Enforced Delay definition

Enforced Delay means any delay described in Section 1003 caused without fault and beyond the reasonable control of a party, which delay shall justify an extension of time to perform as provided in Section 1003.
Enforced Delay has the meaning set forth in Section 6.4.
Enforced Delay means as defined in Section 6(H).

Examples of Enforced Delay in a sentence

  • These remedies are not listed in any prescribed order to pro- vide the Presidio Trust with flexibility in determining which remedies will be most efficient in collecting the par- ticular debt.

  • Enforced Delay in Performance for Causes Beyond Control of Party.

  • Enforced Delay in Performance for Causes Beyond Control of Party 708.

  • Consultant agrees that Consultant alone will bear all risks of delay which are not Enforced Delay.

  • In no event will Enforced Delay include any delay resulting from unavailability for any reason of labor shortages, or the unavailability for any reason of particular consultants, subcontractors, vendors or investors desired by Contractor in connection with the Project.

  • In no event will Enforced Delay include any delay resulting from unavailability for any reason of labor shortages, or the unavailability for any reason of particular Contractors, subcontractors, vendors or investors desired by Contractor in connection with the obligations under this Agreement.

  • In no event will Enforced Delay include any delay resulting from unavailability for any reason of labor shortages, or the unavailability for any reason of particular Consultants, subcontractors, vendors or investors desired by Consultant in connection with the obligations under this Agreement.

  • Failure to provide such notice shall constitute a waiver of the Enforced Delay claim.

  • Provided, however, in order to claim any such time extension or period of Enforced Delay, Developer shall notify City of such claim no later than ten days from the occurrence of any such unforeseeable cause arising under this Section VII (M).

  • An extension of time for any such cause shall be limited to the period of the Enforced Delay, and shall commence to run from the time of the commencement of the Enforced Delay, provided the Party claiming such extension notifies the other Party within ten (10) calendar days of the commencement of the Enforced Delay.


More Definitions of Enforced Delay

Enforced Delay means a delay or default resulting arising only from one or more of the following: (A) a natural disaster or other Force Majeure, (B) an accident that requires all development activities to stop; (C) the interruption of services by suppliers for a substantial period of time when no alternative suppliers are available, (D) the unavailability of construction materials for a substantial period of time when no substitute materials are available, (E) war, civil disturbance, or riot where martial law is declared, or (F) any other severe occurrence that is beyond Developer’s reasonable control, as determined by the County Director of Conservation and Development in his or her sole discretion.
Enforced Delay shall have the meaning set forth in Section
Enforced Delay means any delay described in Section 1103 caused without fault and beyond the reasonable control of a party, which delay shall justify an extension of time to perform as provided in Section 1103. L. (§212)

Related to Enforced Delay

  • Allowed Delay has the meaning set forth in Section 2(c)(ii).

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Service Level Failure means a failure to perform the Software Support Services fully in compliance with the Support Service Level Requirements.

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.

  • MI Failure means when an MI report: a) contains any material errors or material omissions or a missing mandatory field; or b) is submitted using an incorrect MI reporting Template; or c) is not submitted by the reporting date(including where a Nil Return should have been filed);

  • Force Majeure Failure has the meaning set forth in Section 8.1(d).

  • Service Failure means a failure by the Contractor to provide the Services in accordance with any individual service level described above (measured on a monthly/quarterly/annual basis)

  • Daily Failure Amount means the product of (x) .005 multiplied by (y) the Closing Sale Price of the Common Stock on the applicable Share Delivery Date.

  • GEP Failure means Seller’s failure to produce Delivered Energy in an amount equal to or greater than the Guaranteed Energy Production amount for the applicable Performance Measurement Period.

