Notice of Accidents, Claims and Suits Sample Clauses

Notice of Accidents, Claims and Suits. The Material Testing Consultant shall promptly notify the School District and the appropriate insurance company(ies) in writing of any accident(s) as well as any claim, suit or process received by the Material Testing Consultant arising in the course of operations under the Contract. The Material Testing Consultant shall forward such documents received to its insurance company(ies), as soon as practicable, or as required by their insurance policy or policies. The Material Testing Consultant shall advise the School District in writing, within ten (10) calendar days upon notification of a claim or lawsuit based upon the Material Testing Consultant’s services, omission or breach, that it will abide fully by Paragraph 9.1 (Indemnification) and Section 10 (Insurance) of this Contract, and that the applicable insurance carrier(s) has (have) been advised to defend, indemnify, and hold harmless the School District in accordance with the provisions of Paragraph 9.1 (Indemnification) and Section 10 (Insurance) of this Contract. The Material Testing Consultant shall not decline to provide the School District with full protection and coverage under Paragraph 9.1 (Indemnification) and Section 10 (Insurance) of this Contract because some other contractor or consultant may, in whole or in part, be responsible for the occurrence, death, injury, damage, or loss to persons or property, or economic loss, damage, or expense, or because the School District may be a co-insured or an additional insured on some other contractor’s or consultant’s policy of insurance. The Material Testing Consultant agrees that any violation of this Paragraph 10.1i. of Section 10 (Insurance) shall be deemed a material breach of this Contract.
Sample 1
AutoNDA by SimpleDocs
Notice of Accidents, Claims and Suits. The Architectural Designer shall promptly notify the School District and the appropriate insurance company(ies) in writing of any accident(s) as well as any claim, suit or process received by the Architectural Designer arising in the course of operations under the Contract. The Architectural Designer shall forward such documents received to its insurance company(ies), as soon as practicable, or as required by their insurance policy or policies. The Architectural Designer shall advise the School District in writing, within ten (10) calendar days upon notification of a claim or lawsuit based upon the Architectural Designer’s services, omission or breach, that it will abide fully by Paragraph 9.1 (Indemnification) and Section 10 (Insurance) of this Contract, and that the applicable insurance carrier(s) has (have) been advised to defend, indemnify, and hold harmless the School District in accordance with the provisions of Paragraph 9.1 (Indemnification) and Section 10 (Insurance) of this Contract. The Architectural Designer shall not decline to provide the School District with full protection and coverage under Paragraph 9.1 (Indemnification) and Section 10 (Insurance) of this Contract because some other contractor or consultant may, in whole or in part, be responsible for the occurrence, death, injury, damage, or loss to persons or property, or economic loss, damage, or expense, or because the School District may be a co-insured or an additional insured on some other contractor’s or consultant’s policy of insurance. The Architectural Designer agrees that any violation of this Paragraph 10.1i. of Section 10 (Insurance) shall be deemed a material breach of this Contract.
Sample 1
Notice of Accidents, Claims and Suits. The MEP & FP Engineer shall promptly notify the School District and the appropriate insurance company(ies) in writing of any accident(s) as well as any claim, suit or process received by the MEP & FP Engineer arising in the course of operations under the Contract. The MEP & FP Engineer shall forward such documents received to its insurance company(ies), as soon as practicable, or as required by their insurance policy or policies. The MEP & FP Engineer shall advise the School District in writing, within ten (10) calendar days upon notification of a claim or lawsuit based upon the MEP & FP Engineer’s services, omission or breach, that it will abide fully by Paragraph 9.1 (Indemnification) and Section 10 (Insurance) of this Contract, and that the applicable insurance carrier(s) has (have) been advised to defend, indemnify, and hold harmless the School District in accordance with the provisions of Paragraph 9.1 (Indemnification) and Section 10 (Insurance) of this Contract. The MEP & FP Engineer shall not decline to provide the School District with full protection and coverage under Paragraph 9.1 (Indemnification) and Section 10 (Insurance) of this Contract because some other contractor or consultant may, in whole or in part, be responsible for the occurrence, death, injury, damage, or loss to persons or property, or economic loss, damage, or expense, or because the School District may be a co-insured or an additional insured on some other contractor’s or consultant’s policy of insurance. The MEP & FP Engineer agrees that any violation of this Paragraph 10.1i. of Section 10 (Insurance) shall be deemed a material breach of this Contract.
Sample 1
Notice of Accidents, Claims and Suits. The Design Professional shall promptly notify the School District and the appropriate insurance company(ies) in writing of any accident(s) as well as any claim, suit or process received by the Design Professional arising in the course of operations under the Contract. The Design Professional shall forward such documents received to its insurance company(ies), as soon as practicable, or as required by their insurance policy or policies. The Design Professional shall advise the School District in writing, within ten
Sample 1

Related to Notice of Accidents, Claims and Suits

  • Claims and Suits (a) The Receiver shall have the right, in its discretion, to (i) defend or settle any claim or suit against the Assuming Bank with respect to which the Receiver has indemnified the Assuming Bank in the same manner and to the same extent as provided in Article XII, and (ii) defend or settle any claim or suit against the Assuming Bank with respect to any Liability Assumed, which claim or suit may result in a loss to the Receiver arising out of or related to this Agreement, or which existed against the Failed Bank on or before Bank Closing. The exercise by the Receiver of any rights under this Section 9.3(a) shall not release the Assuming Bank with respect to any of its obligations under this Agreement.

