Construction of the Project The Allottee has seen the proposed layout plan, specifications, amenities and facilities of the Apartment/ Plot and accepted the floor plan, payment plan and the specification, amenities and facilities annexed along with this Agreement which has been approved by the competent authority, as represented by the Promoter. The Promoter shall develop the Project in accordance with the said layout plans, floor plans and specifications, amenities and facilities. Subject to the terms in this Agreement, the Promoter undertakes to strictly abide by such plans approved by the competent authorities and shall also strictly abide by the bye-laws, FAR, and density norms and provisions prescribed by the relevant building bye-laws and shall not have an option to make any variation/ alteration/ modification in such plans, other than in the manner provided under the Act, and breach of this term by the Promoter shall constitute a material breach of this Agreement.
Completion of the Project The Contracting Party shall complete the construction, equipping and furnishing of the Improvements in accordance with the Plans and submit to the Board a Certificate of Completion on or before November 1, 2016.
Construction of the Improvements Once development of the Property has commenced, the construction of the Improvements shall be pursued with due diligence and continuity, in a good and workmanlike manner, and in accordance with sound building and engineering practices, all applicable governmental requirements, and the Development Plan. Borrower shall not permit cessation of work for a period in excess of thirty (30) days during any period of time during which development on the Property is scheduled to be performed without the prior written consent of Lender, which may be given or withheld in Lender’s sole discretion, except for delays due to strikes, riots, acts of God, war, unavailability of labor or materials, governmental laws, regulations or restrictions and Borrower shall promptly notify Lender of any such delays; provided, however, that in no event shall work cease for a period in excess of sixty (60) days regardless of the cause. Borrower shall cause all materials supplied for, or intended to be utilized in, the development of any part of the Property, but not affixed to or incorporated into the Property, to be stored on the Property or at such other location as may be approved by Lender in writing, with adequate safeguards, as required by Lender, to prevent loss, theft, damage, or commingling with other materials or projects.
Installation Where installation is required, Contractor shall be responsible for placing and installing the product in the required locations at no additional charge, unless otherwise designated on the Contract or purchase order. Contractor’s authorized product and price list shall clearly and separately identify any additional installation charges. All materials used in the installation shall be of good quality and shall be free of defects that would diminish the appearance of the product or render it structurally or operationally unsound. Installation includes the furnishing of any equipment, rigging, and materials required to install or replace the product in the proper location. Contractor shall protect the site from damage and shall repair damages or injury caused during installation by Contractor or its employees or agents. If any alteration, dismantling, excavation, etc., is required to achieve installation, the Contractor shall promptly restore the structure or site to its original condition. Contractor shall perform installation work so as to cause the least inconvenience and interference with Customers and with proper consideration of others on site. Upon completion of the installation, the location and surrounding area of work shall be left clean and in a neat and unobstructed condition, with everything in satisfactory repair and order.
Construction of the Tenant Improvements Landlord shall construct the Tenant Improvements in accordance with this exhibit and the construction contract to be executed by Landlord and its contractor(s). The construction contract for constructing the Tenant Improvements and the contractor(s) to perform the work shall be approved and/or selected, as the case may be, by Landlord at its sole and absolute discretion without the consent of Tenant.
