Delay Period shall have the meaning set forth in Section 5 hereof.
Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.
Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.
Daily Delay Damages means with respect to a Guaranteed Project Milestone, an amount equal to (a) the Project Development Security Amount posted as of the first date that Daily Delay Damages are payable under this Agreement with respect to such Guaranteed Project Milestone, divided by (b) 120.
Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.
Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, material litigation by parties other than the Parties not caused by the Parties’ failure to perform, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable party using reasonable diligence to overcome which prevents such party from performing its specific duties or obligation hereunder in a timely manner.
Tenant Delays A "Tenant Delay" shall mean any delay in Substantial Completion of the Building as a result of any of the following: (i) Tenant's failure to complete or approve the Tenant Improvement Plans by the dates set forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction by the dates set forth in Section 5.C, (iii) changes to either the Shell Plans and Specifications or the Tenant Improvement Plans requested by Tenant which delay the progress of the work, (iv) Tenant's request for materials, components or finishes which are not available in a commercially reasonable time given the target Commencement Date, (v) Tenant's failure to make a progress payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's request for more than one (1) rebidding of the cost of all or a portion of the work, and (vii) any errors or omissions in the Tenant Improvement Plans provided by Tenant's architect. In the event Landlord believes Tenant is causing a Tenant Delay, Landlord shall notify Tenant in writing, state the action or inaction that it believes is causing the Tenant Delay, and state the date from which a Tenant Delay is being calculated. Claim of Tenant Delay shall be made within five (5) days after Landlord's discovery of the occurrence of the event giving rise to such claim. Tenant shall have the right to expedite work, at its sole cost, to minimize the effect of any Tenant Delays, to the extent it is practicable to do so. However, no Tenant Delay shall advance the Commencement Date to a date before the estimated Commencement Date of October 1, 2001. Notwithstanding anything to the contrary set forth in this Lease and regardless of the actual date the Premises are Substantially Complete (but subject to the limitation in the preceding sentence), the Commencement Date shall be deemed to be the date the Commencement Date would have occurred if no Tenant Delay had occurred as reasonably determined by Landlord. In addition, if a Tenant Delay results in an increase in the cost of the labor or materials, Tenant shall pay the cost of such increases.
Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:
Excused Downtime means the number of minutes in the Charging Period, rounded to the nearest minute that the link state of Customer’s Port is ‘down’ due to:
Commissioning Period means, with respect to each Subproject, the period commencing upon the first delivery of Feed Gas to the Subproject in accordance with Sections 4.8 and 11.1 of the Agreement continuing through achievement of RFSU, commissioning, Start Up, Performance Testing and achievement of Substantial Completion for such Subproject.
Service Level Failure means a failure to perform the Software Support Services fully in compliance with the Support Service Level Requirements.
Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,
Substantial Completion Date means the required date for Substantial Completion of the Project. The Substantial Completion Date can be adjusted only by written Change Order.
Construction Period means the period commencing from the Appointed Date and ending on the date of the Completion Certificate;
Completion Period means the period starting from the date of issue of "Order" and required to complete the work in all respect.
Final Completion Date means the date on which Final Completion occurs.
Quarterly Commencement Date means the 1st day of each of April, July, October and January in each year.
Project Year means the 12 month period beginning from the Effective Date and ending 12 months thereafter and each successive 12 month period following thereafter;
Framework Commencement Date means [insert date dd/mm/yyyy];
Service Failure means a failure by the Contractor to provide the Services in accordance with any individual service level described above (measured on a monthly/quarterly/annual basis)
Milestone Failure means a failure by the Grant Recipient fully to achieve any Milestone by the relevant Milestone Date;
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Rectification Period means the period of time set out in Section 4.3 of this RFP during which a Proponent will be permitted to rectify its Proposal to satisfy the mandatory submission requirements of this RFP.