Disputes and Claims definition

Disputes and Claims means all disputes and/or claims concerning Construction Budget, time, payment, and/or interpretation of this Agreement. Disputes and Claims include, but are not limited to, any disagreement resulting from a delay, a Change Order, any Modification, another written order, or an oral order from the Principal Representative, including any direction, instruction, interpretation, or determination by the Principal Representative, interpretations of the Agreement provisions, Drawings, Plans, or Specifications or the existence of alleged differing site conditions.
Sample 1Sample 2

Examples of Disputes and Claims in a sentence

  • If an award is made to another Federal agency or its FFRDC contractor, all Disputes and Claims will be resolved in accordance with the terms and conditions of the interagency agreement in consultation between DOE and the prime awardee.

  • If an award is made to a DOE/NNSA National Laboratory, all Disputes and Claims will be resolved in accordance with the terms and conditions of the DOE/NNSA National Laboratory’s management and operating (M&O) contract, as applicable, in consultation between DOE and the prime awardee.

  • Architect review of Disputes and Claims shall be impartial and meant to resolve Disputes and Claims.

  • If an award is made to a DOE/NNSA National Laboratory, all Disputes and Claims will be resolved in accordance with the terms and conditions of the DOE/NNSA National Laboratory’s M&O contract, as applicable, in consultation between DOE and the prime awardee.

  • Further, to provide a level of accuracy to the records submitted, the Owner shall have the right to audit books and records pursuant to Article 13.11 based on the actual costs incurred and to reduce the uncertainty in resolving Disputes and Claims with limited information.

  • Further, to provide a level of accuracy to the records submitted, the District shall have the right to audit books and records based on the actual costs incurred and to reduce the uncertainty in resolving Disputes and Claims with limited information.

  • Nothing in the Disputes and Claims procedures set forth in Articles 43 and 44 or other provisions in the General Conditions shall act to waive or relieve the Contractor from meeting the requirements set forth in Government Code section 900 et seq.

  • Claims under this GC shall be made in writing to the party liable within reasonable time after the first observance of such damage and not later than the time limits stipulated in GC 21 - Certificates and Payments, and may be adjusted by agreement or in the manner set out in GC 16 - Settlement of Disputes and Claims.

  • ARTICLE 44 CLAIMS PROCEDURES & REQUIREMENTS Pursuant to the remedies under Public Contract Code section 9201 and Government Code section 930.2, Contractor, through execution of this Agreement, also agrees to comply with the Claims requirements of this Article to quickly and efficiently resolve Disputes and Claims.

  • Disputes and Claims: The NRHA Contracting Officer shall review and decide disputes and claims arising during the performance of the contract, in writing, within thirty days of receipt of the dispute or claim.

Related to Disputes and Claims

  • Agreement Disputes shall have the meaning set forth in Section 6.1.

  • Disputes shall have the meaning set forth in Section 7.1.

  • Litigation Claims means the claims, rights of action, suits or proceedings, whether in law or in equity, whether known or unknown, that any Debtor or any Estate may hold against any Person or Entity, including, without limitation, the Causes of Action of the Debtors or their Estates, in each case solely to the extent of the Debtors’ or their Estates’ interest therein. A non-exclusive list of the Litigation Claims held by the Debtors as of the Effective Date will be Filed with the Plan Supplement, which will be deemed to include any derivative actions filed against any Debtor as of the Effective Date.

  • Dispute means any dispute, controversy, claim or difference of whatever nature arising out of, relating to, or having any connection with this Agreement, including a dispute regarding the existence, formation, validity, interpretation, performance or termination of this Agreement or the consequences of its nullity and also including any dispute relating to any non-contractual rights or obligations arising out of, relating to, or having any connection with this Agreement.

  • Unresolved Claims has the meaning set forth in Section 7.6(c).

  • Third Party Claims has the meaning set forth in Section 11.1.

  • Settled Claims means any and all actions, claims, debts, demands, duties, obligations, sums of money, suits, contracts, agreements, promises, damages, causes of action and rights and liabilities whatsoever (including, but not limited to, any claims for damages, interest, attorneys’ fees, expert or consulting fees and any other costs, expenses, losses, or liabilities whatsoever), whether based on federal, state or local statute or common law, rule or regulation, foreign or domestic, at law or in equity, matured or unmatured, foreseen or unforeseen, known or unknown, suspected or unsuspected, contingent or non-contingent, whether class or individual in nature, against the Released Parties, belonging to Plaintiff or to any other Class Member and/or their present or past heirs, executors, estates, administrators, predecessors, successors, assigns or to any other Person claiming through or on behalf of them (collectively, the “Releasing Persons”), that (i) have been asserted in this Action, or (ii) could have been asserted in this Action or in any other court, tribunal, proceeding or forum against the Released Parties, and that (x) arise out of, are based upon, or relate in any way to any of the claims or allegations in the Action including any of the acts, facts, events, disclosures, or omissions alleged in the Action, and (y) that relate to the purchase or acquisition of Cliffs Depositary Shares pursuant or traceable to the Company’s February 12, 2013 Offering and its associated Registration Statement. “Settled Claims” includes “Unknown Claims” as defined below. Excluded from Settled Claims are claims relating to the enforcement of the Stipulation or the Settlement.

