Notice by Contractor Required. The Contractor shall within five (5) calendar days of beginning of any such delay notify the Owner in writing of causes of delay with justification and supporting documentation. Claims relating to time extensions shall be made in accordance with applicable provisions of Article 7.
Notice by Contractor Required. The Contractor shall within ten (10) Days of beginning of any Excusable Delay (unless Owner grants in writing a further period of time to file such notice prior to the date of final Progress Payment under the Agreement) notify the Owner in writing of causes of delay. Owner will then ascertain the facts and extent of the delay and grant an extension of time for completing the Work when, in its judgment, the findings of fact justify such an extension. The Owner’s findings of fact thereon shall be final and conclusive on the Parties. Extensions of time shall apply only to that portion of the Work affected by the delay and shall not apply to other portions of the Work not so affected. The sole remedy of Contractor for extensions of time under Section 4.8(a) shall be an extension of the Project Schedule at no cost to the Owner.
Notice by Contractor Required. Contractor shall within ten (10) calendar days of beginning of any such Excusable Delay (unless Owner grants in writing a further period of time to file such notice prior to the date of final payment under this Agreement) notify Owner in writing of the Excusable Delay. The Parties will then reasonably and in good faith ascertain the facts and extent and nature of the delay and shall execute a CO for an extension of time, and/or increase in Contract Sum, as applicable for completing the Work when, in Owner’s reasonable judgment, the findings of fact justify such an extension or increase in the Contract Sum. Extensions of time and increases in Contract Sum, shall apply only to that portion of the Work affected by the delay and shall not apply to other portions of the Work not so affected.
