THE WORK The term "
Tenant Improvements Subject to this Section 4, Tenant shall accept the Suite 110 Premises in its “as is” condition (subject to Landlord's continuing repair and maintenance obligations, as outlined in Section 10 of the Lease (as may be amended)), and Landlord shall have no obligation to make any alterations or improvements thereto whatsoever (provided that Landlord shall deliver same in good and tenantable condition, broom clean, with all systems serving same in good working order). Any alterations that Tenant desires to make in the Suite 110 Premises shall be subject to all the terms and conditions set forth in Section 11 of the Lease. Notwithstanding anything in the Lease to the contrary, Landlord hereby agrees to grant Tenant an allowance in the amount of $10,000 to be applied toward the cost (including architectural and engineering fees) of alterations performed by Tenant in the Suite 110 Premises (the “Granted Allowance”) in conjunction with Tenant’s initial occupancy of Suite 110 Premises. Provided no Event of Default then exists under the Lease, the Granted Allowance (or portions thereof) shall be disbursed to Tenant within thirty (30) days following Tenant's submission to Landlord of paid invoices for work related to alterations performed by Tenant in the Suite 110 Premises, accompanied by waivers of liens executed by all contractors employed by Tenant for the performance of such work. If the cost of Tenant's alterations in the Suite 110 Premises exceeds the amount of the Granted Allowance, the excess shall be paid by Tenant after the Granted Allowance is fully exhausted. Any portion of the Granted Allowance that has not been applied (or contracted to be applied) in the manner set forth above by the date which is twelve (12) months following the Eighth Amendment Commencement Date shall revert to Landlord, and Tenant shall have no further rights with respect thereto.
Landlord’s Work Landlord shall construct the base-building elements of the Building (the "Base Building Work"), the sitework on the Land, and the parking structure and surface parking areas on the Land, all in accordance with the Design Specifications attached hereto as Schedule I (collectively, "Landlord's Work"). All of Landlord's Work shall be performed in a good and workmanlike manner, in accordance with plans and specifications ("Landlord's Plans") mutually approved by Landlord and Tenant. Tenant's approval of Landlord's Plans shall not be unreasonably withheld, conditioned or delayed, and Tenant shall not be entitled to condition its approval of Landlord's Plans upon the inclusion therein of any design specifications that are inconsistent with the Design Specifications attached hereto as Schedule I (including requiring a higher performance standard than any performance standard expressly set forth in Schedule I). Tenant shall respond to any request for approval of Landlord's Plans, or any portion or progress set thereof, or any modifications thereto, as promptly as reasonably possible and in any event within ten (10) business days in the case of the original complete set of Landlord's Plans and any structural modifications thereto and within two (2) business days in the case of any nonstructural modifications to Landlord's Plans, and Tenant's failure to respond within such time periods shall be referred to herein and in the Lease as a "Tenant Delay." In the event Tenant disapproves Landlord's Plans or any portion thereof or any modifications thereto, Tenant's notice of disapproval shall specify in detail the reasonable basis for such disapproval. Landlord shall promptly make such revisions to Landlord's Plans as may be necessary to address Tenant's reasonable objections, and shall resubmit Landlord's Plans to Tenant for Tenant's approval. Tenant shall review such revised plans as promptly as reasonably possible and notify Landlord whether Tenant approves or reasonably disapproves Landlord's Plans as modified. This process shall be repeated, if necessary, until Tenant's reasonable objections to Landlord's Plans have been addressed and Tenant has approved Landlord's Plans. After approval of Landlord's Plans, Tenant shall have the right to initiate changes to Landlord's Plans or Landlord's Work, subject to (i) Landlord's approval of any such proposed change, which approval shall not be unreasonably withheld, conditioned or delayed, and (ii) Landlord's and Tenant's mutual agreement concerning (and execution of a change order or other written confirmation of) (A) any net increase in design or construction costs resulting from such change, all of which increased costs shall be borne solely by Tenant, and (B) any delay such change will cause in the completion of Landlord's Work or the achievement of any milestone date(s), which delay shall not extend the Lease Commencement Date or the commencement of Tenant's rental obligations under the Lease (but shall appropriately extend any affected milestone date(s)) and shall be deemed a "Tenant Delay" for purposes hereof and of the Lease. Landlord shall be responsible for causing Landlord's Work to comply with all applicable legal requirements, including (without limitation) requirements of building codes, environmental laws and the Americans with Disabilities Act, and Landlord shall indemnify Tenant and hold it harmless with respect to any loss, cost, damage or liability resulting from Landlord's breach of this obligation (which indemnification shall survive the expiration or termination of the Lease). In constructing the Base Building Work, Landlord shall perform and install all work and materials designated "Base Building" in Schedule II attached hereto. In performing the Base Building Work, Landlord shall use best efforts to achieve the milestone dates set forth in Schedule III attached hereto. In the event Landlord fails to achieve any of said milestone dates, except to the extent such failure is caused by any Tenant Delay, the December 29, 1995 date set forth in Section 3.2 of the Lease shall be extended by one (1) day for each day of delay in achieving the milestone date; provided, however, that such extension shall not occur if (and then only to the extent) Landlord and Tenant mutually agree and acknowledge in writing that the completion of the Tenant Work (as defined below) was not delayed by reason of the delay in achieving Landlord's milestone date. Tenant agrees to use good faith reasonable efforts to counter the effect of any delay by Landlord in achieving any milestone date; however, Tenant shall not be obligated to expend any additional amounts in such efforts (e.g., by employing overtime labor) unless Landlord agrees in advance to bear any incremental cost associated with such efforts (whether or not such efforts are ultimately successful).
