Implementation of Change Order Costs Sample Clauses

Implementation of Change Order Costs. The cost of any work proposed in any Change Order (including the cost to revise previously approved construction drawings and/or Final Plans) shall be at the sole cost and expense of Lessee. If Lessee requests any changes to any previously approved plans, and Lessor agrees to make such changes, Lessor shall promptly give Lessee an estimate of the cost of such changes and the resulting delay in the delivery of the Premises to Lessee (“Change Cost and Delay Estimate”). Within three (3) business days after receipt of the Change Cost and Delay Estimate, Lessee shall give Lessor notice whether Lessee elects to proceed with such changes. If Lessee notifies Lessor in writing that Lessee elects to proceed with such changes, Lessor shall, subject to the terms of this Exhibit C, promptly make such changes. Lessee acknowledges its agreement that any change, addition or alteration requested by Lessee in the layout or configuration of the Premises from that shown on the Final Plans, or any change, modification or alteration in the electrical, mechanical and HVAC systems servicing the Premises attributable to any of the foregoing changes may result in a Lessee Delay, and that any reasonable cost to Lessor of incorporating any approved Change Orders shall be added to the Improvement Costs and paid for by Lessee pursuant to the method of payment for the Improvement Costs described in section 3.4 of this Work Letter, which demand shall include reasonable detail of the costs incurred.
Sample 1
AutoNDA by SimpleDocs

Related to Implementation of Change Order Costs

  • Implementation of Changes If Tenant: (i) approves in writing the cost or savings and the estimated extension in the time for completion of Landlord’s Work, if any, and (ii) deposits with Landlord any Excess TI Costs required in connection with such Change, Landlord shall cause the approved Change to be instituted. Notwithstanding any approval or disapproval by Tenant of any estimate of the delay caused by such proposed Change, the TI Architect’s determination of the amount of Tenant Delay in connection with such Change shall be final and binding on Landlord and Tenant.

  • Execution of Change Orders Change Orders shall be signed by the Contractor, ordinarily certified by the Design Professional, and approved by the Owner in accordance with the form of Change Order prescribed by the Owner. No request for payment by the Contractor for a Change Order shall be due, nor shall any such request appear on an Application for Payment, until the Change Order is executed by the Owner. In the event of emergency (see Article 1.4.4) or significant impact to the Overall Project Schedule, the Owner shall direct the Change Order to proceed upon a Force Account until the cost and time is resolved in the manner set forth in Paragraph 3.2.7.3 below.

  • Implementation Schedule TIME IS OF THE ESSENCE with regard to all dates and time periods set forth and/or incorporated herein. Any material modification or deviation from an approved schedule described in this Agreement shall occur only upon approval of the City and RDA, with any such approvals required to be in writing as an amendment to this Agreement, and which approvals shall not be unreasonably withheld. City shall cooperate and act promptly with respect to any and all permits or approvals necessary for completion of the Project. Notwithstanding the above, this Agreement shall not limit the discretion of the City, or any of its duly appointed and authorized governing bodies, boards or entities, in approving or rejecting any aspect of the Project or improvements contemplated on or about the Property.

  • Implementation of Agreement Each Party must promptly execute all documents and do all such acts and things as is necessary or desirable to implement and give full effect to the provisions of this Agreement.

  • Implementation of Corrective Action Plan After the Corrective Action Plan is finalized, the Purchasers shall use reasonable best efforts to implement the finalized Corrective Action Plan on the timeline set forth therein and provide periodic reports (as provided for therein) to the Sellers on the status of their implementation of the Corrective Action Plan.

  • Project Implementation 2. The Borrower shall:

  • Change Orders Any alteration or deviation from the Services mentioned or any other contractual specifications that result in a revision of this Agreement shall be executed and attached to this Agreement as a change order (“Change Order”).

  • Construction Change Directives 7.3.1 A Construction Change Directive is written order prepared by the Architect and signed by the Owner and Architect, directing a change in the Work and stating a proposed basis for adjustment, if any, in the Contract Sum, or Contract Time, or both. The Owner may by Construction Change Directive, without invalidating the Contract, order changes in the Work within the general scope of the Contract consisting of additions, deletions or other revisions, the Contract Sum and Contract Time being adjusting accordingly.

  • COOPERATION IN IMPLEMENTATION On demand of the other Spouse and without undue delay or expense, each Spouse shall execute, acknowledge, or deliver any instrument, furnish any information, or perform any other acts reasonably necessary to carry out the provisions of this Agreement. If a Spouse fails to execute any document as required by this provision, the court may appoint the court clerk or his or her authorized designee to execute the document on that Xxxxxx’s behalf.

  • Project Changes 1.8.1. All changes shall be administered per the UGC.

Time is Money Join Law Insider Premium to draft better contracts faster.