  • Volume Failure means, with respect to a particular date of determination, the aggregate daily dollar trading volume (as reported on Bloomberg) of the Common Stock on the Principal Market on any Trading Day during the twenty (20) Trading Day period ending on the Trading Day immediately preceding such date of determination (such period, the “Volume Failure Measuring Period”), is less than $2,000,000 (as adjusted for any stock splits, stock dividends, stock combinations, recapitalizations or other similar transactions occurring after the Subscription Date). All such determinations to be appropriately adjusted for any stock splits, stock dividends, stock combinations, recapitalizations or other similar transactions during such Volume Failure Measuring Period.

  • Consistent Failure means any of:

  • Transaction Failure means the failure to consummate a Business Combination within 18 months of the Effective Date (or 24 months after the Effective Date, if a letter of intent, agreement in principle or definitive agreement has been executed within 18 months after the Effective Date and the Business Combination relating thereto has not yet been consummated within such 18-month period).

  • Supply Failure shall have the meaning ascribed to it in Section 2.8.

  • Milestone Failure means a failure by the Grant Recipient fully to achieve any Milestone by the relevant Milestone Date;

  • Excused Outage means any disruption to or unavailability of Services caused by or due to (i) Scheduled Maintenance,

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Price Failure means, with respect to a particular date of determination, the VWAP of the Common Stock on any Trading Day during the seven (7) Trading Day period ending on the Trading Day immediately preceding such date of determination fails to exceed the Floor Price (as adjusted for stock splits, stock dividends, stock combinations, recapitalizations or other similar transactions occurring after the date hereof). All such determinations to be appropriately adjusted for any stock splits, stock dividends, stock combinations, recapitalizations or other similar transactions during any such measuring period.

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.

  • Scheduled Outage has the meaning given to it in the Grid Code;

  • Public Information Failure Payments shall have the meaning ascribed to such term in Section 4.3(b).

  • Excused Downtime means the number of minutes in the Charging Period, rounded to the nearest minute that the link state of Customer’s Port is ‘down’ due to:

  • Tenant Delay Any event or occurrence that delays the completion of the Landlord Work which is caused by or is described as follows:

  • Equity Conditions Failure means that on any applicable date the Equity Conditions have not been satisfied (or waived in writing by the Holder).

  • Persistent Failure means any two (2) or more failures by the Supplier in any rolling period of twelve (12) months to comply with obligations in respect of the Contract Services under the Contract;

  • Tenant Delays A "Tenant Delay" shall mean any delay in Substantial Completion of the Building as a result of any of the following: (i) Tenant's failure to complete or approve the Tenant Improvement Plans by the dates set forth in Section 5.B, (ii) Tenant's failure to approve the bids for construction by the dates set forth in Section 5.C, (iii) changes to either the Shell Plans and Specifications or the Tenant Improvement Plans requested by Tenant which delay the progress of the work, (iv) Tenant's request for materials, components or finishes which are not available in a commercially reasonable time given the target Commencement Date, (v) Tenant's failure to make a progress payment for Tenant Improvement costs as provided in Section 5.F, (vi) Tenant's request for more than one (1) rebidding of the cost of all or a portion of the work, and (vii) any errors or omissions in the Tenant Improvement Plans provided by Tenant's architect. In the event Landlord believes Tenant is causing a Tenant Delay, Landlord shall notify Tenant in writing, state the action or inaction that it believes is causing the Tenant Delay, and state the date from which a Tenant Delay is being calculated. Claim of Tenant Delay shall be made within five (5) days after Landlord's discovery of the occurrence of the event giving rise to such claim. Tenant shall have the right to expedite work, at its sole cost, to minimize the effect of any Tenant Delays, to the extent it is practicable to do so. However, no Tenant Delay shall advance the Commencement Date to a date before the estimated Commencement Date of October 1, 2001. Notwithstanding anything to the contrary set forth in this Lease and regardless of the actual date the Premises are Substantially Complete (but subject to the limitation in the preceding sentence), the Commencement Date shall be deemed to be the date the Commencement Date would have occurred if no Tenant Delay had occurred as reasonably determined by Landlord. In addition, if a Tenant Delay results in an increase in the cost of the labor or materials, Tenant shall pay the cost of such increases.