Minimum Site Requirements for TIPS Sales (when applicable to TIPS Sale). Cleanup: When performing work on site at a TIPS Member’s property, Vendor shall clean up and remove all debris and rubbish resulting from their work as required or directed by the TIPS Member or as agreed by the parties. Upon completion of work, the premises shall be left in good repair and an orderly, neat, clean and unobstructed condition. Preparation: Vendor shall not begin a project for which a TIPS Member has not prepared the site, unless Vendor does the preparation work at no cost, or until TIPS Member includes the cost of site preparation in the TIPS Sale Site preparation includes, but is not limited to: moving furniture, installing wiring for networks or power, and similar pre‐installation requirements. Registered Sex Offender Restrictions: For work to be performed at schools, Vendor agrees that no employee of Vendor or a subcontractor who has been adjudicated to be a registered sex offender will perform work at any time when students are, or reasonably expected to be, present unless otherwise agreed by the TIPS Member. Vendor agrees that a violation of this condition shall be considered a material breach and may result in the cancellation of the TIPS Sale at the TIPS Member’s discretion. Vendor must identify any additional costs associated with compliance of this term. If no costs are specified, compliance with this term will be provided at no additional charge. Safety Measures: Vendor shall take all reasonable precautions for the safety of employees on the worksite, and shall erect and properly maintain all necessary safeguards for protection of workers and the public. Vendor shall post warning signs against all hazards created by the operation and work in progress. Proper precautions shall be taken pursuant to state law and standard practices to protect workers, general public and existing structures from injury or damage. Smoking: Persons working under Agreement shall adhere to the TIPS Member’s or local smoking statutes, codes, ordinances, and policies.
Technical Standards Applicable to a Wind Generating Plant i. Low Voltage Ride-Through (LVRT) Capability A wind generating plant shall be able to remain online during voltage disturbances up to the time periods and associated voltage levels set forth in the standard below. The LVRT standard provides for a transition period standard and a post-transition period standard.
Data Quality 4.1 Each party ensures that the shared Personal Data is accurate.
Xxxxxxx to Meet Timelines Failure by the Union to comply with the timelines will result in the automatic withdrawal of the grievance. Failure by the Employer to comply with the timelines will entitle the Union to move the grievance to the next step of the procedure.
Quality Assurance/Quality Control Contractor shall establish and maintain a quality assurance/quality control program which shall include procedures for continuous control of all construction and comprehensive inspection and testing of all items of Work, including any Work performed by Subcontractors, so as to ensure complete conformance to the Contract with respect to materials, workmanship, construction, finish, functional performance, and identification. The program established by Contractor shall comply with any quality assurance/quality control requirements incorporated in the Contract.
Minimum Shipping Requirements for TIPS Sales Vendor shall ship, deliver, or provide ordered goods and services within a commercially reasonable time after acceptance of the order. If a delay in delivery is anticipated, Vendor shall notify the TIPS Member as to why delivery is delayed and provide an updated estimated time for completion. The TIPS Member may cancel the order if the delay is not commercially acceptable or not consistent with the Supplemental Agreement applicable to the order.
Quality- and Cost-Based Selection Except as ADB may otherwise agree, the Borrower shall apply quality- and cost-based selection for selecting and engaging consulting services.
Use; Quality Control a. Neither party may alter the other party’s trademarks from the form provided and must comply with removal requests as to specific uses of its trademarks or logos.
Benchmarks for Measuring Accessibility For the purposes of this Agreement, the accessibility of online content and functionality will be measured according to the W3C’s Web Content Accessibility Guidelines (WCAG) 2.0 Level AA and the Web Accessibility Initiative Accessible Rich Internet Applications Suite (WAI-ARIA) 1.0 for web content, which are incorporated by reference. Adherence to these accessible technology standards is one way to ensure compliance with the College’s underlying legal obligations to ensure that people with disabilities are able to acquire the same information, engage in the same interactions, and enjoy the same benefits and services within the same timeframe as their nondisabled peers, with substantially equivalent ease of use; that they are not excluded from participation in, denied the benefits of, or otherwise subjected to discrimination in any College programs, services, and activities delivered online, as required by Section 504 and the ADA and their implementing regulations; and that they receive effective communication of the College’s programs, services, and activities delivered online.
Certification Regarding Sales and Use Tax By executing the Contract the Contractor certifies it is either (a) registered with the State Department of Revenue, collects, and remits State sales and use taxes as required by Georgia law, including Chapter 8 of Title 48 of the O.C.G.A.; or (b) not a “retailer” as defined in O.C.G.A. Section 48-8-2. The Contractor also acknowledges that the State may declare the Contract void if the above certification is false. The Contractor also understands that fraudulent certification may result in the State Entity or its representative filing for damages for breach of contract.