Tenant’s Work During the Term Tenant may not perform any work, alterations, installations, additions, improvements, structural repairs or restorations to the Property (“Tenant’s Work”) without the prior written consent of Landlord which (i) in the case of alterations, additions, installations or improvements of a structural nature or involving the Building systems, may be granted or withheld by Landlord in its sole and absolute discretion and (ii) in the case of alterations or improvements of a non-structural nature or not involving Building systems, shall not be unreasonably withheld or delayed. In connection with such consent, Tenant shall submit to Landlord such detailed plans, specifications, drawings and other materials reasonably requested by Landlord. Tenant may make such non-structural alterations and perform work of a decorative nature without Xxxxxxxx’s prior written consent. At Tenant’s sole cost, Xxxxxxxx agrees to cooperate with Xxxxxx (including signing applications) in obtaining any necessary permits for any Tenant’s Work that Xxxxxx is permitted to make hereunder. In all cases the Tenant’s Work shall be performed at Tenant’s sole cost and expense and by contractors selected by Xxxxxx. Tenant agrees that the Tenant’s plans and specifications shall be in compliance with applicable laws, rules and regulations, that Tenant shall not commence construction until it obtains (if required) a building permit for Tenant’s Work, and that such Tenant’s Work shall be performed in accordance with the building permit, in compliance with applicable law and in accordance with the Tenant’s plans and specifications. As a condition of approving such Tenant's Work the Landlord may require the Tenant to maintain such additional insurance coverages (in addition to those required in Article 8 hereof) as the Landlord may reasonably require.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Work Location While employed by the Company hereunder, the Executive shall perform his duties (when not traveling or engaged elsewhere in the performance of his duties) at the offices of the Company in Bermuda. The Executive shall travel to such places on the business of the Company in such manner and on such occasions as the Company may from time to time reasonably require.
Tenant’s Repairs and Maintenance Tenant covenants and agrees that, from and after the date that possession of the Premises is delivered to Tenant and until the end of the Lease Term, Tenant will keep neat and clean and maintain in good order, condition and repair the Premises and every part thereof, excepting only for those repairs for which Landlord is responsible under the terms of Article VII of this Lease and damage by fire or casualty and as a consequence of the exercise of the power of eminent domain. Tenant shall not permit or commit any waste, and Tenant shall be responsible for the cost of repairs which may be made necessary by reason of damages to common areas in the Building or Prudential Center by Tenant, Tenant’s agents, employees, contractors, sublessees, licensees, concessionaires or invitees. Tenant shall maintain all its equipment, furniture and furnishings in good order and repair. If repairs are required to be made by Tenant pursuant to the terms hereof, Landlord may demand that Tenant make the same forthwith, and if Tenant refuses or neglects to commence such repairs and complete the same with reasonable dispatch after such demand, Landlord may (but shall not be required to do so) make or cause such repairs to be made and shall not be responsible to Tenant for any loss or damage that may accrue to Tenant’s stock or business by reason thereof. If Landlord makes or causes such repairs to be made, Tenant agrees that Tenant will forthwith on demand, pay to Landlord as Additional Rent the cost thereof together with interest thereon at the rate specified in Section 16.21, and if Tenant shall default in such payment, Landlord shall have the remedies provided for non-payment of rent or other charges payable hereunder.