Condition of the Premises Tenant has examined the Premises, including the appliances and fixtures ( and furnishings), and acknowledges that they are in good condition and repair, normal wear and tear excepted, and accepts them in its current condition, except for:
Operation of the Property During the Term, NAI shall operate the Property in a good and workmanlike manner and substantially in compliance with all Applicable Laws and will pay or cause to be paid all fees or charges of any kind in connection therewith. (If NAI does not promptly correct any failure of the Property to comply with Applicable Laws that is the subject of a written notice given to NAI or BNPLC by any governmental authority, then for purposes of the preceding sentence, NAI shall be considered not to have maintained the Property "substantially in accordance with Applicable Laws" whether or not the noncompliance would be substantial in the absence of the notice.) During the Term, NAI shall not use or occupy, or allow the use or occupancy of, the Property in any manner which violates any Applicable Law or which constitutes a public or private nuisance or which makes void, voidable or cancelable any insurance then in force with respect thereto. During the Term, to the extent that any of the following would, individually or in the aggregate, materially and adversely affect the value of the Property or NAI's use, occupancy or operations on the Property, NAI shall not, without BNPLC's prior consent: (i) initiate or permit any zoning reclassification of the Property; (ii) seek any variance under existing zoning ordinances applicable to the Property; (iii) use or permit the use of the Property in a manner that would result in such use becoming a nonconforming use under applicable zoning ordinances or similar laws, rules or regulations; (iv) execute or file any subdivision plat affecting the Property; or (v) consent to the annexation of the Property to any municipality. If (A) a change in the zoning or other Applicable Laws affecting the permitted use or development of the Property shall occur after the Base Rent Commencement Date that reduces the value of the Property, or (B) conditions or circumstances on or about the Property are discovered after the Base Rent Commencement Date (such as the presence of an endangered species) which substantially impede development and thereby reduce the value of the Property, and if after any such reduction under clause (A) or (B) preceding the Current AS IS Market Value of the Property is less than sixty percent (60%) of Stipulated Loss Value, then NAI shall pay BNPLC upon request the amount by which Current AS IS Market Value is less than sixty percent (60%) of Stipulated Loss Value, for application as a Qualified Prepayment. During the Term, NAI shall not cause or permit any drilling or exploration for, or extraction, removal or production of, minerals from the surface or subsurface of the Property, and NAI shall not do any act whereby the market value of the Property may reasonably be expected to be materially lessened. During the Term, if NAI receives a written notice or claim from any federal, state or other governmental entity that the Property is not in compliance in any material respect with any Applicable Law, or that any action may be taken against the owner of the Property because the Property does not comply with Applicable Law, NAI shall promptly furnish a copy of such notice or claim to BNPLC. Notwithstanding the foregoing, NAI may in good faith, by appropriate proceedings, contest the validity and applicability of any Applicable Law with respect to the Property, and pending such contest NAI shall not be deemed in default hereunder because of the violation of such Applicable Law, if NAI diligently prosecutes such contest to completion in a manner reasonably satisfactory to BNPLC, and if NAI promptly causes the Property to comply with any such Applicable Law upon a final determination by a court of competent jurisdiction that the same is valid and applicable to the Property; provided, however, in any event such contest shall be concluded and the violation of such Applicable Law must be corrected by NAI and any claims asserted against BNPLC or the Property because of such violation must be paid by NAI, all prior to the earlier of (i) the date that any criminal prosecution is instituted or overtly threatened against BNPLC or any of its directors, officers or employees because of such violation, (ii) the date that any action is taken by any governmental authority against BNPLC or any property owned by BNPLC (including the Property) because of such violation, or (iii) a Designated Sale Date upon which, for any reason, NAI or an Affiliate of NAI or any Applicable Purchaser shall not purchase BNPLC's interest in the Property pursuant to the Purchase Agreement for a price to BNPLC (when taken together with any additional payments made by NAI pursuant to Paragraph 1(A)(2) of the Purchase Agreement, in the case of a purchase by an Applicable Purchaser) equal to the Break Even Price.
