Project Completion Within five (5) days after the delivery by Supplier to Purchaser of a Commissioning Certificate for the Project’s final Turbine, Supplier shall also deliver to Purchaser a completion certificate for all Turbines in the Project (the “Project Completion Certificate”), in the form attached hereto as Exhibit N, together with a list of any remaining Punch List Work on any Turbine, a schedule for completing the Punch List Work and an estimate of the cost of each item of Punch List Work. Supplier shall thereafter promptly complete all Punch List Work.
Feasibility Study Buyer is granted the right to conduct engineering and/or market and economic feasibility studies of the Property and a physical inspection of the Property, including studies or inspections to determine the existence of any environmental hazards or conditions (collectively, the “Feasibility Study”) during the period (the “Feasibility Period”) commencing on the Effective Date and ending at 5:00 p.m., Central Time, on the June 3, 2010. With Seller’s permission, after Seller has received advance notice sufficient to permit it to schedule in an orderly manner Buyer’s examination of the Property and to provide at least 24-hours’ advance written notice to any affected tenants, Buyer or its designated agents may enter upon the Property during normal business hours for purposes of analysis or other tests and inspections which may be deemed necessary by Buyer for the Feasibility Study. Buyer or its designated representative must be accompanied by a designated representative of Seller or have received Seller’s written permission prior to entering upon the Property in connection with Buyer’s Feasibility Study; provided, however, Buyer may not enter into any space leased by any tenant without being accompanied by a designated representative of Seller. Seller agrees to make its representative reasonably available during normal business hours. Buyer will not alter the physical condition of the Property or conduct invasive testing without notifying Seller of its requested tests, and obtaining the written consent of Seller to any physical alteration of the Property or invasive testing. Buyer will utilize commercially reasonable diligence to conduct or cause to be conducted all inspections and tests in a manner and at times which will not unreasonably interfere with any tenant’s use and occupancy of the Property. If Buyer determines, in its sole judgment, that the Property is not suitable for any reason for Buyer’s intended use or purpose, or is not in satisfactory condition, then Buyer may terminate this Contract by written notice to Seller prior to expiration of the Feasibility Period, in which case the Xxxxxxx Money (other than the Option Money) will be returned to Buyer, and neither party shall have any further right or obligation hereunder other than as set forth herein with respect to rights or obligations which survive termination. If this Contract is not terminated pursuant to this Section 5(a), then after expiration of the Feasibility Period, after Seller has received advance notice sufficient to permit it to schedule in an orderly manner Buyer’s examination of the Property and to provide at least 24-hours’ advance written notice to any affected tenants, Buyer or its designated agents may enter upon the Property during normal business hours. Buyer or its designated representative must be accompanied by a designated representative of Seller or have received Seller’s written permission prior to entering upon the Property; provided, however, Buyer may not enter into any space leased by any tenant without being accompanied by a designated representative of Seller. If this Contract is not timely terminated pursuant to this Section 5(a), Buyer’s right to terminate this Contract pursuant to this Section 5(a) and any and all objections with respect to the Feasibility Study will be deemed to have been waived by Buyer for all purposes.
Development Work Do, or cause to be done, such development and other work as may be reasonably necessary to protect from diminution and production capacity of the Mortgaged Property and each producing well thereon.
Information Systems Acquisition Development and Maintenance a. Client Data – Client Data will only be used by State Street for the purposes specified in this Agreement.
Completion 5.1 Completion shall take place on the Completion Date:
Development of the Project The Board of Managers shall take such actions as shall be required to cause either the Company or the Management Company (as defined in Section 9(b) below) to perform and complete the construction and other development work as contemplated and/or required under the NVR Purchase and Sale Agreements, or any other construction company selected by the Board of Managers (the “Development Work”), substantially in accordance with the Project Plan, at a cost to the Company not exceeding the total cost set forth in the Budget, in a manner consistent with this Agreement and all applicable laws, ordinances, rules, regulations or requirements (including, without limitation, those with respect to discrimination) of governmental authorities, and in compliance with any covenants, conditions or restrictions affecting all or any portion of the Property.
