Authorization to Proceed with a Service Work Order Sample Clauses

Authorization to Proceed with a Service Work Order. 2.3.3.1. Upon notification of Service Work Order acceptance in CAFM by the Contractor, the Judicial Council shall direct the Contractor to begin Work in writing according to the terms herein.
Sample 1Sample 2Sample 3See All (7)
AutoNDA by SimpleDocs
Authorization to Proceed with a Service Work Order. Upon notification of Service Work Order acceptance in CAFM by the Contractor, the Judicial Council shall direct the Contractor to begin Work in writing according to the terms herein. Following authorization of a Service Work Order, but before the initiation of Work on a Project, the Judicial Council may furnish additional detailed written and/or graphic instructions to explain the Work more fully, and such instructions become a part of the requirements of the authorized Service Work Order applicable to a Project. Should such additional detailed instructions, in the opinion of Contractor, constitute Work in excess of the requirements of the authorized Service Work Order, Contractor must submit written notice of the same to the Judicial Council within seven (7) Days following receipt of such instructions, and in any event no later than prior to commencement of the Work of the Project. If in the Judicial Council’s judgment, the additional detailed instructions do in fact constitute Work in excess of the requirements of the authorized Service Work Order, the Judicial Council may, at Judicial Council’s option, either close the authorized Service Work Order and create a new Service Work Order or issue a Change Order to account for the additional Work. Only the following Judicial Council’s personnel are approved to authorize a SWO(s): Senior Manager for Facility Management; Regional Manager for Facilities Operations; Project Managers; Supervising Facilities Management Administrators; Facilities Management Administrators; Judicial Council Customer Service Center Personnel.
Sample 1

Related to Authorization to Proceed with a Service Work Order

  • Authorization to Proceed A fully executed and approved authorization in the form of Attachment 6 to this Agreement, Authorization to Proceed (“ATP”) accompanied by an executed purchase order document issued by the Owner to the Project Consultant, authorizing the performance of specific professional services, authorizing commencement of a Phase as defined in Article 2.1 through Article 2.8, and stating the time for completion and the amount of fee authorized for such services.

  • Authorization to Perform Services The Consultant is not authorized to perform any services or incur any costs whatsoever under the terms of this Agreement until receipt of a written Notice to Proceed from the City.

  • Authorization of Services a. The Contractor and its subcontractors shall have in place, and follow, written authorization policies and procedures.

  • Suspension of Work Authorization DocuSign Envelope ID: 117D111C-A794-4428-BDF3-5CF841540F29

  • CHANGES TO PRODUCT OR SERVICE OFFERINGS a. Product or Service Discontinuance Where Contractor is the Product Manufacturer/Developer, and Contractor publicly announces to all U.S. customers (“date of notice”) that a Product is being withdrawn from the U.S. market or that maintenance service or technical support provided by Contractor (“withdrawn support”) is no longer going to be offered, Contractor shall be required to: (i) notify the Commissioner, each Licensee and each Authorized User then under contract for maintenance or technical support in writing of the intended discontinuance; and (ii) continue to offer Product or withdrawn support upon the Contract terms previously offered for the greater of: a) the best terms offered by Contractor to any other customer, or b) not less than twelve (12) months from the date of notice; and (iii) at Authorized User’s option, provided that the Authorized User is under contract for maintenance on the date of notice, either: provide the Authorized User with a Product replacement or migration path with at least equivalent functionality at no additional charge to enable Authorized User to continue use and maintenance of the Product. In the event that the Contractor is not the Product Manufacturer, Contractor shall be required to: (i) provide the notice required under the paragraph above, to the entities described within five (5) business days of Contractor receiving notice from the Product Manufacturer, and (ii) include in such notice the period of time from the date of notice that the Product Manufacturer will continue to provide Product or withdraw support. The provisions of this subdivision (a) shall not apply or eliminate Contractor’s obligations where withdrawn support is being provided by an independent Subcontractor. In the event that such Subcontractor ceases to provide service, Contractor shall be responsible for subcontracting such service, subject to state approval, to an alternate Subcontractor.

  • Notice to Proceed - Site Improvements The Recipient shall not commence, or cause to be commenced, any site improvements or other work on the Land until the Director has issued a Notice to Proceed to the Recipient. Such Notice to Proceed will not be issued until the Director is assured that the Recipient has complied with all requirements for the approval of a grant under Revised Code Sections 164.20 through 164.27 and has completed any land acquisition required by the Project. A Notice to Proceed shall be required for all Project prime contractors or direct procurement initiated by the Recipient following execution of this Agreement.

  • COMMERCIAL REUSE OF SERVICES The member or user herein agrees not to replicate, duplicate, copy, trade, sell, resell nor exploit for any commercial reason any part, use of, or access to 's sites.

  • Governing Law; Submission to Process EXCEPT TO THE EXTENT THAT THE LAW OF ANOTHER JURISDICTION IS EXPRESSLY ELECTED IN A TRANSACTION DOCUMENT, THIS AGREEMENT AND THE OTHER TRANSACTION DOCUMENTS, SHALL BE GOVERNED BY AND CONSTRUED IN ACCORDANCE WITH THE INTERNAL LAWS OF THE STATE OF NEW YORK, WITHOUT REGARD TO PRINCIPLES OF CONFLICTS OF LAW. EACH OF BIONOVA AND SAVIA HEREBY IRREVOCABLY SUBMITS ITSELF AND EACH OTHER RELATED PERSON TO THE NON-EXCLUSIVE JURISDICTION OF THE STATE AND FEDERAL COURTS SITTING IN THE STATE OF NEW YORK AND THE COUNTY OF NEW YORK AND AGREES AND CONSENTS THAT SERVICE OF PROCESS MAY BE MADE UPON IT OR ANY OF ITS SUBSIDIARIES IN ANY LEGAL PROCEEDING RELATING TO THE TRANSACTION DOCUMENTS BY ANY MEANS ALLOWED UNDER NEW YORK OR FEDERAL LAW. EACH OF BIONOVA AND SAVIA IRREVOCABLY WAIVES, TO THE FULLEST EXTENT PERMITTED BY APPLICABLE LAW, ANY OBJECTION THAT IT MAY NOW OR HEREAFTER HAVE TO THE LAYING OF THE VENUE OF ANY SUCH PROCEEDING BROUGHT IN SUCH A COURT AND ANY CLAIM THAT ANY SUCH PROCEEDING BROUGHT IN SUCH A COURT HAS BEEN BROUGHT IN AN INCONVENIENT FORUM.

  • Work Authorization By entering into this Agreement, the Judicial Council only authorizes the Criteria Architect to begin its Work on the Phase indicated on the Coversheet of the Agreement. The Judicial Council has the sole and unilateral right to authorize additional Phases, however, those authorizations will be made in the form of an amendment pursuant to this Agreement, authorizing the appropriate Phase and funding specified herein, which must be executed by the Criteria Architect and the Judicial Council. Work for additional Phases added to the Agreement by amendment will be authorized using Notice to Proceed. Criteria Architect is not authorized to begin any work or services marked “NYA” (Not Yet Authorized).

  • New Work Authorization If the Engineer does not complete the services authorized in a work authorization before the specified completion date and has not requested a supplemental work authorization, the work authorization shall terminate on the completion date. At the sole discretion of the State, it may issue a new work authorization to the Engineer for the incomplete work using the unexpended balance of the preceding work authorization for the project. If approved by the State, the Engineer may calculate any additional cost for the incomplete work using the rates set forth in the preceding work authorization and in accordance with Attachment E, Fee Schedule.

Time is Money Join Law Insider Premium to draft better contracts faster.