Shipments The Vendor shall ship, deliver or provide ordered products or services within a commercially reasonable time after the receipt of the order from the TIPS Member. If a delay in said delivery is anticipated, the Vendor shall notify TIPS Member as to why delivery is delayed and shall provide an estimated time for completion of the order. TIPS or the requesting entity may cancel the order if estimated delivery time is not acceptable or not as agreed by the parties.
Shipment Dell will ship the APEX System to the Site when included as part of the APEX Service. The terms and process for shipment and delivery of the APEX System will be stated in the applicable Service Offering Description.
Rejection State Street reserves the right to decline to process or delay the processing of a payment order which (a) is in excess of the collected balance in the account to be charged at the time of State Street's receipt of such payment order; (b) if initiating such payment order would cause State Street, in State Street's sole judgment, to exceed any volume, aggregate dollar, network, time, credit or similar limits upon wire transfers which are applicable to State Street; or (c) if State Street, in good faith, is unable to satisfy itself that the transaction has been properly authorized.
Purchase Orders Unless otherwise authorized in writing by the Commissioner, no Product is to be delivered or furnished by Contractor until transmittal of an official Purchase Order from the Authorized User. Unless terminated or cancelled pursuant to the authority vested in the Commissioner, Purchase Orders shall be effective and binding upon the Contractor when placed in the mail or electronically transmitted prior to the termination of the contract period, addressed to the Contractor at the address for receipt of orders set forth in the Contract or in the Contract Award Notification. All Purchase Orders issued pursuant to Contracts let by the Commissioner must bear the appropriate Contract number and, if necessary, required State approvals. As deemed necessary, the Authorized User may confirm pricing and other Product information with the Contractor prior to placement of the Purchase Order. The State reserves the right to require any other information from the Contractor which the State deems necessary in order to complete any Purchase Order placed under the Contract. Unless otherwise specified, all Purchase Orders against Centralized Contracts will be placed by Authorized Users directly with the Contractor and any discrepancy between the terms stated on the vendor’s order form, confirmation or acknowledgment, and the Contract terms shall be resolved in favor of the terms most favorable to the Authorized User. Should an Authorized User add written terms and conditions to the Purchase Order that conflict with the terms and conditions of the Contract, the Contractor has the option of rejecting the Purchase Order within five business days of its receipt but shall first attempt to negotiate the additional written terms and conditions in good faith with the Authorized User, or fulfill the Purchase Order. Notwithstanding the above, the Authorized User reserves the right to dispute any discrepancies arising from the presentation of additional terms and conditions with the Contractor. If, with respect to an Agency Specific Contract let by the OGS Commissioner, a Purchase Order is not received by the Contractor within two weeks after the issuance of a Contract Award Notification, it is the responsibility of the Contractor to request in writing that the appropriate Authorized User forward a Purchase Order. If, thereafter, a Purchase Order is not received within a reasonable period of time, the Contractor shall promptly notify in writing the appropriate purchasing officer in OGS. Failure to timely notify such officer may, in the discretion of the OGS Commissioner and without cost to the State, result in the cancellation of such requirement by the OGS Commissioner with a corresponding reduction in the Contract quantity and price.
Acceptance and Rejection a. Buyer shall accept the Services or give Seller notice of rejection within a reasonable time after the date of delivery. No payment, prior test, inspection, passage of title, any failure or delay in performing any of the foregoing, or failure to discover any defect or other nonconformance shall relieve Seller of any obligations under this Contract or impair any rights or remedies of Buyer.
Right to Reject Orders or Cancel Sales All orders, whether initial or additional, are subject to acceptance by and shall only become effective upon confirmation by the Company, which reserves the right to reject any order. Orders not accompanied by an executed Subscription Agreement and the required check or wire transfer in payment for the Shares may be rejected. Issuance and delivery of the Shares will be made only after actual receipt of payment therefor. If any check is not paid upon presentment, or if the Company is not in actual receipt of clearinghouse funds or cash, certified or cashier’s check or the equivalent in payment for the Shares within 15 days of sale, the Company reserves the right to cancel the sale without notice. In the event an order is rejected, canceled or rescinded for any reason, the Dealer agrees to return to the Dealer Manager any commission theretofore paid with respect to such order.
Purchase Order A Customer may use purchase orders to buy commodities or contractual services pursuant to the Contract and, if applicable, the Contractor must provide commodities or contractual services pursuant to purchase orders. Purchase orders issued pursuant to the Contract must be received by the Contractor no later than the close of business on the last day of the Contract’s term. The Contractor is required to accept timely purchase orders specifying delivery schedules that extend beyond the Contract term even when such extended delivery will occur after expiration of the Contract. Purchase orders shall be valid through their specified term and performance by the Contractor, and all terms and conditions of the Contract shall survive the termination or expiration of the Contract and apply to the Contractor’s performance. The duration of purchase orders for recurring deliverables shall not exceed the expiration of the Contract by more than twelve months. Any purchase order terms and conditions conflicting with these Special Contract Conditions shall not become a part of the Contract.
Correction of Errors Contractor shall perform, at its own cost and expense and without reimbursement from the District, any work necessary to correct errors or omissions which are caused by the Contractor’s failure to comply with the standard of care required herein.
Correction of Defects 35.1 The Engineer shall give notice to the Contractor of any Defects before the end of the Defects Liability Period, which begins at Completion and is defined in the Contract Data. The Defects Liability Period shall be extended for as long as Defects remain to be corrected.
Acceptance; Rejection A holder of Notes may accept the offer to prepay made pursuant to this Section 8.3 by causing a notice of such acceptance to be delivered to the Company not later than 15 days after receipt by such holder of the most recent offer of prepayment. A failure by a holder of Notes to respond to an offer to prepay made pursuant to this Section 8.3 shall be deemed to constitute a rejection of such offer by such holder.
