 0 53 $ 6,825.00 $ ‐ $ ‐ $ 6,825.00 4.0 Preliminary Plans 0 $ ‐ $ ‐ Preliminary Design 8 16 24 $ 2,760.00 $ 2,760.00 Utility Coordination 0 $ ‐ $ ‐ Utility Submittal 1 2 3 $ 345.00 $ 345.00 Utility Coordination 1 4 5 $ 555.00 $ 555.00 Utility Documentation 2 2 $ 210.00 $ 210.00 Preliminary Plans 0 $ ‐ $ ‐ 1 Cover 1 2 3 $ 325.00 $ 325.00
Sample 1

Related to Preliminary Plans, Cost Review and Approval

  • Preliminary Plans Tenant shall prepare and submit to Landlord for approval schematics of the Tenant Improvements prepared in conformity with the applicable provisions of this Exhibit F (the “Preliminary Plans”). The Preliminary Plans shall contain sufficient information and detail to accurately describe the proposed design to Landlord and such other information as Landlord may reasonably request. Landlord shall notify Tenant in writing within ten (10) business days after receipt of the Preliminary Plans whether Landlord approves or objects to the Preliminary Plans and of Landlord’s specific objections to the Preliminary Plans (if any). Landlord’s failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If Landlord reasonably objects to the Preliminary Plans, then Tenant shall revise the Preliminary Plans to remedy Landlord’s objections. Tenant shall then resubmit the revised Preliminary Plans to Landlord for approval, such approval not to be unreasonably withheld, conditioned or delayed. Landlord’s approval of or objection to any revised Preliminary Plans and Tenant’s correction of the same shall continue as provided above for the original Preliminary Plans until Landlord has approved the Preliminary Plans in writing. The Preliminary Plans that are approved by Landlord without objection shall be referred to as the “Approved Preliminary Plans.”

  • Review and Approval Documents specified above must be submitted for review and approval by CITY Purchasing and Contracts prior to the commencement of work by CONTRACTOR. Neither approval by CITY nor failure to disapprove the insurance furnished by CONTRACTOR shall relieve CONTRACTOR of CONTRACTOR’S full responsibility to provide the insurance required by this Contract. Compliance with the insurance requirements of this Contract shall not limit the liability of CONTRACTOR or its sub-contractors, employees or agents to CITY or others, and shall be in addition to and not in lieu of any other remedy available to CITY under this Contract or otherwise. CITY reserves the right to request and review a copy of any required insurance policy or endorsement to assure compliance with these requirements.

  • Approval of Plans and Specifications The Plans and Specifications will conform to the requirements and conditions set out by applicable law or any effective restrictive covenant, and to all governmental authorities which exercise jurisdiction over the Leased Premises or the construction thereon.

  • Construction Progress Schedule A schedule indicating proposed activity sequences and durations, milestone dates for receipt and approval of pertinent information, preparation, submittal, and processing of Shop Drawings and Samples, delivery of materials or equipment requiring long-lead time procurement, and proposed date(s) of Material Completion and Occupancy and Final Completion. The schedule will be developed to represent the sixteen or seventeen CSI Specification Divisions. It shall have a minimum number of activities as required to adequately represent to Owner the complete scope of work and define the Project’s critical path and associated activities. If the Project is to be phased, then each individual Phase should be identified from start through completion of the overall Project and should be individually scheduled and described, including any Owner’s occupancy requirements and showing portions of the Project having occupancy priority. The format of the schedule will have dependencies indicated on a monthly grid identifying milestone dates such as construction start, phase construction, structural top out, dry-in, rough-in completion, metal stud and drywall completion, equipment installation, systems operational, Material Completion and Occupancy Date, final inspection dates, Punchlist, and Final Completion date.

  • Project Reports; Completion Report 1. The Recipient shall monitor and evaluate the progress of the Project and prepare Project Reports in accordance with the provisions of Section 2.06 of the Standard Conditions and on the basis of indicators agreed with the World Bank. Each Project Report shall cover the period of one (1) calendar semester, and shall be furnished to the World Bank not later than one (1) month after the end of the period covered by such report.

  • Project Review A. Programmatic Allowances

  • Preliminary Approval Within a reasonable time after execution of this Settlement Agreement by the Parties, Plaintiff shall apply to the Court for the entry of an Order:

  • Review and Appeal (a) Each Party shall establish or maintain judicial, quasi-judicial, or administrative tribunals or procedures for the purpose of the prompt review and, where warranted, correction of final administrative actions regarding matters covered by this Treaty. Such tribunals shall be impartial and independent of the office or authority entrusted with administrative enforcement and shall not have any substantial interest in the outcome of the matter.

  • Construction Plans Tenant shall prepare final plans and specifications for the Tenant Improvements that (a) are consistent with and are logical evolutions of the Approved Schematic Plans and (b) incorporate any other Tenant-requested (and Landlord-approved) Changes (as defined below). As soon as such final plans and specifications ("Construction Plans") are completed, Tenant shall deliver the same to Landlord for Landlord's approval, which approval shall not be unreasonably withheld, conditioned or delayed. All such Construction Plans shall be submitted by Tenant to Landlord in electronic .pdf, CADD and full-size hard copy formats, and shall be approved or disapproved by Landlord within ten (10) business days after delivery to Landlord. Landlord's failure to respond within such ten (10) business day period shall be deemed approval by Landlord. If the Construction Plans are disapproved by Landlord, then Landlord shall notify Tenant in writing of its objections to such Construction Plans, and the parties shall confer and negotiate in good faith to reach agreement on the Construction Plans. Promptly after the Construction Plans are approved by Landlord and Tenant, two (2) copies of such Construction Plans shall be initialed and dated by Landlord and Tenant, and Tenant shall promptly submit such Construction Plans to all appropriate Governmental Authorities for approval. The Construction Plans so approved, and all change orders approved (to the extent required) by Landlord, are referred to herein as the "Approved Plans."

  • Marketing Plans Contractor and the Exchange recognize that Enrollees and other health care consumers benefit from efforts relating to outreach activities designed to increase heath awareness and encourage enrollment. The parties shall share marketing plans on an annual basis and with respect to periodic updates of material changes. The marketing plans of the Exchange and Contractor shall include proposed and actual marketing approaches, messaging and channels and provide samples of any planned marketing materials and related collateral as well as planned, and when completed, expenses for the marketing budget. The Contractor shall include this information for both the Exchange and the outside individual market. The Exchange shall treat all marketing information provided under this Section as confidential information consistent with Section 1.4.1. The obligation of the Exchange to maintain confidentiality of this information shall survive termination or expiration of this Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.