Construction Cost and Cost Estimates Sample Clauses

Construction Cost and Cost Estimates. 6.1 Cost Estimates. Client and Engineer acknowledge that Engineer has no control over cost of labor, materials, equipment or services furnished by others, over contractors’ methods of determining prices, or other competitive bidding or market conditions and that Engineer’s estimates of Project construction cost will be made on the basis of its employees’ experience and qualifications and will represent Engineer’s employees’ best judgment as experienced and qualified professionals, familiar with the construction industry. Engineer does not guarantee that proposal, bids, or actual construction cost will not vary from its estimates of Project cost and Client acknowledges the same.
AutoNDA by SimpleDocs
Construction Cost and Cost Estimates 

Related to Construction Cost and Cost Estimates

  • Construction Costs Under no circumstances shall the Consultant be liable for extra costs or other consequences due to unknown conditions or related to the failure of contractors to perform work in accordance with the plans and specifications. Consultant shall have no liability whatsoever for any costs arising out of the Client’s decision to obtain bids or proceed with construction before the Consultant has issued final, fully-approved plans and specifications. The Client acknowledges that all preliminary plans are subject to substantial revision until plans are fully approved and all permits obtained.

  • Construction Contract; Cost Budget Prior to execution of a construction contract, Tenant shal] submit a copy of the proposed contract with the Contractor for the construction of the Tenant Improvements, including the genera] conditions with Contractor (the “Contract”) to Landlord for its approval, which approval shall not be unreasonably withheld, conditioned or delayed. Following execution of the Contract and prior to commencement of construction, Tenant shall provide Landlord with a fully executed copy of the Contract for Landlord’s records. Prior to the commencement of the construction of the Tenant Improvements, and after Tenant has accepted all bids and proposals for the Tenant Improvements, Tenant shall provide Landlord with a detailed breakdown, by trade, for all of Tenant’s Agents, of the final estimated costs to be incurred or which have been incurred in connection with the design and construction of the Tenant Improvements to be performed by or at the direction of Tenant or the Contractor (the “Construction Budget”), which costs shall include, but not be limited to, the costs of the Architect’s and Engineers’ fees and the Landlord Coordination Fee. The amount, if any, by which the total costs set forth in the Construction Budget exceed the amount of the Tenant Improvement Allowance is referred to herein as the “Over Allowance Amount”. In the event that an Over-Allowance Amount exists, then prior to the commencement of construction of the Tenant Improvements, Tenant shall supply Landlord with cash in an amount equal to the Over- Allowance Amount. The Over-Allowance Amount shall be disbursed by Landlord prior to the disbursement of any of the then remaining portion of the Tenant Improvement Allowance, and such disbursement shall be pursuant to the same procedure as the Tenant Improvement Allowance. In the event that, after the total costs set forth in the Construction Budget have been delivered by Tenant to Landlord, the costs relating to the design and construction of the Tenant Improvements shall change, any additional costs for such design and construction in excess of the total costs set forth in the Construction Budget shall be added to the Over-Allowance Amount and the total costs set forth in the Construction Budget, and such additional costs shall be paid by Tenant to Landlord immediately as an addition to the Over-Allowance Amount or at Landlord’s option, Tenant shall make payments for such additional costs out of its own funds, but Tenant shall continue to provide Landlord with the documents described in items (1), (ii), (iii) and (iv) of Section 2.2.2.1 of this Tenant Work Letter, above, for Landlord’s approval, prior to Tenant paying such costs. All Tenant Improvements paid for by the Over-Allowance Amount shall be deemed Landlord’s property under the terms of the Lease. 4.2.2

  • Project Costs Simultaneously with the execution of this Agreement, the Company shall disclose to the Department all of the Project Costs which the Company seeks to include for purposes of determining the limitation of the amount of the Credit pursuant to Section 5-30 of the Act and provide to the Department a Schedule of Project Costs in the form as attached hereto as Exhibit C.

  • Direct Costs Insert the major cost elements. For each element, consider the application of the paragraph entitled “Costs Requiring Prior Approval” on page 1 of these instructions.

  • Tenant Improvement Costs The Tenant Improvements’ cost (the “Tenant Improvement Costs”) shall mean and include any and all costs and expenses of the Work, including, without limitation, all of the following:

  • Construction Budget The total amount indicated by the District for the Project plus all other costs, including design, construction, administration, financing, and all other costs.