Tenant Work Before commencing any repair or Alteration (“Tenant Work”), Tenant shall deliver to Landlord, and obtain Landlord’s approval of, (a) names of contractors, subcontractors, mechanics, laborers and materialmen; (b) evidence of contractors’ and subcontractors’ insurance; and (c) any required governmental permits. Tenant shall perform all Tenant Work (i) in a good and workmanlike manner using materials of a quality reasonably approved by Landlord; (ii) in compliance with any approved plans and specifications, all Laws, the National Electric Code, and Landlord’s construction rules and regulations; and (iii) in a manner that does not impair the Base Building. If, as a result of any Tenant Work, Landlord becomes required under Law to perform any inspection, give any notice, or cause such Tenant Work to be performed in any particular manner, Tenant shall comply with such requirement and promptly provide Landlord with reasonable documentation of such compliance. Landlord’s approval of Tenant’s plans and specifications shall not relieve Tenant from any obligation under this Section 7.3. In performing any Tenant Work, Tenant shall not use contractors, services, labor, materials or equipment that, in Landlord’s reasonable judgment, would disturb labor harmony with any workforce or trades engaged in performing other work or services at the Project.
Tenant’s Space Plans Tenant shall deliver to Landlord and the TI Architect schematic drawings and outline specifications (the “TI Design Drawings”) detailing Tenant’s requirements for the Tenant Improvements within 5 business days of the date hereof. Not more than 2 days thereafter, Landlord shall deliver to Tenant the written objections, questions or comments of Landlord and the TI Architect with regard to the TI Design Drawings. Tenant shall cause the TI Design Drawings to be revised to address such written comments and shall resubmit said drawings to Landlord for approval within 2 days thereafter. Such process shall continue until Landlord has approved the TI Design Drawings.
TENANT'S USE OF THE PREMISES In consideration of the agreements contained herein, Landlord hereby leases the Premises to Tenant, and Tenant hereby leases the Premises from Landlord, for the Term and upon the terms and conditions hereinafter provided. The Premises are leased subject to, and Tenant agrees not to violate, all present and future covenants, conditions and restrictions of record which affect the Land, all of such documents collectively referred to as the "Restrictions". As an appurtenance to the Premises, Tenant shall have the general and nonexclusive right, together with Landlord and the other tenants of the Project and their respective agents, to use the Common Area subject to the terms and conditions of this Lease. Tenant shall use the Premises solely for the purpose set forth in Tenant's Use Clause as designated in Article 2.n and for no other purpose. Tenant shall not use or occupy the Premises in violation of law or any covenant, condition or restriction affecting the Building or Project or the certificate of occupancy issued for the Building or Project, and shall, upon notice from Landlord, immediately discontinue any use of the Premises which is declared by any governmental authority having jurisdiction to be a violation of law or the certificate of occupancy. Tenant, at Tenant's own cost and expense, shall comply with all laws, ordinances, regulations, rules and/or any directions of any governmental agencies or authorities having jurisdiction which shall by reason of the nature of Tenant's use or occupancy of the Promises, impose any duty upon Tenant or Landlord with respect to the Premises or its use or occupation. A judgment of any court of competent jurisdiction or the admission by Tenant in any action or proceeding against Tenant that Tenant has violated any such laws, ordinances, regulations, rules and/or directions in the use of the Premises shall be deemed to be a conclusive determination of that fact as between Landlord and Tenant. Tenant shall not do or permit to be done anything which will invalidate or increase the cost of any fire, extended coverage or other insurance policy covering the Building or Project and/or property located therein, and shall comply with all rules, orders, regulations, requirements and recommendations of the Board of Fire Insurance underwriters or any other organization performing a similar function. Tenant shall promptly upon demand reimburse Landlord for any additional premium charged for such policy by reason of Tenant's failure to comply with the provisions of this Article. Tenant shall not do or permit anything to be done in or about the Premises which will in any way obstruct or interfere with the rights of other tenants or occupants of the Building or Project, or injure or annoy them, or use or allow the Premises to be used for any improper, immoral, unlawful or objectionable purpose, nor shall Tenant cause, maintain or permit any nuisance in, on or about the Premises. Tenant shall not commit or suffer to be committed any waste in or upon the Premises. Tenant acknowledges that Tenant assumes all responsibility regarding the Occupational Safety Health Act, the legal use and adaptability of the Premises and the compliance thereof with all applicable laws and regulations in effect during the form of this Lease.