  • Claims is defined in Section 12.3.

  • dispute resolution proceeding ’ means any process in which an alternative means of dispute resolution is used to resolve an issue in controversy in which a neutral is appointed and specified parties participate;

  • Informal proceedings means proceedings for probate of a will or appointment of a personal representative conducted by the probate register without notice to interested persons.

  • Litigation means any action, suit or proceeding before any court, mediator, arbitrator or Governmental Authority.

  • Legal Dispute means any action, suit or proceeding between or among the Parties arising in connection with any disagreement, dispute, controversy or claim arising out of or relating to this Agreement or any related document.

  • Arbitrable Dispute means any dispute arising under or in connection with this Agreement.

  • Technical Dispute has the meaning specified in Section 12.2;

  • industrial dispute means any dispute or difference between employers and employers, or between employers and workmen, or between workmen and workmen, which is connected with the employment or non-employment or the terms of employment or with the conditions of labour, of any person;

  • Labor dispute as used here, means a strike, lockout, or other labor dispute between the Employer and its Employees, during which time the Employee is not paid by the Employer.

  • civil proceedings means any proceedings in or before any court or tribunal that are not criminal proceedings;

  • trade dispute means any dispute or difference between employers and workmen, or between workmen and workmen, connected with the employment or non-employment, or the terms of employment, or with the conditions of labour, of any person;

  • Causes of Action means any action, claim, Claim, cause of action, controversy, demand, right, action, Lien, indemnity, Interest, guaranty, suit, obligation, liability, damage, judgment, account, defense, offset, power, privilege, license, and franchise of any kind or character whatsoever, whether known, unknown, contingent or non-contingent, matured or unmatured, suspected or unsuspected, liquidated or unliquidated, disputed or undisputed, secured or unsecured, assertable directly or derivatively, whether arising before, on, or after the Petition Date, in contract or in tort, in law, or in equity or pursuant to any other theory of law. For the avoidance of doubt, “Cause of Action” includes: (a) any right of setoff, counterclaim, or recoupment and any claim for breach of contract or for breach of duties imposed by law or in equity; (b) the right to object to Claims or Interests; (c) any Claim pursuant to section 362 or chapter 5 of the Bankruptcy Code; (d) any claim or defense including fraud, mistake, duress, and usury; and any other defenses set forth in section 558 of the Bankruptcy Code; and (e) any state or foreign law fraudulent transfer or similar claim.

  • Billing Dispute means the dispute of an invoice prepared by an Operator to the Other Operator which is made in good faith.

  • Professional Claim means an Administrative Claim of a Professional for compensation for services rendered or reimbursement of costs, expenses, or other charges and disbursements incurred relating to services rendered or expenses incurred after the Petition Date and prior to and including the Confirmation Date.

  • Unresolved Claim means a Claim, which at the relevant time, in whole or in part: (a) has not been Finally Determined to be a Proven Claim in accordance with the Amended Claims Procedure Order and this Plan; (b) is validly disputed in accordance with the Amended Claims Procedure Order; and/or (c) remains subject to review and for which a Notice of Allowance or Notice of Revision or Disallowance (each as defined in the Amended Claims Procedure Order) has not been issued to the Creditor in accordance with the Amended Claims Procedure Order as at the date of this Plan, in each of the foregoing clauses, including both as to proof and/or quantum;

  • Litigation support contractor means a contractor (including its experts, technical consultants, subcontractors, and suppliers) providing litigation support under a contract that contains the clause at 252.204-7014, Limitations on the Use or Disclosure of Information by Litigation Support Contractors.

  • Dispute Resolution Process means the process described in clause 9

  • consumer dispute means a dispute where the person against whom a complaint has been made, denies or disputes the allegations contained in the complaint;

  • Released Defendant Claims means any and all manner of claims, demands, rights, liabilities, losses, obligations, duties, damages, costs, debts, expenses, interest, penalties, sanctions, fees, attorneys’ fees, actions, potential actions, causes of action, suits, agreements, judgments, decrees, matters, counterclaims, offsets, issues, and controversies of any kind, nature, or description whatsoever, whether accrued or unaccrued, disclosed or undisclosed, apparent or not apparent, foreseen or unforeseen, matured or not matured, suspected or unsuspected, liquidated or not liquidated, fixed or contingent, whether based on state, local, federal, statutory, regulatory, common, or other law or rule, including known claims and Unknown Claims, which any Defendant ever had, now has, or may have against any of the Plaintiff Released Persons and/or the Released SLC Persons that arise out of, are based upon, or relate to the institution, prosecution, or settlement of the claims asserted in the Action. For the avoidance of doubt, the Released Defendant Claims shall not include any claims to enforce this Stipulation or the Settlement.