NO WORK STOPPAGES 5. It is understood and agreed that during the term of this Agreement neither the Union nor any person covered hereunder shall engage in a strike, slowdown or work stoppage against the City and County of San Francisco, nor shall the Union or any person covered hereunder honor any picket line of any other group of City employees who are obliged under a contractual no strike provision or any provisions of the City Charter to refrain from strikes, slowdowns, or work stoppages against the City and County of San Francisco.
WORK STOPPAGES Matters subject to the procedures of this Article shall be settled and resolved in the manner provided herein. During the term of this Agreement, there shall be no cessation or stoppage of work, lockout, picketing or boycotts, except that this limitation shall not be binding upon either party hereto if the other party refuses to perform any obligation under this Article or refuses or fails to abide by, accept or perform a decision or award of an arbitrator.
WORK STOPPAGE There has not been, and there is not currently, any labour trouble which is having a Material Adverse Effect or could reasonably be expected to have a Material Adverse Effect.
OF WORK The following provision designating regular hours on a daily tour and regular daily tours over the nursing schedule determined by the Hospital shall not be construed to be a guarantee of the hours of work to be performed on each tour or during each tour schedule. Subject to Article below:
Change in Scope of Work Any change in the scope of the Work, method of performance, nature of materials or price thereof, or any other matter materially affecting the performance or nature of the Work shall not be paid for or accepted unless such change, addition, or deletion is approved in advance and in writing by a valid change order executed by the District. Contractor specifically understands, acknowledges, and agrees that the District shall have the right to request any alterations, deviations, reductions, or additions to the Project or Work, and the cost thereof shall be added to or deducted from the amount of the Contract Price by fair and reasonable valuations. Contractor also agrees to provide the District with all information requested to substantiate the cost of the change order and to inform the District whether the Work will be done by the Contractor or a subcontractor. In addition to any other information requested, Contractor shall submit, prior to approval of the change order, its request for a time extension (if any), as well as all information necessary to substantiate its belief that such change will delay the completion of the Work. If Contractor fails to submit its request for a time extension or the necessary supporting information, it shall be deemed to have waived its right to request such extension.
Commencement of Work Engineer shall not commence any field work under this Contract until he/she/it has obtained all required insurance and such insurance has been approved by County. As further set out below, Engineer shall not allow any subcontractor/subconsultant(s) to commence work to be performed in connection with this Contract until all required insurance has been obtained and approved and such approval shall not be unreasonably withheld. Approval of the insurance by County shall not relieve or decrease the liability of Engineer hereunder.
Completion of Work Contractor is accountable for completing the Work within the Contract Time stated in the Contract, or as otherwise amended by Change Order.
Contract Work The provision of goods and services identified in the Contract constitute the contract work (Contract Work). Contractor shall perform the Contract Work pursuant to the terms of the Contract. Contractor shall furnish all labor, materials, equipment, tools, transportation, services, appliances, and appurtenances for the Contract Work in strict conformity with this Contract, within the time-period prescribed by the City.
Work of the Bargaining Unit (a) In order to protect the standard of nursing care, the Employer shall not contract out the work normally performed by members of this bargaining unit except:
Scope of Work The Contractor has overall responsibility for and shall provide and furnish all materials, equipment, tools and labor as necessary or reasonably inferable to complete the Work, or any phase of the Work, in accordance with the Owner’s requirements and the terms of the Contract Documents.
