DISTRIBUTION OF CONTRACTOR PRICE LIST AND CONTRACT APPENDICES Contractor shall provide Authorized Users with electronic copies of the Contract, including price lists and Appendices, upon request. OGS CENTRALIZED CONTRACT MODIFICATIONS Contract Updates will be handled as provided in Appendix C – Contract Modification Procedures.
CONTRACTOR’S SUBMISSION OF CONTRACT MODIFICATIONS In connection with any Contract modification, OGS reserves the right to: request additional information reject Contract modifications remove Products from Contract modification requests request additional discounts for new or existing Products
Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.
Attachment C, Standard State Provisions for Contracts and Grants Attachment C is hereby deleted in its entirety and replaced by the Attachment C December 15, 2017 attached to this Amendment. Taxes Due to the State. Contractor certifies under the pains and penalties of perjury that, as of the date this contract amendment is signed, the Contractor is in good standing with respect to, or in full compliance with a plan to pay, any and all taxes due the State of Vermont. Child Support (Applicable to natural persons only; not applicable to corporations, partnerships or LLCs). Contractor is under no obligation to pay child support or is in good standing with respect to or in full compliance with a plan to pay any and all child support payable under a support order as of the date of this amendment.
Compensation Schedule Except as otherwise provided herein, employees shall be compensated within the pay range assigned to the classification of the position in which they are employed and in accordance with the pertinent conditions of employment enumerated in this Agreement. Sec. 503 REGULAR PAY DAY: Employees shall be paid on or about the Friday following the end of the biweekly payroll period.
Construction Schedules 10.1 Within seven (7) days of the University’s issuance of a purchase order, the Contractor shall submit to the Project Coordinator three (3) copies of a Construction Schedule for this Project. The Schedule shall be in bar chart form and shall include all aspects of the work, the interrelationship of the various trades and the critical path of the job. The schedule shall include a timeline for the submission, review and approval of shop drawings for critical path items and delivery and installation dates for those same critical path, or long lead time items, (such as electrical transformers and elevator). The Schedule shall coincide with the Contractor’s approved Schedule of Values. The Schedule shall indicate a completion date in advance of the date established for Substantial Completion. The Schedule shall be acceptable to the Architect/Engineer and the Project Coordinator. It shall be revised and reissued at the beginning of every month for the duration of the project. This monthly update progress Schedule shall include a summary comparison of the original schedule and the latest updated schedule (previous month) showing all activity description and dates. These comparison schedules shall be in the form of a summary bar chart, an activity listing report and actual to target comparisons. The reports may include critical activities, float time, duration of each activity, dates of each activity and the network logic (including successors and predecessors of each activity). Included with the written report and electronic copy of the schedule submission noting the above referenced requirements. Failure to provide the Architect/Engineer, or the Project Coordinator with an acceptable, revised Schedule, within seven (7) days of the receipt of a written request, may result in the withholding of the Contractor’s monthly progress payments until such a Schedule is received.
Change Orders and Contract Amendments 33.1 The Procuring Entity may at any time order the Supplier through notice in accordance GCC Clause 8, to make changes within the general scope of the Contract in any one or more of the following:
Construction Schedule The progress schedule of construction of the Project as provided by Developer and approved by District.
ARBITRATION - SCHEDULING Timely complaints shall be submitted to and determined by an arbitrator. Each arbitration proceeding shall commence not earlier than ten (10) calendar days and not later than thirty (30) calendar days following the date of filing of the complaint.
Order Rejections 53.11.1 CenturyLink shall reject and return to CLEC any order that CenturyLink cannot provision, due to technical reasons, missing information, or jeopardy conditions resulting from CLEC ordering service at less than the standard order interval.
