Liquidated Delay Damages definition

Liquidated Delay Damages means: For all days commencing with the Commercial Operation Milestone Date, an amount equal to Three Hundred Dollars ($310) per MW per Day for each MW below ninety percent (90%) of the Facility’s then anticipated aggregate MW of Nameplate Capacity that have not been installed by the Commercial Operation Milestone. For example, if 100 MW of Solar Panels have been installed as of the Commercial Operation Milestone, Seller shall pay Buyer damages of ([Facility Size] MW * 90%) – (100 MW) * $310/MW/day = $ per day for each day up to and including March 31, 2024 in which 90% of the Facility’s anticipated Nameplate Capacity has not been completed. [Note: Example to be scaled to actual project size.]
Sample 1
Liquidated Delay Damages shall have the meaning set forth in Section 12.2. "Maintenance Schedule" shall have the meaning set forth in Section 10.2.
Sample 1
Liquidated Delay Damages means any amount payable to or for the account of the Borrower under Section 12.1 of the EPC Contract or any other agreement as a result of delayed delivery or performance with respect to the Project or any goods or services supplied in connection with the Project.
Sample 1

Examples of Liquidated Delay Damages in a sentence

  • Except as provided in Section 12.2(C) below, the payment of Liquidated Delay Damages shall be Company’s sole and exclusive remedy for a COD Delay.

  • The payment of accrued Liquidated Delay Damages shall be a condition to any such cure.

  • Liquidated Delay Damages shall begin to accrue on the Day after the Target COD (as it may be extended due to Force Majeure) until the first to occur of COD or termination of this PPA pursuant to Section 12.2(C) below.

  • Seller’s failure to make any payment to Company as and when required by this PPA, including Liquidated Delay Damages, Actual Damages, and any required indemnification.

  • Company may draw from the Security Fund such amounts as are necessary to recover amounts owing to Company pursuant to this PPA, including any Liquidated Delay Damages, Actual Damages, liquidated damages for failure to achieve COD, and any amounts for which Company is entitled to indemnification under this PPA.

  • Upon such an Event of Default, Company may (i) terminate this PPA immediately upon notice to Seller, without penalty or further obligation to Seller except as to costs and balances incurred prior to the effective date of such termination, and (ii) in connection therewith, in addition to accrued Liquidated Delay Damages but in lieu of Actual Damages for the balance of the Term, collect from Seller liquidated damages therefor in the amount of [ dollars ($ )] (“Termination LDs”).

  • Upon such an Event of Default, Company may (i) terminate this PPA immediately upon notice to Seller, without penalty or further obligation to Seller except as to costs and balances incurred prior to the effective date of such termination, and (ii) in connection therewith, in addition to accrued Liquidated Delay Damages but in lieu of Actual Damages for the balance of the Term, collect from Seller liquidated damages therefor in the amount of [insert $100/kW × Net Capability] (“Termination LDs”).

  • In addition, the data acquisition system shall create a record of all required data for storage, review, and reporting.

  • Liquidated Delay Damages shall begin to accrue on the Day after the Target until the first to occur of COD or termination of this PPA pursuant to Section 12.2(C) below.

  • Upon such an Event of Default, Company may (i) terminate this PPA immediately upon notice to Seller, without penalty or further obligation to Seller except as to costs and balances incurred prior to the effective date of such termination, and (ii) in connection therewith, in addition to accrued Liquidated Delay Damages but in lieu of Actual Damages for the balance of the Term, collect from Seller liquidated damages therefor in the amount of [insert $100/kW x Facility Nameplate Capacity].


More Definitions of Liquidated Delay Damages

Liquidated Delay Damages means $200 per MW of Facility Nameplate Capacity per Day..
Sample 1

Related to Liquidated Delay Damages

  • Daily Delay Damages means with respect to a Guaranteed Project Milestone, an amount equal to (a) the Project Development Security Amount posted as of the first date that Daily Delay Damages are payable under this Agreement with respect to such Guaranteed Project Milestone, divided by (b) 120.

  • Delay Damages means the damages assessed pursuant to Section 3.2(a) hereof.

  • Delay Liquidated Damages has the meaning set forth in Section 13.1.

  • Performance Liquidated Damages means any liquidated damages resulting from the Project’s performance which are required to be paid by the EPC Contractor or any other Material Project Party for or on account of any diminution to the performance of the Project.

  • Allowed Delay has the meaning set forth in Section 2(c)(ii).

  • Liquidated Damages Multiplier means the product of (i) the Purchased Unit Price and (ii) the number of Registrable Securities then held by the applicable Holder and included on the applicable Registration Statement.

  • Daily Failure Amount means the product of (x) .005 multiplied by (y) the Closing Sale Price of the Common Stock on the applicable Share Delivery Date.

  • Economic damages means objectively verifiable monetary losses, including medical expenses, loss of earnings, burial costs, loss of use of property, cost of replacement or repair, cost of obtaining substitute domestic services, loss of employment, and loss of business or employment opportunities.

  • Compensatory Damages are those amounts awarded to compensate for the actual damages sustained, and are not awarded as a penalty, nor fixed in amount by statute.

  • Liquidated Damages Amount has the meaning set forth in Section 2(e) hereof.

  • Force Majeure Delay means with respect to the Servicer, any cause or event which is beyond the control and not due to the negligence of the Servicer, which delays, prevents or prohibits such Person’s delivery of the reports required to be delivered or the performance of any other duty or obligation of the Servicer under the Indenture, as the case may be, including, without limitation, computer, electrical and mechanical failures, acts of God or the elements and fire; provided, that no such cause or event shall be deemed to be a Force Majeure Delay unless the Servicer shall have given the Indenture Trustee written notice thereof as soon as practicable after the beginning of such delay.

