Ownership of Improvements All modifications, alterations and improvements made or added to the Leased Premises by Tenant (other than Tenant’s inventory, equipment, movable furniture, wall decorations and trade fixtures) shall be deemed real property and a part of the Leased Premises, but shall remain the property of Tenant during the Lease, and Tenant hereby covenants and agrees not to grant a security interest in any such items to any party other than Landlord. Any such modifications, alterations or improvements, once completed, shall not be altered or removed from the Leased Premises during the Lease Term without Landlord’s written approval first obtained in accordance with the provisions of Paragraph 6.1 above. At the expiration or sooner termination of this Lease, all such modifications, alterations and improvements other than Tenant’s inventory, equipment, movable furniture, wall decorations and trade fixtures, shall automatically become the property of Landlord and shall be surrendered to Landlord as part of the Leased Premises as required pursuant to Article 2, unless Landlord shall require Tenant to remove any of such modifications, alterations or improvements in accordance with the provisions of Article 2, in which case Tenant shall so remove same. Landlord shall have no obligations to reimburse Tenant for all or any portion of the cost or value of any such modifications, alterations or improvements so surrendered to Landlord. All modifications, alterations or improvements which are installed or constructed on or attached to the Leased Premises by Landlord and/or at Landlord’s expense shall be deemed real property and a part of the Leased Premises and shall be property of Landlord. All lighting, plumbing, electrical, heating, ventilating and air conditioning fixtures, partitioning, window coverings, wall coverings and floor coverings installed by Tenant shall be deemed improvements to the Leased Premises and not trade fixtures of Tenant.
Ownership of the Leased Property Lessee acknowledges that the Leased Property is the property of Lessor and that Lessee has only the right to the possession and use of the Leased Property upon the terms and conditions of this Lease.
Tenant Improvements Defined As used herein, “Tenant Improvements” shall mean all improvements to the Premises desired by Tenant of a fixed and permanent nature. Other than funding the TI Allowance (as defined below) as provided herein, Landlord shall not have any obligation whatsoever with respect to the finishing of the Premises for Tenant’s use and occupancy.
Location of Improvements; No Encroachments All improvements which were considered in determining the Appraised Value of the Mortgaged Property lay wholly within the boundaries and building restriction lines of the Mortgaged Property, and no improvements on adjoining properties encroach upon the Mortgaged Property. No improvement located on or being part of the Mortgaged Property is in violation of any applicable zoning law or regulation;
Property Insurance Building Improvements and Rental Value 9.2.1 Lessor shall obtain and keep in force a policy or policies of insurance in the name of Lessor, with loss payable to Lessor, any ground-lessor, and to any Lender insuring loss or damage to the Premises. The amount of such insurance shall be equal to the full insurable replacement cost of the Premises, as the same shall exist from time to time, or the amount required by any Lender, but in no event more than the commercially reasonable and available insurable value thereof. If the coverage is available and commercially appropriate, such policy or policies shall insure against all types of direct physical loss or damage (except the perils of flood and/or earthquake unless required by a Lender), including coverage for debris removal and the enforcement of any Applicable Requirements requiring the upgrading, demolition, reconstruction or replacement of any portion of the Premises as the result of a covered loss. Said policy or policies shall also contain an agreed valuation provision in lieu of any coinsurance clause, waiver of subrogation, and inflation guard protection causing an increase in the annual property insurance coverage amount by a factor of not less than the adjusted U.S. Department of Labor Consumer Price Index for All Urban Consumers for the city nearest to where the Premises are located. Lessee Owned Alterations and Utility Installations, Trade Fixtures, and Lessee’s personal property shall be insured by Lessee not by Lessor unless the item in question has become the property of Lessor under the terms of this Lease.
Cost of Tenant Improvements Unless specified otherwise herein, Landlord shall bear and pay the cost of the Tenant Improvements (which cost shall include, without limitation, the costs of construction, the cost of permits and permit expediting, and all architectural and engineering services obtained by Landlord in connection with the Tenant Improvements, the Contractor's fees, Landlord's fee for construction administration in an amount equal to the amount charged by any construction manager retained by Landlord (the "Construction Manager") up to a maximum of $6,121,750 (the "Tenant Improvement Allowance"). The Tenant Improvement Allowance shall be utilized only for building improvements to the Building (and Tenant's architect fees), and not for signage, furniture costs, any third party consulting or contracting fees, any telecom/cabling costs, or any other purpose. Tenant shall bear and pay the cost of the Tenant Improvements (including but not limited to all of the foregoing fees and costs) in excess of the Tenant Improvement Allowance, if any. The cost of the Tenant Improvements shall exclude the cost of furniture, fixtures and inventory and other items of Tenant's Work (as defined below). Notwithstanding the foregoing, the Tenant Improvement Allowance shall not be used for (and Tenant shall have no responsibility for) the following costs except to the extent any of the foregoing are caused by Tenant, are due to Tenant Delays or result from the failure of Tenant to comply with the terms of the Lease or this Work Letter: (1) Property Maintenance Costs prior to the Delivery Date; (2) charges for overtime, except to the extent approved by Tenant; (3) costs to correct construction defects; (4) costs incurred to enforce contracts or cure contractor or subcontractor defaults (including legal fees); or (5) principal or interest on construction loan obtained by Landlord for construction of the Tenant Improvements.