  • Construction Allowance (a) Landlord shall provide to Tenant a construction allowance not to exceed $135.00 per rentable square foot in the Relocation Premises (the “Construction Allowance”) to be applied toward the Total Construction Costs, as adjusted for any changes to the Tenant Work. If the Total Construction Costs are estimated to exceed the Construction Allowance by more than $5.00 per rentable square foot of the Relocation Premises, then no advance of the Construction Allowance shall be made by Landlord until Tenant has first paid to the contractor from its own funds (and provided reasonable evidence thereof to Landlord) the anticipated amount by which the projected Total Construction Costs exceed the amount of the Construction Allowance. Thereafter, Landlord shall pay to Tenant (or at Tenant’s request directly to Tenant’s general contractor) the Construction Allowance in multiple disbursements (but not more than once in any calendar month) following the receipt by Landlord of the following items: (i) a request for payment and sworn statements of Tenant and contractor, (ii) final or partial lien waivers, as the case may be, from all persons performing work or supplying or fabricating materials for the Tenant Work, fully executed, acknowledged and in recordable form, which waivers may be conditioned upon receipt of payment, (iii) the Architect’s certification that the Tenant Work for which reimbursement has been requested has been finally completed, including (with respect to the last application for payment only) any punch-list items, on the appropriate AIA form or another form approved by Landlord, and, (iv) with respect to the disbursement of the last 10% of the Construction Allowance, (1) the permanent certificate of occupancy issued for the Relocation Premises, if required by applicable law, (2) the record drawing in CAD format, PDF format and hard copy required by Section 5 above, and (3) an estoppel certificate confirming such factual matters as Landlord or Landlord’s Mortgagee may reasonably request (collectively, a “Completed Application for Payment”). Landlord shall pay the amount requested in the applicable Completed Application for Payment to Tenant within 30 days following Tenant’s submission of the Completed Application for Payment. If, however, the Completed Application for Payment is incomplete or incorrect, Landlord shall promptly notify Tenant of the same and Landlord’s payment of such request shall be deferred until 30 days following Landlord’s receipt of the corrected Completed Application for Payment. Notwithstanding anything to the contrary contained in this Exhibit, Landlord shall not be obligated to make any disbursement of the Construction Allowance during the pendency of any of the following: (1) Landlord has received written notice of any unpaid claims relating to any portion of the Tenant Work or materials in connection therewith covered by previously funded applications for payment, (2) there is an unbonded lien outstanding against the Building or the Relocation Premises or Tenant’s interest therein by reason of work done, or claimed to have been done, or materials supplied or specifically fabricated, claimed to have been supplied or specifically fabricated, to or for Tenant or the Relocation Premises, (3) the conditions to the advance of the Construction Allowance are not satisfied, or (4) Tenant is in Default under the Lease.

  • Operating Costs The Assuming Institution agrees, during its period of use of any Leased Data Management Equipment, to pay to the Receiver or to appropriate third parties at the direction of the Receiver all operating costs with respect thereto and to comply with all relevant terms of any existing Leased Data Management Equipment leases entered into by the Failed Bank, including without limitation the timely payment of all rent, taxes, fees, charges, maintenance, utilities, insurance and assessments.

  • Tenant Improvement Allowance Items Except as otherwise set forth in this Tenant Work Letter, the Tenant Improvement Allowance shall be disbursed by Landlord only for the following items and costs (collectively the “Tenant Improvement Allowance Items”):

  • Tenant’s Costs Tenant agrees to reimburse or pay Landlord within thirty (30) days after invoice from Landlord for (a) any cleaning expenses incurred by Landlord (to the extent requested by Tenant or as required by Landlord if Landlord reasonably determines that Tenant has failed to maintain the Premises in the condition required by the terms of this Lease, and following not less than five (5) Business Days written notice to Tenant, and Tenant’s failure to correct such failure to Landlord’s reasonable satisfaction with such time period), including carpet cleaning, garbage and trash removal expenses, over and above the normal cleaning provided by Landlord, if any, or due to the presence of a lunchroom or kitchen or food or beverage dispensing machines within the Premises, (b) any expense incurred by Landlord for usage in the Premises of heating, ventilating and air conditioning services, elevator services, electricity, water, janitorial services, or any other services or utilities over and above the normal usage (on a per rentable square foot basis) for the Building, (c) any expense incurred by Landlord relating to or arising out of the usage by Tenant or Tenant’s Agents of the public or common areas of the Building or Land, or any of the equipment contained therein, which usage is over and above the normal usage for such public or common areas or equipment, and (d) any other direct expense incurred by Landlord on Tenant’s behalf. The normal cleaning to be provided by Landlord to the Premises is described in Exhibit G. Landlord reserves the right to install and activate separate metering of electricity, water or other utilities to the Premises, and Tenant agrees to reimburse or pay Landlord within twenty (20) Business Days after invoice from Landlord for the reasonable, actual and documented costs of such separate metering, in which case the Base Amount Allocable to the Premises and Operating Costs shall be adjusted accordingly. If Tenant desires any of the services specified in this paragraph 3.4.8, at a time other than Normal Business Hours (hereinafter defined), then such services shall be supplied to Tenant upon the written request of Tenant delivered to Landlord before 3:00 p.m. on the Business Day preceding such extra usage, and Tenant shall pay to Landlord the actual cost of such services within thirty (30) days after Landlord has delivered to Tenant an invoice therefor. The costs incurred by Landlord in providing HVAC service to Tenant at a time other than Normal Business Hours, shall include costs for electricity, water, sewage, water treatment, labor, metering, filtering, and maintenance reasonably allocated by Landlord to providing such service. Notwithstanding the foregoing, in the event that Tenant desires HVAC service on a Requested Saturday Morning between the hours of 9:00 a.m. to 1:00 p.m., and provided that Tenant delivers a written request to Landlord prior to 3:00 p.m. on the Business Day preceding the Requested Saturday Morning on which such HVAC service is requested in which Tenant specifies the hours during which such HVAC service is requested, Landlord shall provide HVAC service to the Premises at no additional charge to Tenant during the requested period between 9:00 a.m. to 1:00 p.m. on such Saturday morning (the “Requested Saturday Morning”). As used in this Lease, the term “Normal Business Hours” means 8:00 a.m. to 6:00 p.m. on Business Days

Draft better contracts in just 5 minutes Get the weekly Law Insider newsletter packed with expert videos, webinars, ebooks, and more!