Normal Weather Deemed Foreseeable Sample Clauses

Normal Weather Deemed Foreseeable. Normal seasonal weather conditions at and in the vicinity of the Project are, for all purposes relating to the Work, hereby deemed foreseeable. Therefore, the Contractor must accommodate in the proposed Master Construction Schedule the anticipated number of work days during which performance of the Work cannot occur or continue due to normal seasonal weather conditions (each a “Rain Day”). The number of Rain Days included in the Master Construction Schedule shall be determined by reference to weather data compiled by the National Oceanic and Atmospheric Administration that establishes the normal seasonal weather conditions for the general location of the Project Site and the time(s) of the year(s) during which the Work will be performed. The Contractor shall bear the risk attributable to all normal seasonal weather conditions, including, without limitation, precipitation, temperatures, winds, amount of daylight, et cetera.
Sample 1
AutoNDA by SimpleDocs
Normal Weather Deemed Foreseeable. Normal seasonal weather conditions at and in the vicinity of the Project are, for all purposes relating to the Work, hereby deemed foreseeable. Therefore, the Contractor must accommodate in the proposed Master Construction Schedule the anticipated number of work days during which performance of the Work cannot occur or continue due to normal seasonal weather conditions (each a “Rain Day”). The number of Rain Days included in the Master Construction Schedule shall be determined based on weather data compiled by the National Oceanic and Atmospheric Administration that establishes the normal seasonal weather conditions for the general location of the Project Site and the time(s) of the year(s) during which the Work will be performed. The Contractor shall bear the risk attributable to all normal seasonal weather conditions, including, without limitation, precipitation, temperatures, winds, amount of daylight, et cetera. The Contractor shall include anticipated Rain Days in the Master Construction Schedule and as part of the critical path of the Project. Any Rain Days not used in any given month may be saved and used in any other month as necessary. Under no circumstances, however, can any saved and unused Rain Day be utilized to extend the Contract Time. Contractor is only entitled to a weather-related extension of time once all Rain Days have been used, and as provided in Section 11.3.2 below.
Sample 1

Related to Normal Weather Deemed Foreseeable

  • FLORIDA CONVICTED/SUSPENDED/DISCRIMINATORY COMPLAINTS By submission of an offer, the respondent affirms that it is not currently listed in the Florida Department of Management Services Convicted/Suspended/Discriminatory Complaint Vendor List.

  • Unusual Job Requirements of Short Duration ‌ The nature of health care is such that at times it may be necessary for an employee to perform work not normally required in his/her job for the safety, health or comfort of a client or resident. It is understood that an employee shall not be expected to perform a task for which he/she is not adequately trained.

  • Other Unforeseen Conditions If unknown physical conditions are encountered at the Site that differ materially from those indicated in the Contract Documents, then the Contractor shall give notice to the Design Professional promptly before conditions are further disturbed, but in no event later than two business days after the first observance of the conditions. The Design Professional shall promptly investigate such conditions and, if they differ materially and cause an increase or decrease in the Contractor's cost or time required for performance of any part of the Work, the Design Professional may recommend an adjustment by Change Order to the Contract Sum or Contract Time, or both. If the Design Professional determines that the conditions at the Site are not materially different from those indicated in the Contract Documents and that no change in the terms of the Contract is justified, the Design Professional shall so notify the Owner and the Contractor in writing, stating the reasons. Protest by either party of the Design Professional’s decision shall be in accordance with Section 5, Part 2.

  • Rate Redetermination after Catastro- phic Damage In event of Catastrophic Damage and ad- justment, if any, of Included Timber, Contracting Officer shall make an appraisal to determine for each species the catastrophe-caused difference between the appraised unit value of Included Timber remaining immediately prior to the catastrophe and the appraised unit value of existing and potential Included Timber immediately after the ca- tastrophe. Included Timber is any that would not be elimi- nated under B8.32. Potential Included Timber is any that would be added under B8.32. Tentative Rates and Flat Rates in effect at the time of catastrophe shall be adjusted by said differences to be- come the redetermined rates for the purpose of a contract modification under B8.32. Accordingly, Base Rates shall be adjusted to correspond to the redetermined rates if redetermined rates are less than the original Base Rates, subject to new Base Rate limitations of 25 cents per hun- dred cubic feet or equivalent. However, existing Base In- dices shall not be changed under this Subsection. Upon agreement under B8.32, redetermined rates and Required Deposits shall be considered established under B3.1 for timber Scaled subsequent to Catastrophic Damage. At time of such appraisal, Specified Road construc- tion cost shall include the estimated cost of any construc- tion work listed in the Schedule of Items performed and abandoned.

  • De-commissioning due to Emergency 17.6.1 If, in the reasonable opinion of the Concessionaire, there exists an Emergency which warrants de-commissioning and closure of the whole or any part of the Bus Terminal, the Concessionaire shall be entitled to de- commission and close the whole or any part of the Bus Terminal to Users and passengers for so long as such Emergency and the consequences thereof warrant; provided that such de-commissioning and particulars thereof shall be notified by the Concessionaire to the Authority without any delay, and the Concessionaire shall diligently carry out and abide by any reasonable directions that the Authority may give for dealing with such Emergency.

  • Leave for Storms or Hazardous Conditions (a) Time lost by an employee as a result of absence or lateness due to storm conditions or because of the condition of public streets and highways or because an employee finds it necessary to seek permission to leave prior to the end of the regular shift must be:

  • Leave for Storm Or Hazardous Conditions It is the responsibility of the Nurse to make every reasonable effort to arrive at their work location as scheduled, however, during storm conditions, when such arrival is impossible, or delayed, all absent time will be deemed to be leave, and the Nurse has the option to:

  • Mileage Measurement Where required, the mileage measurement for LIS rate elements is determined in the same manner as the mileage measurement for V&H methodology as outlined in NECA Tariff No. 4.

  • Teaching Loads The range of teaching loads, number of preparations and number of pupil contacts required should provide for effective instruction and meaningful teacher-student interaction. DPS and the Association agree to work together to seek increased state funding to decrease class size. The principal shall report to the CSC, after the roster verification process, the number of students in each class and this will be published in the CSC minutes on the school’s website. For the purposes of this section, a “class” shall be defined as any general education, including electives and model one classes. Upon request, after the roster verification process, the District shall provide the Association with the student information management system data regarding class enrollment.

  • Switching System Hierarchy and Trunking Requirements For purposes of routing ECI traffic to Verizon, the subtending arrangements between Verizon Tandem Switches and Verizon End Office Switches shall be the same as the Tandem/End Office subtending arrangements Verizon maintains for the routing of its own or other carriers’ traffic (i.e., traffic will be routed to the appropriate Verizon Tandem subtended by the terminating End Office serving the Verizon Customer). For purposes of routing Verizon traffic to ECI, the subtending arrangements between ECI Tandem Switches and ECI End Office Switches shall be the same as the Tandem/End Office subtending arrangements that ECI maintains for the routing of its own or other carriers’ traffic.

Time is Money Join Law Insider Premium to draft better contracts faster.