Third and Subsequent Occurrence Sample Clauses

Third and Subsequent Occurrence. For the third or subsequent occurrence within any one Calendar Year of contamination for a particular container (i.e., Recyclable Materials or Organic Waste), Contractor must collect the contaminated Container (as Solid Waste) and must charge the Service Recipient a contamination fee as set forth in Exhibit 1. Contractor must continue providing the Recyclable Materials or Organic Waste Collection Services. Contractor must provide (or have provided) digital/photographic documentation to the Service Recipient that clearly documents the Service Recipient’s on-going contamination problems and written Notices of contamination as described above. Contractor may increase the Container size or collection frequency and impose a contamination surcharge on the account for a period of six months or until the Service Recipient has demonstrated no contamination for a period of three consecutive months. Contractor must document contamination issue and surcharge in Waste Reporting System and notify City within five (5) Business Days if Contractor increases the Container size or collection frequency for excessive contamination or imposes the contamination surcharge to the account. City will consult with Contractor and consider, and pursue as applicable, appropriate legal remedies against offending Service Recipients in order to secure discontinuance of the contamination.
Sample 1
AutoNDA by SimpleDocs
Third and Subsequent Occurrence. For the third and subsequent occurrence within any one Calendar Year of contamination for a particular container (i.e., Recyclable Materials or Organic Waste), Contractor will provide a Contamination Violation Notice that contains instructions on the proper procedures for setting out Recyclable Materials or Organic Waste, and Contractor must collect the contaminated Container (as Solid Waste) and will charge the Service Recipient a contamination fee as set forth in Exhibit 1. For any contamination fee charge being assessed, Contractor must provide digital/visual documentation to the Service Recipient that clearly documents the Service Recipient’s on-going contamination problems. Contractor may increase the Container size, require locking Bins, or increase collection frequency, and impose a contamination surcharge on the account for a period of six months or until the Service Recipient has demonstrated no contamination for a period of three consecutive months. Contractor must document contamination issue and surcharge in the Waste Reporting System and notify City within five (5) Business Days if Contractor increases the Container size, require locking Bins, increase collection frequency for excessive contamination, or imposes the contamination surcharge to the account. City will consider, and pursue as applicable, appropriate legal remedies against offending Service Recipients in order to secure discontinuance of the contamination
Sample 1

Related to Third and Subsequent Occurrence

  • Reports of unusual occurrence The Contractor shall, during the Maintenance Period, prior to the close of each day, send to the Authority and the Authority’s Engineer, by facsimile or e- mail, a report stating accidents and unusual occurrences on the Project Highway relating to the safety and security of the Users and Project Highway. A monthly summary of such reports shall also be sent within 3 (three) business days of the closing of month. For the purposes of this Clause 15.4, accidents and unusual occurrences on the Project Highway shall include:

  • Substantial Completion Date Substantial Completion of the Work as defined in Article 6.1.2 of the General Conditions to the Continuing Contract for Construction Management shall be achieved by July 31, 2022.

  • C4 Price adjustment on extension of the Initial Contract Period C4.1 The Contract Price shall apply for the Initial Contract Period. In the event that the Client agrees to extend the Initial Contract Period pursuant to clause F8 (Extension of Initial Contract Period) the Client shall, in the 6 month period prior to the expiry of the Initial Contract Period, enter into good faith negotiations with the Contractor (for a period of not more than 30 Working Days) to agree a variation in the Contract Price.

  • C4 Contract Price During Extension of the Initial Contract Period C4.1 Subject to the Pricing Schedule and the provision in clause F6 (Variation), the Contract Price shall apply for the Initial Contract Period and following an extension pursuant to clause F8 (Extension of Initial Contract Period), to the date of expiry of the extended period, or such earlier date of termination or partial termination of the agreement in accordance with the Law or the provisions of the Contract. C5 Euro

  • Completion Date The Work under this Contract shall be completed by midnight of the date required in the Contract as the Material Completion and Occupancy Date unless extended by approved requests for extension of time.

  • The OCN, From XXX, and Invoice Number will control the invoice sequencing The From XXX will be used to identify to <<customer_name>> which BellSouth XXX is sending the message. BellSouth and <<customer_name>> will use the invoice sequencing to control data exchange. BellSouth will be notified of sequence failures identified by <<customer_name>> and resend the data as appropriate. THE DATA WILL BE PACKED USING ATIS EMI RECORDS.

  • Hearing Dates and Date of Award Except for the Expedited Arbitration procedure described above, hearing dates shall be scheduled within thirty (30) working days of selection of an arbitrator or on the next practicable date mutually agreeable to the parties. Awards shall be due forty-five (45) calendar days following the receipt of closing arguments. As a condition of appointment to the permanent panel, arbitrators shall be advised of this requirement and shall certify their willingness to abide by these time limits.

  • Completion Dates The Recipient agrees to complete each Project within the time periods specified in the Underlying Agreement and all activities must be completed by the Award’s end date, unless FTA agrees in writing to extend the end date. Unless FTA determines otherwise in writing, interim milestone dates and other completion dates applicable to the Award are good faith estimates and are not intended to be firm contractual requirements. However, FTA and the Recipient agree that milestone dates and other completion dates for Full Funding Grant Agreements, Small Starts Grant Agreements or other specific agreements in which FTA expressly states that the milestone dates or other completion dates for the Underlying Agreement are firm dates that may be enforced.

  • Recovery of Schedule Delays During Last Sixty Days of Contract Time At any time during the last sixty days of the Contract Time that the Design Professional finds that the Contractor is behind schedule per the Contract Time, as amended, the Design Professional shall notify the Contractor in writing. Within seven days of the date of the Design Professional's notice, the Contractor shall prepare and deliver to the Design Professional and Owner a written plan explaining how the Contractor intends to bring the Project back on schedule. The Contractor's plan must provide sufficient detail to allow the Design Professional and Owner to determine the proposal's feasibility.

  • Events Beyond Our Control If an Event Beyond Our Control occurs and prevents Us from performing any of Our obligations under this Contract to any extent, then We are not required to perform that obligation to the extent and for as long as We are prevented by that Event Beyond Our Control. If such an Event Beyond Our Control occurs and We consider it appropriate to do so, We may notify You of the Event Beyond Our Control by any reasonable means, including by a public announcement.

Time is Money Join Law Insider Premium to draft better contracts faster.