Construction of Tenant Improvements After the Landlord and Ground Lessor (in accordance with Paragraph 12 hereof) approve Tenant’s Plans and Tenant receives any necessary building permits, Tenant shall administer and diligently prosecute the construction of Tenant Improvements in accordance with Tenant’s Plans, in compliance with applicable Laws, and using building standard material, subject to Landlord’s right, at its election, to itself construct the Restroom Improvements. All Tenant Improvements (other than, if applicable, the Restroom Improvements) shall be constructed by Tenant’s Contractor (and/or its subcontractors), and Tenant shall be responsible for project management with respect to construction of the Tenant Improvements. During construction of the Tenant Improvements, Tenant and its contractors and subcontractors (i) shall not interfere with the access to, use of, or business conducted within any other portions of the Project by other tenants or occupants, (ii) shall use diligent efforts to coordinate the timing of work, deliveries and other construction matters with tenants or occupants of the Project that could be adversely impacted by such work, deliveries and construction matters, including, without limitation, by scheduling work CERTAIN CONFIDENTIAL PORTIONS OF THIS EXHIBIT WERE OMITTED AND REPLACED WITH “[***]”. A COMPLETE VERSION OF THIS EXHIBIT HAS BEEN FILED SEPARATELY WITH THE SECRETARY OF THE SECURITIES AND EXCHANGE COMMISSION PURSUANT TO AN APPLICATION REQUESTING CONFIDENTIAL TREATMENT UNDER RULE 406 OF THE SECURITIES ACT OF 1933. that would create noise, vibrations, dust or other similar annoyances to other tenants or occupants of the Project outside normal business hours, notwithstanding any additional cost (for overtime or otherwise) that Tenant may incur, (iii) shall clean and secure construction and staging areas daily, (iv) shall stage all construction and store all construction materials and equipment in a location designated by Landlord (in Landlord’s sole discretion) on the Project, and (v) shall otherwise abide by all rules and requirements established or imposed by Landlord relating to the performance of the Tenant Improvements, including rules relating to any required shutdown of utilities (including life-safety systems), storage of materials, and coordination of work with other tenant’s or occupant’s contractors. Tenant shall not be charged any construction management fee for Landlord’s review of Tenant’s Plans or any oversight of the construction of the Tenant Improvements.
Delay of the Substantial Completion of the Premises Except as provided in this Section 5.2, the Lease Commencement Date shall occur as set forth in the Lease and Section 5.1, above. If there shall be a delay or there are delays in the Substantial Completion of the Premises or in the occurrence of any of the other conditions precedent to the Lease Commencement Date, as set forth in the Lease, as a direct, indirect, partial, or total result of:
Maintenance Repairs and Alterations Landlord hereby covenants that the Premises shall be in reasonably good and usable condition as of the effective date of this Agreement. Replacements made by Landlord, if any, shall belong to it. Landlord shall keep access to the Premises free and clear of any and all obstructions including snow and ice. ** Portions of this agreement have been omitted and filed separately with the SEC pursuant to a confidential treatment request CONFIDENTIAL EXECUTION VERSION In the event of an emergency, Tenant shall have the right to perform any obligation of Landlord under this Agreement and recover from Landlord any reasonable amounts so expended by Tenant within thirty (30) days of the date of demand or, in the alternative, to offset amounts so expended against Rent. Landlord shall, at its sole expense, make structural repairs and replacements to the footings, foundation and structural elements of walls and roofs of the Premises and also shall be responsible for maintenance, repairs and replacements, at its sole expense, of heating, ventilating, air conditioning systems, plumbing systems, and electrical systems, provided, however, that Tenant, at its sole expense, shall be responsible for maintenance, repairs and replacements regarding the irrigation system on the Premises as well as Tenant's occupancy costs as described above in Section 4 of this Agreement and shall also be responsible for maintenance, repairs or replacements necessitated by Tenant's actions. Contact information for the Landlord in case of any maintenance, repair or replacement issues is as follows: [**]1 Additions, improvements and alterations made by Tenant, whether temporary or permanent in nature, shall be subject to the prior approval of Landlord and upon completion shall belong to Tenant, provided that removal may be made without damage to the Premises at the expiration of the Agreement term. If removal of the improvements or alterations would cause damage to the Premises, said improvements and alterations shall automatically become the property of Landlord. Tenant, at its sole expense, shall be responsible for maintenance, repairs and replacements of any additions, improvements or alterations made by Tenant on, in or to the Premises. Tenant shall keep the Premises in good order, repair and condition at all times during the Agreement term, except for ordinary wear and tear.
