Construction and Enforcement This Agreement shall be construed in accordance with the laws of the State of Florida, without and application of the principles of conflicts of laws. If it becomes necessary for any party to institute legal action to enforce the terms and conditions of this Agreement, and such legal action results in a final judgment in favor of such party ("Prevailing Party"), then the party or parties against whom said final judgment is obtained shall reimburse the Prevailing Party for all direct, indirect or incidental expenses incurred, including, but not limited to, all attorney's fees, court costs and other expenses incurred throughout all negotiations, trials or appeals undertaken in order to enforce the Prevailing Party's rights hereunder. Any suit, action or proceeding with respect to this Agreement shall be brought in the state or federal courts located in St. Lucie County in the State of Florida. The parties hereto hereby accept the exclusive jurisdiction and venue of those courts for the purpose of any such suit, action or proceeding. The parties hereto hereby irrevocably waive, to the fullest extent permitted by law, any objection that any of them may now or hereafter have to the laying of venue of any suit, action or proceeding arising out of or relating to this Agreement or any judgment entered by any court in respect thereof brought in St. Lucie County, Florida, and hereby further irrevocably waive any claim that any suit, action or proceeding brought in St. Lucie County, Florida, has been brought in an inconvenient forum.
Interpretation and Enforcement 1. The Parties shall take all appropriate measures, whether general or specific, to ensure fulfilment of the obligations arising out of this Agreement and shall refrain from any measures which would jeopardise attainment of the objectives of this Agreement.
Compliance and Enforcement If Contractor willfully fails to comply with any of the provisions of the LBE Ordinance, the rules and regulations implementing the LBE Ordinance, or the provisions of this Agreement pertaining to LBE participation, Contractor shall be liable for liquidated damages in an amount equal to Contractor’s net profit on this Agreement, or 10% of the total amount of this Agreement, or $1,000, whichever is greatest. The Director of the City’s Human Rights Commission or any other public official authorized to enforce the LBE Ordinance (separately and collectively, the “Director of HRC”) may also impose other sanctions against Contractor authorized in the LBE Ordinance, including declaring the Contractor to be irresponsible and ineligible to contract with the City for a period of up to five years or revocation of the Contractor’s LBE certification. The Director of HRC will determine the sanctions to be imposed, including the amount of liquidated damages, after investigation pursuant to Administrative Code §14B.17. By entering into this Agreement, Contractor acknowledges and agrees that any liquidated damages assessed by the Director of the HRC shall be payable to City upon demand. Contractor further acknowledges and agrees that any liquidated damages assessed may be withheld from any monies due to Contractor on any contract with City. Contractor agrees to maintain records necessary for monitoring its compliance with the LBE Ordinance for a period of three years following termination or expiration of this Agreement, and shall make such records available for audit and inspection by the Director of HRC or the Controller upon request.
Remedies and Enforcement A. Executive acknowledges and agrees that the Company's remedy at law for a breach of any of the provisions of Section 7 herein would be inadequate and the breach shall be per se deemed as causing irreparable harm to the Company. In recognition of this fact, in the event of a breach by Executive of any of the provisions of Section 7, Executive agrees that, in addition to any remedy at law available to the Company, including, but not limited to monetary damages, the Company, without posting any bond, shall be entitled to obtain equitable relief in the form of specific performance, temporary restraining order, temporary or permanent injunction or any other equitable remedy which may then be available to the Company.
Audits, Inspection and Enforcement From time to time, COUNTY may inspect the facilities, systems, books and records of Business Associate to monitor compliance with this Agreement and this Addendum. Business Associate shall promptly remedy any violation of any provision of this Addendum and shall certify the same to the COUNTY Compliance Officer in writing. The fact that COUNTY inspects, or fails to inspect, or has the right to inspect, Business Associate’s facilities, systems and procedures does not relieve Business Associate of its responsibility to comply with this Addendum, nor does COUNTY:
Governing law and enforcement (a) The choice of English law as the governing law of the Finance Documents will be recognised and enforced in its jurisdiction of incorporation.