SUBCONTRACTOR CLAIMS AND DISPUTES Sample Clauses

SUBCONTRACTOR CLAIMS AND DISPUTES. Subcontracts are between the SM and the subcontractor, and the SM is responsible for resolving subcontract disputes. The SM shall advise the ACO and COTR/ACOTR of disputes, changes in status of disputes, and potential costs or delays in delivery or possible litigation. MARAD will not directly participate in disputes and/or settlement. MARAD endorses and recommends the use of alternative disputes resolution (ADR) procedures. The SM is responsible for all administrative and legal costs associated with resolving such disputes, except when the government has authorized reimbursement by issuance of a TO. When private counsel has been authorized, the government will reimburse reasonable costs associated with such representation subject to the funding limitations of TO. Payments of judgments or settlements resulting from this disputes resolution process are the responsibility of the SM, although the SM may request reimbursement provided that indemnification under Section G.7.4.1 does not apply. SM is cautioned to seek prior approval from the ACO of settlements, which the SM intends to submit for reimbursement, in order that a reserve of appropriated funds can be made for the claim. The liability of the United States under this clause is subject to the availability of appropriated funds. If a dispute is not settled between the SM and the subcontractor and the matter advances to a formal claim in the Courts, Section G.7 Claims and Litigation will apply.
Sample 1Sample 2
AutoNDA by SimpleDocs

Related to SUBCONTRACTOR CLAIMS AND DISPUTES

  • Claims and Disputes A. Claims by CONTRACTOR shall be made in writing to the COUNTY within two (2) business days after the commencement of the event giving rise to such claim or CONTRACTOR shall be deemed to have waived the claim. All claims shall be priced in accordance with the section in this document entitled “Changes in Work”.

  • Resolution of Claims and Disputes 4.4.1 The Architect will review Claims and take one or more of the following preliminary actions within ten days of receipt of a Claim: (1) request additional supporting data from the claimant, (2) submit a schedule to the parties indicating when the Architect expects to take action, (3) reject the Claim in whole or in part, stating reasons for rejection, (4) recommend approval of the Claim by the other party or (5) suggest a compromise. The Architect may also, but is not obligated to, notify the surety, if any, of the nature and amount of the Claim.

  • Complaints and Disputes 28.1. If the Client wishes to report a complaint, he must send an email to the Company with the completed “Complaints Form” found on the Website. The Company will try to resolve it without undue delay and according to the Company’s Complaints Procedure for Clients.

  • Contractor Claims In the event of any demand by Contractor for (A) a time extension, including, without limitation, for relief from damages or penalties for delay assessed by the District under the Contract, (B) payment by the District of money or damages arising from work done by, or on behalf of, the Contractor pursuant to the Contract and payment of which is not otherwise expressly provided for or to which Contractor is not otherwise entitled to, or (C) an amount of payment disputed by the District, the parties shall attempt to resolve the dispute by those procedures set forth in Public Contract Code section 9204 and/or Article 1.5 (commencing with section 20104) of Chapter 1, Part, 3, Division 2, of the Public Contract Code, if applicable, the provisions of which are each attached hereto and incorporated herein by this reference. If a claim, or any portion thereof, remains in dispute upon satisfaction of all applicable dispute resolution requirements, the Contractor shall comply with all claims presentation requirements as provided in Chapter 1 (commencing with section 900) and Chapter 2 (commencing with section 910) of Part 3 of Division 3.6 of Title 1 of Government Code as a condition precedent to the Contractor’s right to bring a civil action against the District. For purposes of those provisions, the running of the time within which a claim must be presented to the District shall be tolled from the time the Contractor submits its written claim until the time the claim is denied, including any time utilized by any applicable meet and confer process. Pending resolution of the dispute, Contractor and its subcontractors shall continue to perform the Work under the Contract and shall not cause a delay of the Work during any dispute, claim, negotiation, mediation, or arbitration proceeding, except by written agreement of the District.

  • Complaints and Dispute Resolution 16.1 Where a dispute arises in connection with any aspect of this Agreement, the parties acting with good faith, will use all reasonable endeavours to bring any such issue to the attention of the other party in a timely fashion and in any event within 60 days of any such dispute coming to their attention.

  • Contract Disputes The Parties shall deal in good faith and attempt to resolve potential disputes informally. If the dispute concerning a question of fact arising under the terms of this Contract is not disposed of in a reasonable period of time by the Contractor’s Supervisor and the County‘s project manager as specified in Article 25. Notices by way of the following process, such matter shall be brought to the attention of the County DPA by way of the following process:

  • Disputes and Claims Failure to file such a protest within the time specified shall constitute agreement on the part of the Contractor with the terms, conditions, amounts and adjustments or non- adjustment to the contract price and/or contract time set forth in the field order.

  • Claims and Suits (a) The Receiver shall have the right, in its discretion, to (i) defend or settle any claim or suit against the Assuming Bank with respect to which the Receiver has indemnified the Assuming Bank in the same manner and to the same extent as provided in Article XII, and (ii) defend or settle any claim or suit against the Assuming Bank with respect to any Liability Assumed, which claim or suit may result in a loss to the Receiver arising out of or related to this Agreement, or which existed against the Failed Bank on or before Bank Closing. The exercise by the Receiver of any rights under this Section 9.3(a) shall not release the Assuming Bank with respect to any of its obligations under this Agreement.

  • Labour Disputes 15.01 If employees are prevented from performing their duties because of a strike or lock-out on the premises of another employer, the employees shall report the matter to the Employer, and the Employer will make reasonable efforts to ensure that such employees are employed elsewhere, so that they shall receive their regular pay and benefits to which they would normally be entitled.

  • Direct Claims Any Action by an Indemnified Party on account of a Loss which does not result from a Third Party Claim (a “Direct Claim”) shall be asserted by the Indemnified Party giving the Indemnifying Party reasonably prompt written notice thereof, but in any event not later than 30 days after the Indemnified Party becomes aware of such Direct Claim. The failure to give such prompt written notice shall not, however, relieve the Indemnifying Party of its indemnification obligations, except and only to the extent that the Indemnifying Party forfeits rights or defenses by reason of such failure. Such notice by the Indemnified Party shall describe the Direct Claim in reasonable detail, shall include copies of all material written evidence thereof and shall indicate the estimated amount, if reasonably practicable, of the Loss that has been or may be sustained by the Indemnified Party. The Indemnifying Party shall have 30 days after its receipt of such notice to respond in writing to such Direct Claim. The Indemnified Party shall allow the Indemnifying Party and its professional advisors to investigate the matter or circumstance alleged to give rise to the Direct Claim, and whether and to what extent any amount is payable in respect of the Direct Claim and the Indemnified Party shall assist the Indemnifying Party’s investigation by giving such information and assistance (including access to the Company’s premises and personnel and the right to examine and copy any accounts, documents or records) as the Indemnifying Party or any of its professional advisors may reasonably request. If the Indemnifying Party does not so respond within such 30 day period, the Indemnifying Party shall be deemed to have rejected such claim, in which case the Indemnified Party shall be free to pursue such remedies as may be available to the Indemnified Party on the terms and subject to the provisions of this Agreement.

Time is Money Join Law Insider Premium to draft better contracts faster.