Claim Format Sample Clauses

Claim Format. All Claims must be in writing and sent to County by registered or certified mail, return receipt requested. The Claim submitted by Contractor shall include, but not be limited to, the following: (a) A cover letter and certification under penalty of perjury of the accuracy of the contents of the Claim; (b) A summary of the Claim including underlying facts, entitlement, schedule analysis, quantum calculations and Contract provisions supporting relief; (c) A list of documents relating to the Claim including Specifications, Drawings, Requests for Clarification/RFIs, schedules, notices of delay, cost calculations and spreadsheets, and any other relevant documents: (d) A chronology of events and correspondence; (e) An analysis of Claim merit; (f) An analysis of Claim cost; and (g) All supporting documents referenced in (c).
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Claim Format. A. Contractor shall submit the formal claim(s) with a cover letter and certification of the accuracy of the formal claim.
Sample 1
Claim Format. Any claim for an equitable adjustment of the Contract Price and/or the Contract Time of performance, including but not limited to changes ordered by either the Owner or Contractor must be made in writing with detailed breakdown as required by the Contract Documents. Pricing must be prepared according to the labor rates and equipment rates established in the PROJECT SUBCONTRACT AGREEMENT.
Sample 1
Claim Format. The Contractor shall submit the Claim justification in the following format:
Sample 1
Claim Format. All Claims must be in writing and sent to County by registered or certified mail, return receipt requested. The Claim submitted by Developer shall include, but not be limited to, the following: (a) a cover letter and certification under penalty of perjury of the accuracy of the contents of the Claim; (b) a summary of the Claim including underlying facts, entitlement, schedule analysis, quantum calculations and Agreement provisions supporting relief;
Sample 1

Related to Claim Format

  • Claim Form i. Within 15 days after receiving a notice of a claim, you or your Dental Provider will be provided with a Claim Form to make claim for Benefits. To make a claim, the form should be completed and signed by the Provider who performed the services, and by the patient (or the parent or guardian if the patient is a minor), and submitted to the address above.

  • Sending a Claim Notice Before beginning a lawsuit, mediation or arbitration, you and we agree to send a written notice (a claim notice) to each party against whom a claim is asserted, in order to provide an opportunity to resolve the claim informally or through mediation. Go to xxxxxxxxxxxxxxx.xxx/ claim for a sample claim notice. The claim notice must describe the claim and state the specific relief demanded. Notice to you may be provided by your billing statement or sent to your billing address. Notice to us must include your name, address and Account number and be sent to American Express ADR c/o CT Corporation System, 00 Xxxxxxx Xxxxxx, Xxx Xxxx, Xxx Xxxx 00000. If the claim proceeds to arbitration, the amount of any relief demanded in a claim notice will not be disclosed to the arbitrator until after the arbitrator rules.

  • Claims Submission We will submit your claims and assist you in any way we reasonably can to help get your claims paid. Your insurance company may need you to supply certain information directly. It is your responsibility to comply with their request. Please be aware that the balance of your claim is your responsibility whether or not your insurance company pays your claim. Your insurance benefit is a contract between you and your insurance company; we are not party to that contract.

  • Indemnification Process 20.2.1 As used in this Section 20, “Indemnified Person” means a person whom an Indemnifying Party is obligated to indemnify, defend and/or hold harmless under Section 20.1.

  • Product Claims You acknowledge that Company, not an App Distributor, is responsible for addressing any claims of yours or any third party relating to the Company application or your possession and/or use of the Company application, including, but not limited to: (i) product liability claims; (ii) any claim that the Company application fails to conform to any applicable legal or regulatory requirement; and (iii) claims arising under consumer protection or similar legislation. (5)

  • Claim of Infringement In the event that use of any facilities or equipment (including software), becomes, or in the reasonable judgment of the Party who owns the affected network is likely to become, the subject of a claim, action, suit, or proceeding based on intellectual property infringement, then said Party shall promptly and at its sole expense and sole option, but subject to the limitations of liability set forth below:

  • Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.

  • Claim Procedure Any Person entitled to indemnification hereunder shall (i) give prompt written notice to the indemnifying party of any claim with respect to which it seeks indemnification (provided that the failure to give prompt notice shall impair any Person’s right to indemnification hereunder only to the extent such failure has prejudiced the indemnifying party) and (ii) unless in such indemnified party’s reasonable judgment a conflict of interest between such indemnified and indemnifying parties may exist with respect to such claim, permit such indemnifying party to assume the defense of such claim with counsel reasonably satisfactory to the indemnified party. If such defense is assumed, the indemnifying party shall not be subject to any liability for any settlement made by the indemnified party without its consent (but such consent shall not be unreasonably withheld, conditioned or delayed). An indemnifying party who is not entitled to, or elects not to, assume the defense of a claim shall not be obligated to pay the fees and expenses of more than one counsel for all parties indemnified by such indemnifying party with respect to such claim, unless in the reasonable judgment of any indemnified party a conflict of interest may exist between such indemnified party and any other of such indemnified parties with respect to such claim. In such instance, the conflicted indemnified parties shall have a right to retain one separate counsel, chosen by the Holders representing a majority of the Registrable Securities included in the registration if such Holders are indemnified parties, at the expense of the indemnifying party.

  • Indemnification for Suits or Claims for Intellectual Property Infringement The Contractor shall indemnify and hold the Owner harmless from any suits or claims of infringement of any patent rights, trademarks or copyrights arising out of any patented, trademarked, or copyrighted materials, methods, or systems used by the Contractor.

  • NOTICE OF THIRD PARTY CLAIMS Pursuant to Public Contract Code Section 9201, District shall provide Contractor timely notification of the receipt of any third-party claim relating to this Contract. District shall be entitled to recover its reasonable costs incurred in providing such notification.

Time is Money Join Law Insider Premium to draft better contracts faster.