Lessee Improvements Lessee shall not make or allow to be made any alterations or physical additions in or to the leased premises without first obtaining the written consent of Lessor, which consent shall not be unreasonably withheld. Any alterations, physical additions or improvements to the leased premises made by Lessee shall at once become the property of Lessor and shall be surrendered to Lessor upon the termination of this Lease provided that Lessee shall be entitled to retain the property listed on Exhibit A attached hereto, and provided further that, Lessor, at its option, may require Lessee to remove any physical additions and/or repair any alterations in order to restore the leased premises to the condition existing at the time Lessee took possession, reasonable wear and tear excepted, all costs of removal and/or alterations to be borne by Lessee. This clause shall not apply to moveable equipment of furniture owned by Lessee, which may be removed by Lessee at the end of the term of this Lease if Lessee is not then in default and if such equipment and furniture are not then subject to any other rights, liens and interests of Lessor.
TENANT'S USE OF THE PREMISES Tenant shall use the Premises solely for the purposes set forth in Tenant's Use Clause. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall, by reason of the nature of Tenant's use or occupancy of the Premises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Insurance Services Office or any other organization performing a similar function. Tenant shall
Use of the Leased Property (a) Lessee covenants that it will proceed with all due diligence and will exercise reasonable efforts to obtain and to maintain all Licenses and other approvals needed to use and operate the Leased Property and the Hotel under applicable local, state and federal law.
Improvements to Premises Lessee shall take the Premises in its "as-is" condition for the Extended Term except for certain Leasehold Improvements (herein so called) to the Premises which shall be completed in accordance with the specifications attached hereto as Exhibit A (the "Approved Plans"), which have been approved by both Lessor and Lessee. Lessor shall cause the Leasehold Improvements to be installed or constructed in accordance with the Approved Plans by Lessor's contractor. So long as no Event of Default (or event which with notice or lapse of time could become an Event of Default) has occurred under the Lease, Lessor agrees to provide Lessee an allowance equal to One Hundred Fifty-Three Thousand One Hundred Nineteen and No/100 Dollars ($153,119.00) (the "Improvement Allowance"), which allowance is to be used solely for completion of the Leasehold Improvements in accordance with the Approved Plans, and an additional allowance equal to Three Thousand Two Hundred and No/100 Dollars ($3,200.00) (the "Architectural Allowance"), which allowance is to be used solely for space planning and design services for the Premises. In the event that any alterations or modifications to the Premises are required in order to comply with applicable law, including, without limitation, the Americans with Disabilities Act of 1990, as amended, or the State of Texas equivalent laws and regulations, the cost of any such alterations or modifications shall be satisfied out of the Improvement Allowance. The cost of the Leasehold Improvements and the space planning and design fees is to be paid by Lessor out of the Improvement Allowance and the Architectural Allowance, respectively. Any completed work (labor or materials) outside the scope of the Approved Plans or the cost of which is in excess of the Improvement Allowance or the Architectural Allowance, as the case may be, shall be at Lessee's sole cost and will be billed to Lessee by Lessor and will be due and payable within ten (10) days after Lessee's receipt of an invoice therefor. Notwithstanding the foregoing, Lessee will not be liable for work outside the scope of the Approved Plans or excess costs over the amount of the Improvement Allowance or the Architectural Allowance unless Lessee has consented in writing to such work outside the scope of the Approved Plans or excess costs prior to the commencement of such work or the incurring of such excess costs. Any portion of the Improvement Allowance or the Architectural Allowance remaining upon the completion of the Leasehold Improvements shall be deemed forfeited by Lessee. Lessor further acknowledges and agrees that Section 4.07 of the Lease is hereby amended to provide that Lessee shall not be required to surrender possession of the Premises to Lessor "in the same condition as when received", but rather shall be entitled to surrender possession of the Premises in the same condition as exists upon the completion of the Leasehold Improvements described in Paragraph 3 above, subject to any and all other requirements set forth in Section 4.07 of the Lease.
