Successful Completion means that in the reasonable opinion of the Customer, Deliverables completed by the Supplier are fit for purpose, completed on time and otherwise meet all the criteria defined under this Contract;
Final Completion means the date determined and certified by A/E and Owner on which the Work is fully and satisfactorily complete in accordance with the Contract.
Successful Applicant means an “employee applicant” or “applicant” who has been offered employment within this Bargaining Unit by the Employer.
Tests after Completion means the tests (if any) which are specified in the Contract and which are carried out in accordance with the Specification after the Works or a Section (as the case may be) are taken over by the Procuring Entity.
Successful Bidder” or “Successful E-Auction Process Participant means, the Qualified Bidder whose bid is approved and who is declared successful by the Liquidator at the end of the determined auction phase.C. INTRODUCTION
Study Completion means the database for the Study has been locked and all Essential Documents have been provided to the Sponsor, including a copy of the letter from the Reviewing HREC acknowledging receipt of the final report and/or closure letter from the Principal Investigator.
Phase II Study means a study in humans of the safety, dose ranging or efficacy of a product, as further defined in 21 C.F.R. § 312.21(b) (or the equivalent thereof outside the United States).
Successful Vendor means the organization or person with whom the order is placed or who is contracted to execute the work as detailed in the bid.
Phase II Trial means a clinical trial of a Licensed Product on patients, including possibly pharmacokinetic and dose ranging studies, the principal purposes of which are to make a preliminary determination that such Licensed Product is safe for its intended use and to obtain sufficient information about such Licensed Product’s efficacy to permit the design of further clinical trials, and generally consistent with 21 CFR §312.21(b), or its successor regulation, or the equivalent in any foreign country.
Completion of Services means..................................................
Test on Completion means such tests as prescribed in the Contract to be performed by the Contractor before the work is Taken Over by TSECL.
Phase 2 Trial means a human clinical trial conducted on study subjects with the disease or condition being studied for the principal purpose of achieving a preliminary determination of efficacy or appropriate dosage ranges, as further described in 21 C.F.R. §312.21(b) (including any such clinical study in any country other than the United States).
Virtual Completion means the premise is in the opinion of the Employer fit for occupation.
Substantial Completion Date means the date on which Substantial Completion occurs.
Substantial Completion means the stage in the progress of the work as determined and certified by the Contracting Officer in writing to the Contractor, on which the work (or a portion designated by the Government) is sufficiently complete and satisfactory. Substantial completion means that the property may be occupied or used for the purpose for which it is intended, and only minor items such as touch-up, adjustments, and minor replacements or installations remain to be completed or corrected which:
Phase I Trial means a clinical trial of a Licensed Product in human patients conducted primarily for the purpose of determining the safety, tolerability and preliminary activity of the Licensed Product, including, without limitation, for determining the maximum tolerated dose, or optimal dose. For purposes of this Agreement, a Phase I trial shall specifically exclude a study in healthy volunteers.
Final Completion Date means the date on which Final Completion occurs.
project completion period means the period of sixty (60) months commencing from and expiring on for the construction and obtaining of Temporary Occupation Permit or Permits for the whole of the Development as provided in clause 3.3;
Phase III Study means a human clinical trial that is prospectively designed to demonstrate statistically whether a product is safe and effective for use in humans in a manner sufficient to obtain regulatory approval to market such product in patients having the disease or condition being studied as described in 21 C.F.R. § 312.21(c) (FDCA), as amended from time to time, and the foreign equivalent thereof.
Project Milestone means the project milestone set forth in Schedule-J;
Project Completion means completion of the Redevelopment in accordance with this Agreement to the state where the whole of the Morley Shopping Centre, as so redeveloped, is capable of occupation for its intended purpose;
Phase I Study means a study in humans which provides for the first introduction into humans of a product, conducted in healthy volunteers or patients to obtain information on product safety, tolerability, pharmacological activity or pharmacokinetics, as more fully defined in 21 C.F.R. § 312.21(a) (or the non-United States equivalent thereof).
Phase III Trial means a Clinical Trial of an investigational product in subjects that incorporates accepted endpoints for confirmation of statistical significance of efficacy and safety with the aim to generate data and results that can be submitted to obtain Regulatory Approval as described in 21 C.F.R. 312.21(c), or a comparable Clinical Trial prescribed by the relevant Regulatory Authority in a country other than the United States.
Project Completion Date means the date on which the Completion Certificate is issued;
Completion of work means completion of the entire contracted work. Exhaustion of quantity of any particular item mentioned in the bid document shall not imply completion of work or any component thereof.
Flood Elevation Determination means a determination by the Administrator of the water surface elevations of the base flood, that is, the flood level that has a one percent or greater chance of occurrence in any given year.