TERMINATION BY LANDLORD definition

TERMINATION BY LANDLORD. LANDLORD reserves the right to terminate this agreement with a SIXTY (60) day written notice to BROKER. In the event this agreement is terminated by LANDLORD, the BROKER's rights provided for in this agreement shall survive such termination. All monies expended by BROKER shall be paid to BROKER prior to this cancellation and BROKER is authorized to withhold any sums owed to BROKER from monies held prior to the final disbursement to LANDLORD. An additional cancellation fee of $195.00 will be charged to LANDLORD should LANDLORD terminate this agreement for any reason. If BROKER has not procured a TENANT within 90 days of the property being fully available for rent, LANDLORD may terminate this Agreement with no penalty.
Sample 1

Examples of TERMINATION BY LANDLORD in a sentence

  • SCHEDULE 3Residential Tenancies Act 1995—Section 91(1) (Residential Tenancies (General) Regulations 1995—Regulation 12(2)) NOTICE OF TERMINATION BY LANDLORD FOR A PERIODIC TENANCY (GENERAL FORM) (Note: A landlord cannot use this form to terminate a fixed-term tenancy (except under section 82 of the Act)—Application must be made to the Residential Tenancies Tribunal) To: .

  • Any attempted assignment, delegation, or transfer in violation of this Section shall be void and have no force or effect whatsoever, and at LANDLORD’S sole discretion, is grounds for TERMINATION BY LANDLORD under Section 28 TERMINATION BY LANDLORD of this Agreement.

  • Any attempted assignment, transfer of ownership interest, or delegation in violation of this Section shall be void and have no force or effect whatsoever, and at LANDLORD’s sole discretion, is grounds for Termination by LANDLORD under SECTION 35 TERMINATION BY LANDLORD of this Agreement.

  • TERMINATION BY LANDLORD: Termination is effective when actually physically received by BROKER BY CERTIFIED MAIL.

  • Any attempted assignment, delegation, or transfer in violation of this Section shall be void and have no force or effect whatsoever, and at LANDLORD’S sole discretion, is grounds for TERMINATION BY LANDLORD under Section 31 TERMINATION BY LANDLORD of this Agreement.

  • Any attempted assignment, delegation, or transfer in violation of this Section shall be void and have no force or effect whatsoever, and at LANDLORD’S sole discretion, is grounds for TERMINATION BY LANDLORD under Section 28 of this Agreement.

  • Any attempted assignment, transfer of ownership interest, or delegation in violation of this Section shall be void and have no force or effect whatsoever, and at LANDLORD’s sole discretion, is grounds for Termination by LANDLORD under SECTION 36 TERMINATION BY LANDLORD of this Agreement.

  • Landlord shall be responsible for ordinary and regular maintenance.6. TERMINATION BY LANDLORD Notwithstanding anything else in this Agreement to the contrary, Landlord shall have a unilateral right to terminate this Agreement, and the Tenant’s right of occupancy thereunder, upon ninety (90) days written notice in accordance with the Notice provisions of Paragraph 33.

Related to TERMINATION BY LANDLORD

  • Termination Right have the respective meanings given in the PRA Contractual Stay Rules.

  • Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.

  • Partial Termination has the meaning set forth in the Section 6.3(a).

  • Renewal Rent for the Aircraft means the rent payable therefor in respect of a Renewal Lease Term determined pursuant to Section 17.2.2 of the Lease.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • this Lease means the relevant portion of Articles 1 through 29 of this Office Lease to which this Tenant Work Letter is attached as EXHIBIT B and of which this Tenant Work Letter forms a part, and all references in this Tenant Work Letter to sections of "this Tenant Work Letter" shall mean the relevant portion of Sections 1 through 7 of this Tenant Work Letter.

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Termination for Convenience means the termination of the Trade Contract Agreement or the Trade Contractor Work by the Authority without cause and for the convenience of the Authority as decided in its sole discretion.

  • this Tenant Work Letter means the relevant portion of Sections 1 through 6 of this Tenant Work Letter.

  • Base Rent $ 25,024 per month ("Base Rent"), payable on the 1st day of each month commencing on the Commencement Date (Also see Paragraph 4.) [ ] If this box is checked, this Lease provides for the Base Rent to be adjusted per Addendum ___, attached hereto.

  • Termination With Cause means the termination of the Executive’s employment by act of the Board for any of the following reasons:

  • Recapture Period means, with respect to any Project, the period from the date such Project is Placed in Service through the fifth anniversary of such date.

  • Additional Rent means all amounts, other than Basic Rent and any Security Deposit, required to be paid by the Tenant to the Landlord in accordance with this Agreement.

  • Base Rental means the amount of rent due to Landlord per square foot for the first year of the Term. Base Rental for the first year of Term shall be $32.50 per square foot for the building and $7.50 per square foot for the drive thru at the Premises. Year Per SqFt First Floor Per SqFt Drive Thru TotalPer Annum TotalPer Month 1 $ 32.50 $ 7.50 $ 151,512.00 $ 12,626.00

  • Additional Rental has the meaning set forth in Section 4.03.

  • Master Lease means any master lease now or hereafter entered into, in which the Healthcare Facility is aggregated with other HUD-insured healthcare facilities and leased to a Master Tenant and any amendments or joinders thereto.

  • Termination or “Terminated” means, for purposes of this Plan with respect to a Participant, that the Participant has for any reason ceased to provide services as an employee, officer, director, consultant, independent contractor or advisor to the Company or a Parent or Subsidiary of the Company. An employee will not be deemed to have ceased to provide services in the case of (i) sick leave, (ii) military leave, or (iii) any other leave of absence approved by the Committee; provided, that such leave is for a period of not more than 90 days, unless reemployment upon the expiration of such leave is guaranteed by contract or statute or unless provided otherwise pursuant to formal policy adopted from time to time by the Company and issued and promulgated to employees in writing. In the case of any employee on an approved leave of absence, the Committee may make such provisions respecting suspension of vesting of the Award while on leave from the employ of the Company or a Parent or Subsidiary of the Company as it may deem appropriate, except that in no event may an Award be exercised after the expiration of the term set forth in the applicable Award Agreement. The Committee will have sole discretion to determine whether a Participant has ceased to provide services and the effective date on which the Participant ceased to provide services (the “Termination Date”).

  • Term of this Lease or “Term” means the time during which this Lease is in effect, as provided for in Article 3 of this Site Lease.

  • Non-Renewal shall have the meaning set forth in Paragraph 2(b) hereof.

  • Termination Option means the option of either party to terminate a transaction in the event that the other party fails to perform a Firm obligation to deliver Gas in the case of Seller or to receive Gas in the case of Buyer for a designated number of days during a period as specified on the applicable Transaction Confirmation.

  • Terminating Party As defined in Section 7.1(f).

  • Automatic Termination shall have the meaning set forth in Section 2.3.2.

  • Basic Rent means Basic Rent as defined in Paragraph 6.

  • Fixed term tenancy means a tenancy that has a fixed term of existence, continuing to a

  • Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:

  • Rent as used in this Section 21 shall be deemed to be and to mean all sums of every nature required to be paid by Tenant pursuant to the terms of this Lease, whether to Landlord or to others. As used in Sections 21(c)(ii)(A) and (B), above, the “worth at the time of award” shall be computed by allowing interest at the Default Rate. As used in Section 21(c)(ii)(C) above, the “worth at the time of award” shall be computed by discounting such amount at the discount rate of the Federal Reserve Bank of San Francisco at the time of award plus 1%.