  • Notification of Incidents, Claims or Suits 21 CONTRACTOR shall report to COUNTY:

  • COMPLAINT AND GRIEVANCE PROCEDURE 1. When a member of the bargaining unit has any grievance or complaint, he shall forthwith convey to his immediate superior, orally with or without a member of the Association Executive or in writing, all facts relative to the grievance and/or complaint. The member and the superior shall make every attempt to resolve the problem at this preliminary stage.

  • Notice of Potential Claims The Contractor shall not be entitled to additional compensation or to extension of time for (1) any act or failure to act by the County Project Manager or the County, or (2) the happening of any event or occurrence, unless the Contractor has given the County a written Notice of Potential Claim within ten (10) days of the commencement of the act, failure, or event giving rise to the claim, and before final payment by the County. The written Notice of Potential Claim shall set forth the reasons for which the Contractor believes additional compensation or extension of time is due, the nature of the cost involved, and insofar as possible, the amount of the potential claim. Contractor shall keep full and complete daily records of the work performed, labor and material used, and all costs and additional time claimed to be additional.

  • Time limit for claims No Indemnified Party may make a Claim for indemnification under Section 6.1 in respect of any Claim unless notice in writing of the Claim, incorporating a statement setting out in reasonable detail the grounds on which the Claim is based, has been given by the Indemnified Party prior to the expiration of the applicable Survival Period as set forth in Part VI of Appendix B.

  • Notice of Claims If the City or Contractor receives notice of any claim or circumstances which could give rise to an indemnified loss, the receiving Party shall give written notice to the other Party within 30 days. The notice must include the following:

  • All Claims Must be Arbitrated It is the intention of the parties that this agreement bind all parties whose claims may arise out of or relate to treatment or service provided by the physician including any spouse or heirs of the patient and any children, whether born or unborn at the time of the occurrence giving rise to any claim. In the case of any pregnant mother, the term “patient” herein shall mean both the mother and the mother’s expected child or children. All claims for monetary damages exceeding the jurisdictional limit of the small court against the physician, and physician’s partners, associates, association, corporation partnership, and the employees, agents, and estates of any of them, must be arbitrated including, without limitation, claims for loss of consortium, wrongful death, emotional distress, or punitive damages. Filing any action in any court by the physician to collect any fee from the patient shall not waive the right to compel arbitration of any malpractice claim.

  • Notification of Claims In order that the indemnification provisions contained in this Section shall apply, upon the assertion of a claim for which either party may be required to indemnify the other, the party seeking indemnification shall promptly notify the other party of such assertion, and shall keep the other party advised with respect to all developments concerning such claim. The party who may be required to indemnify shall have the option to participate with the party seeking indemnification in the defense of such claim or to defend against said claim in its own name or in the name of the other party. The party seeking indemnification shall in no case confess any claim or make any compromise in any case in which the other party may be required to indemnify it except with the other party’s prior written consent.

  • Contractor Claims In the event of any demand by Contractor for (A) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract, (B) payment by the District of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or to which Contractor is not otherwise entitled to, or (C) an amount of payment disputed by the District, the parties shall attempt to resolve the dispute by those procedures set forth in Public Contract Code section 9204 and/or Article 1.5 (commencing with section 20104) of Chapter 1, Part, 3, Division 2, of the Public Contract Code, if applicable, the provisions of which are each attached hereto and incorporated herein by this reference. If a claim, or any portion thereof, remains in dispute upon satisfaction of all applicable dispute resolution requirements, the Contractor shall comply with all claims presentation requirements as provided in Chapter 1 (commencing with section 900) and Chapter 2 (commencing with section 910) of Part 3 of Division 3.6 of Title 1 of Government Code as a condition precedent to the Contractor’s right to bring a civil action against the District. For purposes of those provisions, the running of the time within which a claim must be presented to the District shall be tolled from the time the Contractor submits its written claim until the time the claim is denied, including any time utilized by any applicable meet and confer process. Pending resolution of the dispute, Contractor and its subcontractors shall continue to perform the Work under the Contract and shall not cause a delay of the Work during any dispute, claim, negotiation, mediation, or arbitration proceeding, except by written agreement of the District.

  • Complaints Procedure 18.1 If the Client has any cause for complaint in relation to the services provided by the Company, he should file a complaint as per the Company’s Complaint Handling policy which is available on the Company’s website.

Time is Money Join Law Insider Premium to draft better contracts faster.