Substantial Completion The Tenant Improvements shall be deemed to be “Substantially Completed” on the date that (i) the Tenant Improvements are essentially and satisfactorily completed in accordance with the Final Plans to the extent that the Leased Premises may be occupied by Tenant for its Approved Use, subject only to completion of minor finishing, adjustment of equipment, and other minor construction aspects (“punch list items”) which do not, in the aggregate, cause interference (other than minor inconvenience) with the use and occupancy of the Leased Premises for the Approved Use, and (ii) a certificate of occupancy, whether conditional or final, has been issued by the proper governmental authority. Landlord shall give Tenant at least 30 days prior notice (written or oral) of Landlord’s reasonable estimate of the date of Substantial Completion of the Tenant Improvements. Tenant shall schedule with Landlord a mutually acceptable date, which will not be later than 3 business days after the date of Substantial Completion (but in no event earlier than the Landlord’s estimated date of Substantial Completion), for a walk-through inspection of the Leased Premises. In such walk-through, Landlord and Tenant will mutually and reasonably agree upon a punch list, and subject to Tenant Delay, Landlord will use reasonable efforts to cause such punch list work to be completed within 30 days after such walk-through. Landlord hereby warrants to Tenant, which warranty shall survive for one year following the date of Substantial Completion of the Tenant Improvements, that (a) the materials and equipment furnished by Landlord and Landlord’s contractors in the completion of the Tenant Improvements will be of good quality and new, and (b) such materials and equipment and the work of such contractors shall be free from defects not inherent in the quality required or permitted hereunder. This warranty shall exclude damages or defects caused by Tenant, its agents, employees or contractors, improper or insufficient maintenance, improper operation or normal wear and tear under normal usage. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by November 1, 2018. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed on or before December 1, 2018, (the “Fifth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fifth Floor Substantial Completion Date that the Tenant Improvements for the Fifth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fifth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the Commencement Date and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Landlord shall use diligent and good faith efforts to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed by February 1, 2019. Subject only to Force Majeure (as defined in §11 hereof) and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required construction permits for the Tenant Improvements (the “Construction Permits”) by not later than June 30, 2018, then in the event that Landlord fails to cause the Tenant Improvements for the Fourth Floor Premises to be Substantially Completed on or before March 1, 2019, (the “Fourth Floor Substantial Completion Date”), Tenant shall be entitled to a day-for-day credit of Base Rent due as of the Commencement Date, for each day after the Fourth Floor Substantial Completion Date that the Tenant Improvements for the Fourth Floor Premises are not Substantially Completed; provided, however, that, for every day of delay which results from a Tenant Delay or a Force Majeure, the Fourth Floor Substantial Completion Date shall be moved back on a day-for-day basis. Such day-for-day credit of Base Rent shall commence upon the June 1, 2019, and shall continue until applied in full; provided that at no time may Tenant offset more than 50% of the Base Rent amount due each month until such abatement has been completed. Subject only to Force Majeure and Tenant Delay, and provided that Landlord, using good faith efforts, obtains all required Construction Permits by not later than June 30, 2018, if the Tenant Improvements for the Leased Premises are not Substantially Completed on or before April 1, 2019 (“Outside Completion Date”), then Tenant shall have the one-time right by not later than 10 days after the Outside Completion Date to terminate this lease by delivering written notice to Landlord, which notice shall be hand delivered to 0000 Xxxx Xxxxx Xxxxx, Xxxxxxxx, Xxxx 00000, Attention: Xxxxxx X. Xxxxx, Xx., and upon hand delivery of such termination notice to said address, this lease shall be deemed null and void and the parties shall have no further rights or obligations hereunder, except those that specifically survive the expiration or earlier termination of this lease. Landlord and Tenant acknowledge and agree that Tenant’s damages as a result of Landlord’s failure to cause the Tenant Improvements for the Fifth Floor Premises to be Substantially Completed by not later than the Fifth Floor Substantial Completion Date or the Fourth Floor Premises to be Substantially Completed by not later than the Fourth Floor Substantial Completion Date are difficult to ascertain, that such amounts set forth above are a reasonable pre-estimate of Tenant’s probable loss as a result thereof and that such damages constitute reasonable liquidated damages for Tenant’s loss and not a penalty.
Commissioning preparation of a system or systems to allow hydrocarbons or other process fluids to be safely introduced into the system or systems for processing. In this phase testing will focus on systems, including utilities.
Final Completion 6.5.1 Final Completion of the Work shall be achieved within ninety (90) Days after the earlier of the actual date of Substantial Completion or the Scheduled Substantial Completion Date (the “Final Completion Date”).
Development and Regulatory Milestones With respect to each of the following milestones, Ikaria shall pay BioLineRx the corresponding payment set forth below within [**] days after the achievement by Ikaria, its Affiliates or Licensees of such milestone: MILESTONE PAYMENT
