Coordinating Professional State projects Sample Clauses

Coordinating Professional State projects. State has designated its Roadway Design Engineer as the Coordinating Professional (defined in § 81 3408) for this project as required by Neb. Rev. Stat. § 81-3437.02 of the Nebraska Engineers and Architects Regulation Act (Neb. Rev. Stat § 81-3104 et seq.). The Coordinating Professional will apply his or her seal and signature and the date to the cover sheet of all documents and denote the seal as that of the Coordinating Professional. The Coordinating Professional will verify that all design disciplines involved in the project are working in coordination with one another, and that any changes made to the design are approved by the corresponding discipline. The Coordinating Professional shall also comply with the provisions of the Act, including Neb. Rev. Stat. § 81-3437(3)(f), and the implementing Rules and Regulations, Title 110, NAC section 6.3, and when applicable, will complete the duties of design coordination set out in Neb. Rev.
Sample 1
AutoNDA by SimpleDocs
Coordinating Professional State projects. State has designated its Roadway Design Engineer as the Coordinating Professional (defined in § 81 3408) for this project as required by Neb.Rev.Stat. § 81-3437.02 of the Nebraska Engineers and Architects Regulation Act (Neb.Rev.Stat § 81-3104 et seq.)., State has designated its Roadway Design Engineer as the Coordinating Professional for this project. The definition of “Coordinating Professional” set out in § 81 3408 (Neb. Rev. Stat. § 81-3401 et seq.) of the Nebraska Engineers and Architects Regulation Act applies. The Coordinating Professional shall will apply his or her seal and signature and the date to the cover sheet of all documents and denote the seal as that of the Coordinating Professional. The Coordinating Professional shall verify that all design disciplines involved in the project are working in coordination with one another, and that any changes made to the design are approved by the corresponding discipline. The Coordinating Professional shall also comply with the provisions of the Act, including Neb.Rev.Stat. § 81-3437(3)(f), and the implementing Rules and Regulations, Title 110, NAC section 6.3, and when applicable, will complete the duties of design coordination set out in Neb.Rev.
Sample 1

Related to Coordinating Professional State projects

  • Engineer's Coordination with Owner Engineer shall be available for conferences with City so that Project can be designed with the full benefit of City's experience and knowledge of existing needs and facilities and be consistent with current policies and construction standards. City shall make available to Engineer all existing plans, maps, field notes, and other data in its possession relative to the Project. Engineer may show justification to City for changes in design from City standards due to the judgment of said Engineer of a cost savings to City and/or due to the surrounding topographic conditions. City shall make the final decision as to any changes after appropriate request by Engineer.

  • PROFESSIONAL DEVELOPMENT AND EDUCATIONAL IMPROVEMENT A. The Board agrees to implement the following:

  • PROFESSIONAL IMPROVEMENT A. The parties’ support the principle of continuing training of teachers, participation by teachers in professional organizations in the areas of their specialization, leaves for work on advanced degrees or special studies, foreign travel and participation in community educational projects.

  • Construction Management Plan Contractor shall prepare and furnish to the Owner a thorough and complete plan for the management of the Project from issuance of the Proceed Order through the issuance of the Design Professional's Certificate of Material Completion. Such plan shall include, without limitation, an estimate of the manpower requirements for each trade and the anticipated availability of such manpower, a schedule prepared using the critical path method that will amplify and support the schedule required in Article 2.1.5 below, and the Submittal Schedule as required in Article 2.2.3. The Contractor shall include in his plan the names and resumés of the Project Superintendent, Project Manager and the person in charge of Safety.

  • Architect/Engineer (A/E) means a person registered as an architect pursuant to Tex. Occ. Code Xxx., Chapter 1051, as a landscape architect pursuant to Tex. Occ. Code Xxx., Chapter 1052, a person licensed as a professional engineer pursuant to Tex. Occ. Code Xxx., Chapter 1001 and/or a firm employed by Owner or a design-build contractor to provide professional architectural or engineering services and to exercise overall responsibility for the design of a Project or a significant portion thereof, and to perform the contract administration responsibilities set forth in the Contract.

  • Project Coordination The Engineer shall coordinate all subconsultant activity to include quality and consistency of deliverables and administration of the invoices and monthly progress reports. The Engineer shall coordinate with necessary local entities.

  • City’s Project Manager The City’s Project Manager is Xxxxxx Xxxxxxxx. The City shall give Contractor prompt written notice of any re-designation of its Project Manager.

  • Contractor’s Project Manager 7.2.1 The Contractor’s Project Manager is designated in Exhibit F (Contractor’s Administration). The Contractor shall notify the County in writing of any change in the name or address of the Contractor’s Project Manager.

  • Construction Activities Please list all major construction activities, both planned and completed, to be performed by Seller or the EPC Contractor. Activity EPC Contractor / Subcontractor Completion Date __/__/____ (expected / actual) __/__/____ (expected / actual)

  • County’s Project Manager Note: The written approval of substituted A-E Key Personnel is for departmental use only and shall not be used for auditing purposes outside OC Public Works or other County department.

Time is Money Join Law Insider Premium to draft better contracts faster.