  • Excused Downtime means the number of minutes in the Charging Period, rounded to the nearest minute that the link state of Customer’s Port is ‘down’ due to:

  • Excusable Delay means a delay due to acts of God, governmental restrictions, stays, judgments, orders, decrees, enemy actions, civil commotion, fire, casualty, strikes, work stoppages, shortages of labor or materials or other causes beyond the reasonable control of Borrower, but lack of funds in and of itself shall not be deemed a cause beyond the control of Borrower.

  • Noneconomic damages ’ means damages for phys-

  • Common expense liability means the liability for common

  • Force Majeure Delays means any actual delay in the construction of the Tenant Improvements, which is beyond the reasonable control of Landlord or Tenant, as the case may be, as described in Paragraph 33 of the Lease.

  • SPECIAL LIQUIDATED DAMAGES means the amount payable by the Transport Supplier in case of default arising out of Non-availability of vehicle(s)/crew when the Company's operations are normal and also Non-availability of services due to unauthorized / lightening strike by Transport Supplier or his/her crew for any reason whatsoever. The period of non-availability of services will be treated as shutdown and shall attract Special Liquidated damage at the rate of twice the pro- rata fixed charge per day. Special L.D. shall be levied irrespective of whether such default resulted in a shutdown for the whole day or part thereof.

  • Catastrophic Damage as used hereunder is major change or damage to In- cluded Timber on Sale Area, to Sale Area, to access to Sale Area, or a combination thereof:

  • Landlord Delay means any actual delay in the completion of the Improvements as a result of Landlord’s breach or material default under this Third Amendment (including, without limitation, any breach of representation or warranty); any delays relating to any of the matters specified in Section 5.3 of Exhibit B; any failure to respond to any items required to be furnished or approved by Landlord within a time period expressly set forth in this Third Amendment or the Lease (unless a deemed approval is specified, in which case no Landlord Delay shall be assessed); Landlord’s failure to allow contractors access to the Building or Premises as scheduled in advance with the Building’s property manager or Landlord’s request for material changes in the fmal Plans and Specifications after Landlord’s approval thereof (unless such request was caused by an error or omission by Tenant), provided, however, that notwithstanding the foregoing, no Landlord Delay shall be deemed to have occurred unless and until Tenant has delivered to Landlord a factually correct written notice (the “Landlord Delay Notice”), specifying the bona fide action or inaction which Tenant contends constitutes the Landlord Delay. If such action or inaction is not cured by Landlord within two (2) business days of Landlord’s receipt of such Landlord Delay Notice, then the Landlord Delay shall be deemed to have occurred as of the expiration of such two (2) business day period. A delay in construction of the Improvements due to a Tenant Delay (as defined in Exhibit B, attached to and part of the Original Lease), any Force Majeure event or a delay by any governmental authority (including but not limited to the City of Los Angeles) shall not be deemed a Landlord Delay. Any Landlord Delay Notice shall be sent to the notice address set forth in the Lease with copies to (a) to the property manager at the management office of the Building; and to (b) Xxxxxxx Xxxxxx Management LLC, 000 Xxxxxxxx Xxxxxxxxx, Xxxxx 000, Xxxxx Xxxxxx, Xxxxxxxxxx 00000, Attention: Leasing Legal Department Manager.

  • Damages Accrual Period has the meaning set forth in Section 2(e) hereof.

  • Transaction Failure Date means the 18-month anniversary of the Effective Date (or the 24 month anniversary of the Effective Date, if a letter of intent, agreement in principle or definitive agreement has been executed within 18 months after the Effective Date and the Business Combination relating thereto has not yet been consummated within such 18-month period).

  • Aggregate Amounts Due as defined in Section 2.17.

  • Delay Period shall have the meaning set forth in Section 5 hereof.

  • Excusable Delays means delays due to acts of terrorism, acts of war or civil insurrection, strikes, riots, floods, earthquakes, fires, tornadoes, casualties, acts of God, labor disputes, governmental restrictions or priorities, embargoes, national or regional material shortages, failure to obtain regulatory approval from any Federal or State regulatory body, unforeseen site conditions, extraordinary rainfall or snowfall, or any other condition or circumstances beyond the reasonable or foreseeable control of the applicable Party using reasonable diligence to overcome which prevents such Party from performing its specific duties or obligation hereunder in a timely manner; provided, however, Excusable Delay does not include lack of financing, unanticipated or unexpected increases in the costs of construction, or errors in business judgment by a Party; and provided further that Excusable Delay shall only extend the time of performance for the period of such Excusable Delay, which shall begin on the date which the event of Excusable Delay first occurs and extend until the date which the event which has caused the Excusable Delay has been corrected or performed, or reasonably should have been corrected or performed.

  • Severe property damage means substantial physical damage to property, damage to the treatment facilities which would cause them to become inoperable, or substantial and permanent loss of natural resources which can reasonably be expected to occur in the absence of a bypass. Severe property damage does not mean economic loss caused by delays in production.

  • Maximum Potential Additional Dividend Liability, as of any Valuation Date, means the aggregate amount of Additional Dividends that would be due if the Corporation were to make Retroactive Taxable Allocations, with respect to any fiscal year, estimated based upon dividends paid and the amount of undistributed realized net capital gains and other taxable income earned by the Corporation, as of the end of the calendar month immediately preceding such Valuation Date and assuming such Additional Dividends are fully taxable.