Compensable Delay – Delay by Owner or Program Manager Sample Clauses

Compensable Delay – Delay by Owner or Program Manager. If the Design-Builder is delayed in the progress of the Work between the Proceed Order and the Material Completion and Occupancy Date, as amended, by an act or neglect of the Owner, Owner's employees, Program Manager or Separate Design-Builders employed by the Owner, or by labor disputes not reasonably anticipated, or by other causes beyond the Design-Builder's control which the Program Manager determines may justify delay, then the Contract Time will be extended by Change Order for such reasonable time as the Program Manager and the Owner may determine; provided, however, that (i) such delays extend the Overall Project Schedule’s critical path; (ii) the Design-Builder has taken all reasonable actions to mitigate the effects of the delay on the Work; (iii) the fault or negligence of the Design-Builder, the Design-Builder's agents or employees did not materially contribute to such causes; and (iv) the Design-Builder shall have notified Owner of the cause or causes of such delay within fourteen days from the date on which the Design-Builder first becomes aware of such delay. Extensions of Time and compensation for Time Dependent Overhead Costs for Unavoidable Delay are to be processed as a Change Order pursuant to Article 3.4.6.
Sample 1Sample 2Sample 3See All (13)
AutoNDA by SimpleDocs

Related to Compensable Delay – Delay by Owner or Program Manager

  • Force Majeure, Notice of Delay, and No Damages for Delay The Contractor will not be responsible for delay resulting from its failure to perform if neither the fault nor the negligence of the Contractor or its employees or agents contributed to the delay and the delay is due directly to acts of God, wars, acts of public enemies, strikes, fires, floods, or other similar cause wholly beyond the Contractor’s control, or for any of the foregoing that affect subcontractors or suppliers if no alternate source of supply is available to the Contractor. In case of any delay the Contractor believes is excusable, the Contractor will notify the Department or Customer in writing of the delay or potential delay and describe the cause of the delay either (1) within 10 days after the cause that creates or will create the delay first arose, if the Contractor could reasonably foresee that a delay could occur as a result, or (2) if delay is not reasonably foreseeable, within five days after the date the Contractor first had reason to believe that a delay could result. The foregoing will constitute the Contractor’s sole remedy or excuse with respect to delay. Providing notice in strict accordance with this paragraph is a condition precedent to such remedy. No claim for damages will be asserted by the Contractor. The Contractor will not be entitled to an increase in the Contract price or payment of any kind from the Department or Customer for direct, indirect, consequential, impact or other costs, expenses or damages, including but not limited to costs of acceleration or inefficiency, arising because of delay, disruption, interference, or hindrance from any cause whatsoever. If performance is suspended or delayed, in whole or in part, due to any of the causes described in this paragraph, after the causes have ceased to exist the Contractor will perform at no increased cost, unless the Department or Customer determines, in its sole discretion, that the delay will significantly impair the value of the Contract to the State of Florida or to Customers, in which case the Department or Customer may (1) accept allocated performance or deliveries from the Contractor, provided that the Contractor grants preferential treatment to Customers with respect to commodities or contractual services subjected to allocation, or (2) purchase from other sources (without recourse to and by the Contractor for the related costs and expenses) to replace all or part of the commodity or contractual services that are the subject of the delay, which purchases may be deducted from the Contract quantity, or (3) terminate the Contract in whole or in part.

  • Excusable Delays Except with respect to defaults of subproviders, the Engineer shall not be in default by reason of any failure in performance of this contract in accordance with its terms (including any failure to progress in the performance of the work) if such failure arises out of causes beyond the control and without the default or negligence of the Engineer. Such causes may include, but are not restricted to, acts of God or the public enemy, acts of the Government in either its sovereign or contractual capacity, fires, floods, epidemics, quarantine restrictions, strikes, freight embargoes, and unusually severe weather.

  • Excusable Delay The Contractor is entitled to an equitable adjustment of time, issued via Change Order, for delays caused by the following:

  • Cyber incident damage assessment activities If DoD elects to conduct a damage assessment, the Contracting Officer will request that the Contractor provide all of the damage assessment information gathered in accordance with paragraph (e) of this clause.

  • CONSTRUCTION OF THE BUS TERMINAL 12.1 Obligations prior to commencement of construction Prior to commencement of Construction Works, the Concessionaire shall:

  • Independence from Material Breach Determination Except as set forth in Section X.D.1.c, these provisions for payment of Stipulated Penalties shall not affect or otherwise set a standard for OIG’s decision that CHSI has materially breached this CIA, which decision shall be made at OIG’s discretion and shall be governed by the provisions in Section X.D, below.

  • Union Activity on Premises and/or Access to Premises The Union agrees that neither it, nor its officers, agents, representatives and members will engage in the solicitation of members, holding of meetings or any other Union activities on Hospital premises or on Hospital time without the prior approval of the Hospital, except as specifically provided for in this Agreement. Such approval will not be unreasonably denied.

  • CONTRACTOR RESPONSIBILITY FOR SYSTEM AGENCY’S TERMINATION COSTS If the System Agency terminates the Contract for cause, the Contractor shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Contractor. These costs include, but are not limited to, the costs of procuring a substitute vendor and the cost of any claim or litigation attributable to Contractor’s failure to perform any Work in accordance with the terms of the Contract.

  • PERFORMING AGENCY RESPONSIBILITY FOR SYSTEM AGENCY’S TERMINATION COSTS If the System Agency terminates the Contract for cause, the Performing Agency shall be responsible to the System Agency for all costs incurred by the System Agency and the State of Texas to replace the Performing Agency. These costs include, but are not limited to, the costs of procuring a substitute vendor and the cost of any claim or litigation attributable to Performing Agency’s failure to perform any Work in accordance with the terms of the Contract.

  • Deadlines for Providing Insurance Documents after Renewal or Upon Request As set forth herein, certain insurance documents must be provided to the OGS Procurement Services contact identified in the Contract Award Notice after renewal or upon request. This requirement means that the Contractor shall provide the applicable insurance document to OGS as soon as possible but in no event later than the following time periods:  For certificates of insurance: 5 business days  For information on self-insurance or self-retention programs: 15 calendar days  For other requested documentation evidencing coverage: 15 calendar days  For additional insured and waiver of subrogation endorsements: 30 calendar days Notwithstanding the foregoing, if the Contractor shall have promptly requested the insurance documents from its broker or insurer and shall have thereafter diligently taken all steps necessary to obtain such documents from its insurer and submit them to OGS, OGS shall extend the time period for a reasonable period under the circumstances, but in no event shall the extension exceed 30 calendar days.

Time is Money Join Law Insider Premium to draft better contracts faster.